Philippine Supreme Court Jurisprudence


Philippine Supreme Court Jurisprudence > Year 1980 > December 1980 Decisions > G.R. No. L-49654 December 19, 1980 - VIRGILIO V. DIONISIO v. VICENTE PATERNO:




PHILIPPINE SUPREME COURT DECISIONS

SECOND DIVISION

[G.R. No. L-49654. December 19, 1980.]

VIRGILIO V. DIONISIO, Petitioner, v. HON. VICENTE PATERNO, in substitution of HON. BALTAZAR AQUINO as Minister of Public Highways and Chairman of the Contract Price Adjustment Committee and HON. NEMESIO YABUT as Municipal Mayor of Makati, Metro Manila, Respondents.

SYNOPSIS


Petitioner seeks reconsideration of the decision in G.R. No. L-49654 holding that Presidential Decree No. 454 and its amendment which refers to adjustment of the contract price of construction due to unexpected rise in the price of gasoline occuring after the job has already been started do not cover the case of petitioner contractor. Petitioner claims that the decision failed to hold categorically that he is entitled to the amount of adjustment prepared, computed and recommended by the CPAC Technical Committee, and instead left the reconciliation of the discrepancy between the 13.874% adjustment arrived at by the said committee, on the one hand, and the 2.86% adjustment approved by the CPAC itself and subsequently by the President, on the other, to the respondent and his subordinates and the CPAC, as well as the NEDA.

The Supreme Court, reiterating the reasons for its ruling in the decision sought to be reconsidered, held that to make petitioner seek from respondents the reconciliation of the CPAC 2.86% adjustment with its Technical Committee 13.874% adjustment is to unnecessarily make it difficult for petitioner, and ordered respondent to pay petitioner the updated government estimate or the 13.874% adjustment.

Motion granted and decision amended.


SYLLABUS


1. ADMINISTRATIVE LAW; MINISTRY OF PUBLIC HIGHWAYS; ADJUSTMENT OF CONTRACT PRICE UNDER PRESIDENTIAL DECREE NO. 454, AS AMENDED; NOT APPLICABLE IN CASE AT BAR. — The crux of the problem is whether the computation of the CPAC which applied PD. No. 454, as amended, to petitioner’s requested adjustment, is correct and legally tenable. In the decision now under reconsideration, the Court had ruled that the computation of CPAC which applied PD No. 454, as amended, to petitioner would not be fair, not only because the President had so ordered, but also because the rise in the prices of the material items of the construction in question took place before he started working and he accordingly opportunely asked for the corresponding updating of the GE. He was promised, it would be done provided, he started work immediately. Indeed, it is unfair to apply PD No. 454, as amended, to petitioner because as of the date he commenced, the prices had already gone up. It is so attested by the Technical Committee which updated the GE as of February 7, 1976, barely seven days after the work was started.

2. REMEDIAL LAW; JUDGMENTS; AMENDMENT IN CASE AT BAR; REASON THEREOF. — As the Court has already noted in its decision of July 23, 1980, it is quite remarkable and does not speak well of those concerned, that whereas other contractors who seemed to have delayed their work in order to get higher adjustment after six months were given up to 270% adjustment, on the other hand, petitioner who labored cooperatingly with the administration to finish his job long before the contract time is ironically being made to suffer by computing his adjustment only on work left undone after six months. Thus, the Court, if only to erase the manifest inequity that appears in the premises, and more, for the legal reasons given, is convinced that to make petitioner seek from respondents the reconciliation of the CPAC 2.86% adjustment with its Technical Committee 13.874% adjustment is to unnecessarily make things difficult for petitioner, and amended its decision so as to order respondent to pay petitioner the updated GE estimate as of February 7, 1976, i.e., the Technical Committee 13.874% adjustment, such that he is entitled to and should be paid the additional sum of P1,955,060.99, without interest.


R E S O L U T I O N


BARREDO, J.:


Motion for reconsideration dated August 24, 1980 of petitioner of the decision of this Court in this case of July 23, 1980. Despite copy thereof having been duly served upon respondents, no comment on nor opposition thereto has been filed by any of them with this Court up to this day.chanrobles lawlibrary : rednad

Incidentally, the case against respondent Mayor Nemesio Yabut has already become final and executory, no motion for reconsideration having been filed by either party in relation thereto. Anent to it, however, We might clarify that while We have not ordered immediate payment by respondent Mayor to petitioner, it is understood that said respondent is under immediate obligation to comply with the conditions specified in the Presidential directive of March 29, 1978 quoted in Our decision, namely, to promptly seek funds for the purpose and secure accounting and auditing approval thereof like a good judgment debtor, considering the comparatively better resources of the Municipality of Makati than other local governments.

The main gripe of petitioner against Our decision insofar as the respondent Minister of Public Highways and his successors are concerned, 1 is that We have failed to hold categorically that he is entitled to the amount of adjustment prepared, computed and recommended by the CPAC Technical Committee dated April 12, 1978, and instead left the reconciliation of the discrepancy between the 13.874% adjustment arrived at by the said CPAC Technical Committee, on the one hand, and the 2.86% adjustment approved by the CPAC itself and subsequently by the President, on the other, to the respondents and his subordinates and the CPAC, as well as the NEDA. Petitioner maintains that the record is replete with incontrovertible showing that it should be the former percentage of adjustment that should prevail and made the subject of Our mandamus.chanrobles virtual lawlibrary

After a careful review of the record. We are sufficiently persuaded that petitioner is right, for the following reasons:chanrob1es virtual 1aw library

1. There can be no dispute that the CPAC Technical Committee’s report and recommendation adhered to the directive of the President as regards the non-application to petitioner of PD 454, as amended, the commitment of Commissioner Aquino, We have found to be binding upon the Government and, as stated by the CPAC itself, in its Resolution 215, "the criteria used by the Technical Committee (was found by the Adjustment Committee — CPAC —) to be adequate and consistent with the existing conditions at the project area and with the guidelines adopted by the Contract Price Adjustment Committee."cralaw virtua1aw library

2. From the very start, petitioner has been making it more than plain that more accurately, he has not been demanding an adjustment under P.D. 454, even though he has referred to it, evidently, in a hurried effort to obtain relief from his predicament. For it is indeed clear that P.D. 454 and its amendment do not cover or contemplate petitioner’s situation. Said presidential decree refers to adjustment of the contract price of constructions due to unexpected rise in the price of gasoline occurring after the job has already been started. That is not the case of petitioner. In his case, what happened was that the original government estimate of P17,741,755.80 was based on prices prevailing on January 6, 1976. It occurred, however, that an unforeseen increase in the price of gasoline and the consequent increase of the other items involved in the construction took effect on January 15, 1976. Petitioner who was being urged, because of Presidential directives enjoining immediate start of the work in question, to proceed and accept by negotiation the construction. Petitioner demurred, citing the adverse effects of the January 15th rise of prices. But Commissioner Aquino could not wait; he urged petitioner to go ahead, assuring him that the G.E. (government estimate) would be correspondingly adjusted. In the spirit of cooperation with the administration of President Marcos, petitioner acceded to Commissioner Aquino’s request and assurance, which he naturally assumed was made in good faith, although not without making of record in writing the circumstances and the reasons that impelled him to start the job by writing Commissioner Aquino immediately about it. At first Commissioner Aquino was non-committal but after several tries on the part of petitioner, Commissioner Aquino finally reiterated his commitment in writing on March 4, 1978 as follows:jgc:chanrobles.com.ph

"‘We recognize the fact that the government estimate and the contract cost and unit prices were based on the prevailing prices of petroleum products and construction materials prior to the last increase in prices of petroleum products. We also recognize and appreciate your gesture of trust in our fairness by signing the contract to avoid delay in the project implementation fully aware of this fact.

‘In view hereof, we have forwarded for appropriate action to our ‘Contract Price Adjustment Committee’ your request for adjustment of contract cost. Rest assured that your request will be dealt with fairness.’" (Page 10, of Decision)

3. What transpired subsequently is not very easy to comprehend. Upon instructions of Commissioner Aquino, on April 12, 1978, the CPAC Technical Committee submitted a report signed by all its seven members. The report reads thus:jgc:chanrobles.com.ph

"MEMORANDUM FOR:chanrob1es virtual 1aw library

The Head Secretariat

CPAC, This Department

Reference is being made to your memorandum requesting for comment on the 2nd Indorsement dated March 15, 1978 of the Secretary of Economic Planning particularly with regards to the second paragraph thereof.

Relative thereto, please be informed that the total original government estimate for Buendia-Manila South Diversion Road Over pass, Sta. 0-370 to Sta. 0-385, Makati, Metro Manila, prepared on Jan. 6, 1976, was P17,741,755.80. On August 9, 1976, per request of that office, the original government estimate for said project was updated as of February 7, 1976 and the total updated cost was P20,203,340.90 or an increase of 13.874%.

CPAC TECHNICAL COMMITTEE:chanrob1es virtual 1aw library

(Sgd.) (Sgd.)

AMOR C. CENIDOZA OMAR C. COSTIBOLO

Member for Road Project Representative of COA,

Member

(Sgd.) (Sgd.)

JACINTO L. LAWAS DIOSDADO I. LAGMAN

Member Representative of DPWTC,

Member

(Sgd.)

NICASIO T. LEONCIO

Member for Bridge Projects

(Sgd.) (Sgd.)

ERWIN I. PATTUGALAN ALFREDO Z. REYES

Member for SPS & ADB Projects Chairman"

(Annex "E") (Page 12 of Decision)

The above adjustment figures represent a percentage of 13.874.

When this report was submitted to the CPAC itself, of which Commissioner Aquino was either co-chairman or member, surprisingly said committee, came out with a substantially different conclusion, notwithstanding its recognition that the criteria used by the Technical Committee was adequate and consistent with existing conditions and with the guidelines adopted by the CPAC. The CPAC reduced the adjustment only to 2.86%.chanrobles law library : red

We have endeavored to look deeply into this apparent inconsistency and We have discovered that, as contended by petitioner, the Technical Committee and the CPAC proceeded from different premises. While the figures in either case do not appear to be disputed, it has turned out that whereas its Technical Committee computed the GE as of February 7, 1976, almost at the commencement of the work, the CPAC, applying PD No. 454, as amended, and based its figures on the work that was unaccomplished after six months from its commencement, which were barely two months, petitioner having commendably exerted unusual efforts to finish the job long before the contracted deadline, thus leaving very little to be done during the last two months of the eight months within which the construction was completed and delivered. No less than in the rejoinder of respondent are these circumstances revealed. Pertinently, said rejoinder states:jgc:chanrobles.com.ph

"As of February 7, 1976, the original government estimate of P17,741,755.80 was updated and the total updated cost was P20,203,340.90 as found by the DPH Technical Committee.

However, respondent Minister of Public Highways stresses the fact that petitioner, in accordance with the said promise and the directive of President Marcos to give him an adjustment, already received the amount of P506,524.11 which was the amount awarded to him by the Contract Price Adjustment Committee, taking into account the provisions of Section 2 of Presidential Decree No. 454 as amended by PD 906 which reads:chanrob1es virtual 1aw library

Section 1. Section of Presidential Decree No. 454 is hereby amended to read as follows:chanrob1es virtual 1aw library

Section 2. Notwithstanding the provisions of Section 3 hereof, the initial adjustment of contract prices of projects covered by this Decree shall not be earlier than six (6) months after the date of bidding. Readjustments on the unit price shall be made every six months thereafter.’

As already stated in our comment, the contract was signed on January 28, 1976 and the project was finished in September 1976 or a period of eight months. Following the above quoted provision of the Decree on adjustment, petitioner cannot claim price adjustment earlier than six months from January 28, 1976. The reason why the result of his adjustment was only for 2.86% increase as compared with the other contractors who were granted increases ranging from 15% to 270.5% was primarily because after six months from the commencement of the prosecution of the project, only very little work was left, as evidenced by the fact that petitioner was able to completely finish the project in only two more months.

While it is true that the CPAC Technical Committee submitted a report that the government estimate of the project was updated as of February 7, 1976 to P20,203,340.90 or an increase of 13.87% from the original government estimate of P17,741,755.30, the same was not utilized as basis by the Contract Price Adjustment Committee considering that it will contravene the provisions of Section 2 of PD-454 as amended by PD-906 above quoted regarding the adjustment not earlier than six months. The amount of P506,524.11 given to petitioner by the Contract Price Adjustment Committee and which he admitted to have received was not only fair but in accordance with the intent and provisions of both PD-454 and PD 906. On the other hand, the P1,955,060.99 stated in the directive of the NEDA to respondent Aquino was based on petitioner’s own computation disregarding the provisions of said Presidential Decrees and was adopted by the said government agency under a mistake of fact." (Pp. 175-177 of Record)

And so, the crux of the problem now is whether the computation of the CPAC which applied PD No. 454, as amended, to petitioner’s requested adjustment, is correct and legally tenable. In Our decision now under reconsideration We have ruled on this point negatively, and We have not found, for none has been given, any reason why We should now rule differently. We reiterate that it would not be fair to apply PD No. 454, as amended, to petitioner, not only because the President had so ordered, but also because the rise in the prices of the material items of the construction in question took place before he started working and he accordingly opportunely asked for the corresponding updating of the GE. He was promised, it would be done provided, he started work immediately. Indeed, We say it is unfair to apply Pd No. 454, as amended, to petitioner because as of the date he commenced, the prices had already gone up. It is so attested by the Technical Committee which updated the GE as of February 7, 1976, barely seven days after the work was started.chanrobles virtual lawlibrary

As We have already noted in Our decision of July 23, 1980, it is quite remarkable and does not speak well of those concerned, that whereas other contractors who seemed to have delayed their work in order to get higher adjustments after six months were given up to 270% adjustment, on the other hand, petitioner who labored cooperatingly with the administration to finish his job long before the contract time is ironically being made to suffer by computing his adjustment only on the work left undone after six months. If only to erase the manifest inequity that appears in the premises, and more, for the legal reasons given above, We are convinced that to make petitioner seek from respondents the reconciliation of the CPAC 2.86% adjustment with its Technical Committee 13.874% adjustment is to unnecessarily make things difficult for petitioner. He would have to begin a calvary all over again, as We already intimated in Our decision.

AND SO, setting aside what appears to be strict technicality anyway, We hereby GRANT petitioner’s motion for reconsideration and the mandamus enjoined in Our decision is hereby amended so as to order as We hereby order the respondent to pay petitioner the updated GE estimate as of February 7, 1976, such that he is entitled to and should be paid the additional sum of P1,955,060.99, without interest.chanrobles virtual lawlibrary

IT IS SO ORDERED.

Aquino, Concepcion Jr., Fernandez, and De Castro, JJ., concur.

Abad Santos, J., took no part.

Endnotes:



1. Here We take judicial notice of the fact that Commissioner Paterno has been replaced by Minister Jesus Hipolito who is deemed joined hereto and bound hereby.




Back to Home | Back to Main




















chanrobles.com





ChanRobles On-Line Bar Review

ChanRobles Internet Bar Review : www.chanroblesbar.com

ChanRobles MCLE On-line

ChanRobles Lawnet Inc. - ChanRobles MCLE On-line : www.chanroblesmcleonline.com






December-1980 Jurisprudence                 

  • G.R. No. 72553 December 2, 1980 - FELICITO R. QUIMPO v. TANODBAYAN, ET AL.

  • G.R. No. L-39742 December 2, 1980 - AIR MANILA, INC. v. COURT OF INDUSTRIAL RELATIONS

  • G.R. No. L-27733 December 3, 1980 - RENATO RAYMUNDO v. ALBERTO R. DE JOYA, ET AL.

  • G.R. No. L-30686 December 3, 1980 - MARIANO UMALI v. FLORO CAPLI CRUZ

  • G.R. No. L-38840 December 3, 1980 - PEOPLE OF THE PHIL. v. PIO B. FERANDOS

  • G.R. Nos. L-44493-94 December 3, 1980 - DIATAGON LABOR FEDERATION LOCAL 110 OF THE ULGWP v. BLAS F. OPLE

  • G.R. Nos. L-26944-45 December 5, 1980 - PEOPLE OF THE PHIL. v. ELADIO GALVEZ, ET AL.

  • A.M. No. OCA-112 December 19, 1980 - IN RE: JUDGE JOSE G. PAULIN

  • A.M. No. 1867 December 19, 1980 - NATIONAL MINES AND ALLIED WORKERS UNION v. ROMEO A. REAL

  • AC-1928 December 19, 1980 - IN RE: MARCIAL A. EDILLION

  • G.R. No. L-23494 December 19, 1980 - ALFREDO CATOLICO v. FLORENCIO DEUDOR

  • G.R. No. L-26993 December 19, 1980 - PRESCIOSO EREVE v. LAZARO ESCAROS

  • G.R. No. L-27469 December 19, 1980 - NATIONAL SUGAR WORKERS UNION v. ARSENIO I. MARTINEZ

  • G.R. No. L-28821 December 19, 1980 - LILIA YUSAY GONZALES v. COURT OF TAX APPEALS, ET AL.

  • G.R. No. L-34057 December 19, 1980 - TROPICAL HOMES, INC. v. DELFIN FLORES

  • G.R. No. L-34532 December 19, 1980 - PASAY LAW AND CONSCIENCE UNION INC. v. PABLO CUNETA

  • G.R. No. L-40150 December 19, 1980 - PEOPLE OF THE PHIL. v. CESAR OBEDA

  • G.R. No. L-41764 December 19, 1980 - NEW PACIFIC TIMBER & SUPPLY CO. v. ALBERTO V. SENERIS

  • G.R. No. L-41885 December 19, 1980 - NAUTICA SHIPPING AGENCY AND MANAGEMENT CO. v. NATIONAL SEAMEN BOARD

  • G.R. No. L-45517 December 19, 1980 - PEOPLE OF THE PHIL. v. HERMINIGILDO MUÑOZ

  • G.R. No. L-47188 December 19, 1980 - VICTOR NATOR v. JOSE RAMOLETE

  • G.R. No. L-49654 December 19, 1980 - VIRGILIO V. DIONISIO v. VICENTE PATERNO

  • G.R. No. 50241 December 19, 1980 - PASUDECO WORKERS’ UNION OFFICERS v. BUREAU OF LABOR RELATIONS

  • G.R. No. 51809 December 19, 1980 - ABRAHAM RAZON v. AMADO G. INCIONG

  • G.R. No. 52789 December 19, 1980 - ROMEO S. GONZALES v. COMMISSION ON ELECTIONS

  • G.R. No. 52806 December 19, 1980 - GREGORIO ARANETA UNIVERSITY FOUNDATION v. AMADO G. INCIONG

  • G.R. Nos. 53581-83 December 19, 1980 - MARIANO J. PIMENTEL v. COMMISSION ON ELECTIONS

  • G.R. No. 54247 December 19, 1980 - REYNALDO A. FABULA v. NATIONAL LABOR RELATIONS COMMISSION

  • A.M. No. 100-MJ December 29, 1980 - CANDIDO BULAN v. TEOFILO B. CARDENAS

  • A.C. No. 126 December 29, 1980 - IN RE: ATTY. TRANQUILINO ROVERO

  • A.M. No. P-1343 December 29, 1980 - PABLO GARCIA v. JOSE S. CATBAGAN

  • A.M. No. 2112-CFI December 29, 1980 - JOSE MANGULABNAN v. JOSE TECSON

  • G.R. No. L-23950 December 29, 1980 - COMMISSIONER OF INTERNAL REVENUE v. PILAR TANJUATCO, ET AL.

  • G.R. No. L-35007 December 29, 1980 - THE CHIEF OF STAFF, AFP v. TEOFILO GUADIZ, JR.

  • G.R. No. L-40872 December 29, 1980 - MELECIA M. MACABUHAY v. JUAN L. MANUEL

  • G.R. No. L-41144 December 29, 1980 - IGNACIO BUENBRAZO v. GERONIMO R. MARAVE

  • G.R. No. L-43203 December 29, 1980 - JOSE CRISTOBAL v. ALEJANDRO MELCHOR

  • G.R. No. L-44597 December 29, 1980 - CORREA A. AJERO v. EMPLOYEES’ COMPENSATION COMMISSION

  • G.R. No. L-46584 December 29, 1980 - NICETAS VDA. DE CASAPAO v. REPUBLIC OF THE PHIL.