Philippine Supreme Court Jurisprudence


Philippine Supreme Court Jurisprudence > Year 2004 > June 2004 Decisions > Mindanao State University v. Roblett Industrial & Construction Corp : 138700 : June 9, 2004 : J. Carpio-Morales : Third Division : Decision:




Mindanao State University v. Roblett Industrial & Construction Corp : 138700 : June 9, 2004 : J. Carpio-Morales : Third Division : Decision

PHILIPPINE SUPREME COURT DECISIONS

THIRD DIVISION

[G.R. NO. 138700. June 9, 2004]

MINDANAO STATE UNIVERSITY, Petitioner, v. ROBLETT INDUSTRIAL AND CONSTRUCTION CORP., et. al. Respondents.

D E C I S I O N

CARPIO MORALES, J.:

From the November 27, 1998 Decision1 of the Court of Appeals affirming that dated January 23, 1991 of the Regional Trial Court (RTC) of Marawi City (Branch 8)2 which dismissed the Complaint for sum of money and damages of herein petitioner Mindanao State University (MSU), the Petition for Review 3 subject of the present decision was lodged.

On December 17, 1974, MSU, a government educational institution, represented by its then President Mauyag A. Tamano, and Roblett Industrial Construction Corporation (Roblett), represented by its Manager-Sales and Contractor Vicente D. Diana, Jr., forged a Construction Contract4 for the construction of a Student Center and Cafeteria building for a consideration of FIVE MILLION EIGHT HUNDRED THOUSAND (P5,800,000.00) PESOS. Contract time was fixed at eighteen months, to begin at the tenth (10th) calendar day following the receipt by [Roblett] of the Notice to Proceed with the work to be issued by the [MSU] after the signing of the [Contract].

To the Contract was attached an addendum5 reading:chanroblesvirtua1awlibrary

Anent to the contract executed by the University and the Roblett Industrial Construction Corporation, a provision has been provided that materials delivered by the contractors to the jobsite must be certified by the ARCHITECT and the PROJECT ENGINEER. Inasmuch as the contractor has already delivered the materials and the Architects certification will take time to be secured and in order to avail ourselves of the prevailing prices in the market, may we request authority that such procedure be revised. Upon delivery of materials on the jobsite, they will be inspected by the auditor for quantity and cost consideration per auditing regulations and the University engineer or his representative shall certify whether such materials delivered are within the specifications of that project. Payment could then be released to the contractor on this basis. (Emphasis and underscoring supplied)cralawlibrary

The contract price was subsequently twice escalated by a total of P2,441,725.00. The price, as escalated, thus amounted to P8,241,725.00.

In mid 1975, Tamano was replaced as President by Tukod Macaraya who adopted the policy that all contracts had to be first approved by the MSU Board of Regents, thus resulting in the suspension of the construction of the Student Center and Cafeteria. The suspension was to last for around seven months.

In November 1975, Tamano reassumed as President of MSU.

On June 22, 1976, MSU, represented by Tamano, and Roblett, represented by its Provincial Manager Cornelio Tan, entered into another Construction Contract for the construction of a Girls Dormitory and Recreation Hall for a consideration of TWO MILLION (P2,000,000.00) PESOS,6 within a contract period of six calendar months commencing on the tenth (10th) calendar day following the receipt by ROBLETT of the Notice to proceed with the construction. Shortly after the forging of this second contract, Tamano was again replaced as President, this time by then Provincial Governor Ali Dimaporo who suspended the construction projects.

In the meantime, a committee was formed by the MSU to appraise the construction of the Student Center and Cafeteria so far accomplished by ROBLETT. The committee, referred to as the Zozobrado Committee as it was headed by Public Works District Engineer II Roque Zozobrado, by Report dated November 15, 1976,7 concluded that ROBLETT had subsequently completed 58.747 or 59 percentum more or less of the total work. .. in the original contract.

The two escalations in the contract price for the construction of the Student Center and Cafeteria were subsequently approved by the MSU Board of Regents in its Resolution of March 21, 1977,8 after considering the phenomenal soaring of prices of labor and construction materials and to allow the contractor, Roblett. .., to continue and proceed with the project. .. ; Provided further that. .. 3) [Robletts] Performance Bond shall be renewed or updated and that [Roblett] shall finish the projects within a period of EIGHT (8) months from April 1977. The construction of both projects resumed soon after.

On June 8, 1978, QUAZAR INSURANCE AGENCY represented by Douglas Paalam with limited authority, as agent of PARAMOUNT INSURANCE CORPORATION, and ROBLETT executed in favor of MSU Performance Bond No. 01499 in the amount of P1,606,400.00 to secure the full and faithful performance by ROBLETT its part of [the contracts] and the satisfaction of obligations for materials used and labor employed upon the work.

Alleging that in mid 1978, even after Roblett had incurred delay in finishing the projects subject of the two contracts, it unjustifiably stopped construction and abandoned and refused to resume it, MSU filed a June 26, 1980 Complaint10 before the Regional Trial Court of Marawi City, for sum of money and damages, subject of the case at bar, against ROBLETT, its representatives and PARAMOUNT INSURANCE CORPORATION.

In its Complaint, MSU alleged that as of November 15, 1976, before the MSU Board approved on March 21, 1977 the two escalations in the construction cost of the Student Center and Cafeteria, Roblett drew through fraudulent means the total amount of P6,638,509.08. .. although the percentage of accomplishment was only 59%; that at the time of the filing of the complaint, ROBLETT had accomplished only 67% of the Student Center and Cafeteria but had withdrawn the total amount of P8,0891,919.4511 representing 97% of the escalated contract price of P8,241,725.00, hence, it was overpaid by P2,496,963.75;that with respect to the Dormitory and Recreation Hall, Roblett had accomplished only 94% of the project and had collected P1,670,000.00, and albeit there was no overpayment, since it incurred delay in the completion thereof, which would have been on November 30, 1977, the liquidated penalty provision of the contract covering it called for it to pay damages; that in view of ROBLETTs refusal to finish the projects, MSU was constrained to rescind the contracts, by letter of December 15, 197812 addressed to ROBLETT officials, and engage the services of another contractor to finish the projects; and that it notified PARAMOUNT INSURANCE CORPORATION, by letter of January 10, 1979,13 that it was confiscating the Performance Bond but it refused to comply with its obligations thereunder.

Roblett,in its Answer with Counterclaim and Crossclaim,14 denied abandoning the projects and being overpaid, it claiming that, inter alia, with respect to the Student Center and Cafeteria contract, it did not accept the terms and conditions of the MSU Board Resolution of March 21, 1977 and that it received less than P8,241,725.00 in accordance with the percentage of accomplishment duly certified to and approved by [MSU] and not due to fraud; that stoppage of the construction of the Student Center Cafeteria and the dormitory was involuntary. .. because no funds were made available and released by [MSU] for the completion of the buildings; that it finished the construction of the dormitory and if there was any delay in the accomplishment of the work therein, it was because [MSU] itself delayed and/or refused to release the necessary funds therefor, hence, the provision on liquidated penalty cannot apply; and that the contract paid for the Student Center and Cafeteria has not expired. .. because [MSU] has not yet made available and released the remaining funds for the completion thereof.

In its Answer with Counterclaim and Crossclaim15 too, PARAMOUNT INSURANCE CORPORATION, denying any liability under the Performance Board, alleged that, inter alia, Douglas Paalam was never empowered to execute the bond and, in any event, he violated its guidelines including failure to remit any premium as allegedly he was not paid therefor by MSU; and that the bond was executed only on June 8, 1978 after expiration, not prior to the execution, of the construction contracts as provided for therein (construction contracts).

In its decision,16 the trial court, noting the testimony of MSU witness Atty. Abdul Aguam, MSU Director for Legal Services, that there were three notices of suspension of work, and that of ROBLETT witness former MSU Assistant University Engineer Abdullah Sarangani that:chanroblesvirtua1awlibrary

.. . the MSU is located in this area and because of long rainy season, sometimes it lasts for seven days and certainly, it has adverse effect on the accomplishment of the project. Secondly, the MSU had undergone changes of leadership and it would appear that the changes of leadership brought about different policy. In the case of contract, there is usually investigation and this causes stoppage of work and also the weather affected the work; the labor force must have been disturbed. (Emphasis and underscoring supplied),

found that the delay in the completion of the Student Center and Cafeteria was not attributable to Roblett.

With respect to the issue of overpayment regarding the construction of the Student Center and Cafeteria, the trial court held that under the express provisions of the contract (Art. 5 [Exhibit 2] and Art. 6 [Exh. 1-13]), the University Engineer is the one empowered to determine the rate of progress of work and since witness [former MSU Assistant Engineer] Sarangani had positively identified the last Progress billing approved and signed by him, Exhibit 1 showing that as of period ending June 15, 1976 75.50% of the project had been completed], then this exhibit should prevail over all other evaluation.

The trial court went on to pass upon the effect of the MSU Board Resolution of March 21, 1977 on a) the November 15, 1976 Report of the Zozobrado Committee re the percentage of work (59%) done by Roblett, b) the payments to Roblett in excess of the original contract price, and c) the delay incurred by Roblett,in this wise:

x x x

The findings [in the November 15, 1976 Report] of the Zozobrado Commi[ttee] was evidently available to the Board before its meeting [on March 21, 1977]. The Board, however, did not order any investigation of any anomaly or asked (sic) Roblett to make a refund. Instead the Board approved the two escalations requested which in effect legalized all payments made previous to March 21, 1977 although it may have exceeded the original contract.

When the [March 21, 1977] resolution was adopted, the defendant Roblett ha[d] already incurred in delay, having exceeded the time frame of his original contract. However, the board adopted a new time frame from April 1 to Nov. 30, 1977. However, the Board Resolution was not converted into an addendum to the original contract and neither was it signed by both parties. It can be inferred from this fact that the defendant did not agree to this new time frame.

4.Can the plaintiff be permitted to deny and disclaim the official acts of its own university officials acting within the limits of their official capacities, in the absence of allegations and proofs of fraud and collusion with the defendant?chanroblesvirtualawlibrary

The witnesses for the defendant Roblett Albino Rivera and Abdullah Sarangani testified in a credible, frank and candid manner that all requests for payments were supported by Progress Reports which the staff of the Physical Plant Division had to verify, investigate, and assess first before it could be approved. And the billings and vouchers underwent further approval by the Administrative Division including the University President. There was never any allegation and proof of fraud and collusion and no university official was indicted for approving the vouchers. The university must therefore be estopped from denying the official acts of its own officials. Art. 1431 of the New Civil Code specifically provides thus

Through estoppel, an admission or representation is rendered conclusive upon the person making it, and cannot be denied or disproved as against the person relying thereon. (Emphasis and underscoring supplied)cralawlibrary

As for the claim of MSU for the enforcement of ROBLETTs Performance Bond, the trial court held that the QUAZAR INSURANCE AGENCY represented by Mr. Douglas Paalam failed to comply with the standard operating procedure under the Bonds Underwriting Guidelines of PARAMOUNT INSURANCE CORPORATION. More specifically, the trial court held, inter alia, that [t]his transaction was entered into by Roblett & QUAZAR INSURANCE AGENCY after a breach of the undertaking sought to be secured was already committed and was in violation of Article 11 of the contract between MSU and ROBLETT that a Performance Bond be secured upon the inception of the construction; and that no premium was received by PARAMOUNT INSURANCE CORPORATION for the bond.

The trial court accordingly rendered its decision, the dispositive portion of which reads:chanroblesvirtua1awlibrary

WHEREFORE, Plaintiffs complaint is ordered DISMISSED for its failure to prove the causes of action alleged in the complaint and judgment is rendered against the plaintiff and in favor of defendants Roblett and Paramount ordering plaintiff to pay

1.To defendant Roblett thirty thousand (P30,000.00) for attorneys fees and litigation expenses

2.To defendant Paramount Twenty Thousand (P20,000.00) for attorneys fees and Ten Thousand (P10,000.00) for litigation expenses.

Costs against plaintiff.

SO ORDERED.17 cralawred

On appeal by the MSU, the Court of Appeals as stated early on, by the challenged decision of November 27, 1998,18 affirmed the decision of the trial court.

Hence, MSUs present petition19 which assigns to the appellate court the same errors it assigned to the trial court, to wit:

I

THE LOWER COURT ERRED IN DISMISSING APPELLANTS COMPLAINT AGAINST APPELLEE ROBLETT INDUSTRIAL AND CONSTRUCTION CORPORATION DESPITE ROBLETTS DELAY IN PERFORMING ITS OBLIGATIONS UNDER THE CONTRACTS FOR THE CONSTRUCTION OF THE STUDENT CENTER AND GIRLS DORMITORY THAT WARRANTED PLAINTIFFS RESCISSION OF SAID CONTRACTS.

II

THE LOWER COURT ERRED IN DENYING APPELLANTS CLAIM FOR DAMAGES FOR ALLEGED FAILURE TO APPLY TO THE COURTS FOR A DECREE OF RESCISSION OR RESOLUTION.

III

THE LOWER COURT ERRED IN DENYING APPELLANTS CLAIM TO RECOVER THE AMOUNT OF THE PRICE OVERPAID TO ROBLETT UNDER THE CONTRACTS.

IV

THE LOWER COURT ERRED IN DISMISSING PLAINTIFFS CLAIM FOR INDEMNITY UNDER THE BOND ISSUED BY DEFENDANT PARAMOUNT INSURANCE CORPORATION ON THE GROUND THAT NO VALID CONTRACT EXISTS BECAUSE: 1) THE BOND WAS ISSUED IN EXCESS OF DOUGLAS PAALAMS AUTHORITY AS AGENT FOR PARAMOUNT; 2) THERE WAS NON-PAYMENT OF PREMIUMS.20 (Underscoring supplied)cralawlibrary

The jurisprudential doctrine that findings of facts of the Court of Appeals are conclusive on the parties, and carry even more weight when these coincide with the factual findings of the trial court21 must remain undisturbed, MSU not having succeeded in showing why the doctrine does not apply in the case at bar.

Indeed, there is no denying that the staccato delays in the construction of the Student Center and Cafeteria, which delays covered a total period of about 17 months, was in the main due to the policy changes of the different Presidents of MSU during the period of the construction undertaken by ROBLETT.

There is no denying too that, by the account of MSU former Asst. Engr. Sarangani, all requests for payment by ROBLETT were supported by PROGRESS REPORTS which were subjected to verification and assessment, and the billings and vouchers covering payments were combed through before they were finally approved by the MSU management.

It is thus incongruous for MSU to complain about having overpaid ROBLETT with respect to the construction of the Student Center and Cafeteria, especially in light of the provision of the Construction Contract that application for partial payment may be made by the CONTRACTOR corresponding to work already performed, materials installed, or in accordance with the schedule of values of individual work items approved by the PROJECT ENGINEER, and the March 21, 1977 MSU Board Resolution sanctioning the two escalations of the contract price previously made by the past administration. .. which resolution categorically stated that payment to the contractor shall be subject to the provisions of the National Accounting and Auditing Manual and other pertinent laws, decrees and rules on the matter and shall likewise be based on actual percentage of work accomplished. Any payments made to ROBLETT by MSU officials are, therefore, presumed to have been made in the regular performance of official duty.

As for MSUs allegation that ROBLETT was, as of November 15, 1976, able to draw from it, through fraudulent means, the total of P6,638,509.08 on [the Student Center and Cafeteria] contract although the percentage of accomplishment was only 59%, it bears emphasis that fraud is not presumed and must be proven by clear and convincing evidence.22 This MSU failed to discharge. In any event, as the trial court observed, the Zozobrado Committee Report reflecting part of the allegation was available to the MSU Board before it when, on March 15, 1977, it passed the Resolution of even date, yet no investigation or order for refund was made, as in fact the price escalations were approved.

In fine, MSU failed to indubitably show that ROBLETT welched on its obligations under the two contracts subject of the case. Discussion of the issue of rescission and damages is thus rendered unnecessary.23 And so is the issue of overpayment, also for failure to prove the same.

This renders unnecessary too a discussion of MSUs claim for the enforcement of ROBLETTs Performance Bond arising from the alleged delay in the completion of the construction contracts.

Even assuming arguendo that there was delay in the completion of the dormitory which was attributable to ROBLETT, MSU had not refuted with success the trial courts denial of such claim upon its finding that, among other things, the QUAZAR INSURANCE AGENCY exceeded its limited authority as agent to issue bonds and failed to comply with the procedure under the Bonds Underwriting Guidelines of PARAMOUNT INSURANCE CORPORATION to thus render the contract which was not ratified by PARAMOUNT INSURANCE CORPORATION unenforceable.

WHEREFORE, the petition is hereby DENIED.

SO ORDERED.

Vitug, (Chairman), Sandoval-Gutierrez, and Corona, JJ., concur.

Endnotes:


1 CA Rollo at 45-59.

2 RTC Records at 645-675.

3 Rollo at 8-32-a.

4 Exhibit A - A-7; Annex A to Complaint, RTC Records at 16-22.

5 Annex A-7 to Complaint, id. at 23.

6 Exhibit B B-9; Annex B to Complaint, Id. at 24-33.

7 Exhibit K.

8 Vide par. 9, Complaint, RTC Records at 9.

9 Exhibit C; Annex C to Complaint, Id. at 34-35.

10 The original records of the case were reconstituted after the building housing the RTC was burned on June 28, 1984. The reconstituted records do not show when the complaint was filed. The reconstituted complaint with Annexes A E is on pp. 6-41, RTC Records.

11 In its petition before this Court, MSU alleges in its Statement of Facts and Matters Involved that the amount already withdrawn by ROBLETT was P7,197.689.46, to thereby result to an overpayment of P1,750.150.46 (vide : Rollo at 14).

12 Exhibit D D-1; Annex D D-1 to Complaint, RTC Records at 38-39.

13 Exhibit E E-1; Annex E to Complaint, Id. at 40-41.

14 Id. at 42-50.

15 Id. at 64-69.

16 Vide note 2.

17 RTC Records at 675.

18 Vide note 1.

19 Vide note 3.

20 Rollo at 20-21.

21 Alcarez v. Tangga-an, 401 SCRA 84 (2003); Union Motor Corporation v. Court of Appeals, 361 SCRA 509 (2001); Nazareno v. Court of Appeals, 343 SCRA 637 (2000).

23 Art. 1191, Civil Code provides:chanroblesvirtua1awlibrary

The power to rescind obligations is implied in reciprocal ones, in case one of the obligors should not comply with what is incumbent upon him.

x x x x (Underscoring supplied)cralawlibrary




Back to Home | Back to Main




















chanrobles.com





ChanRobles On-Line Bar Review

ChanRobles Internet Bar Review : www.chanroblesbar.com

ChanRobles MCLE On-line

ChanRobles Lawnet Inc. - ChanRobles MCLE On-line : www.chanroblesmcleonline.com






June-2004 Jurisprudence                 

  • People v. Ojeda : 104238-58 : June 3, 2004 : J. Corona : Third Division : Decision

  • Standard Chartered v. Confesor : 114974 : June 16, 2004 : J. Callejo Sr : Second Division: Decision

  • Kara-an v. Ombudsman : 119990 : June 21, 2004 : J. Carpio : First Division : Decision

  • Teodosio v. CA: 124346 : June 8, 2004 : J. Corona : Third Division : Decision

  • Sps Apostol v. CA: 125375 : June 17, 2004 : J. Callejo Sr : Second Division : Decision

  • RP v. CA: 126316 : June 25, 2004 : J. Callejo Sr : Second Division : Decision

  • Sps Robles v. CA: 128053 : June 10, 2004 : J. Tinga : Second Division : Decision

  • Poblete v. CA: 128859 : June 29, 2004 : J. Tinga : Second Division : Resolution

  • Soriano v. CA: 128938 : June 4, 2004 : J. Tinga : Second Division : Decision

  • People v. Cario : 131117 : June 15, 2004 : J. Callejo Sr : Second Division : Decision

  • People v. Isnani : 133006 : June 6, 2004 : J. Sandoval-Gutierrez : Third Division : Decision

  • Tan v. Tan : 133805 : June 29, 2004 : J. Sandoval-Gutierrez : Third Division : Decision

  • People v. Reforma : 133440 : June 7, 2004 : J. Callejo Sr. : Second Division : Decision

  • People v. Ong : 137348 : June 21, 2004 : J. Puno : En Banc : Decision

  • Marcopper Mining Corp v. Solidbank Corp : 134049 : June 17, 2004 : J. Callejo Sr : Second Division : Decision

  • People v. Masagnay : 137364 : June 10, 2004 : J. Austria-Martinez : Second Division : Decision

  • Sonza v. ABS CBN : 138051 : June 10, 2004 : J. Carpio : First Division : Decision

  • Mindanao State University v. Roblett Industrial & Construction Corp : 138700 : June 9, 2004 : J. Carpio-Morales : Third Division : Decision

  • People v. Torpio : 138984 : June 4, 2004 : J. Callejo, Sr : Second Division : Decision

  • People v. Garin : 139069 : June 17, 2004 : J. Callejo Sr : Second Division : Decision

  • Macia v. Lim : 139284 : June 4, 2004 : J. Callejo Sr : Second Division : Decision

  • Santiago Lighterage v. CA: 139629 : June 21, 2004 : J. Carpio : First Division : Decision

  • People v. Hernandez : 139697 : June 15, 2004 : J. Callejo Sr : En Banc : Decision

  • People v. Ambrocio : 140267 : June 29, 2004 : J. Quisumbing : Second Division : Decision

  • People v. Ador : 140538-39 : June 14, 2004 : J. Puno : Second Division : Decision

  • Valencia v. Sandiganbayan : 141336 : June 29, 2004 : J. Ynares-Santiago : First Division : Decision

  • Rodson Philippines Inc v. CA: 141857 : June 9, 2004 : Second Division : Decision

  • Home Dev't v. COA: 142297 : June 15, 2004 : J. Azcuna : En Banc : Decision

  • Univ of Immaculate Concepcion v. Sec of Labor : 143557 : June 25, 2004 : J. Sandoval-Gutierrez : Third Division : Decision

  • People v. Ancheta : 143935 : June 4, 2004 : J. Corona : Third Division : Decision

  • SK Realty Inc v. KH Uy : 144282 : June 8, 2004 : J. Sandoval-Gutierrez : Third Division : Decision

  • Lung Center of the Phil v. QC : 144104 : June 29, 2004 : J. Callejo Sr : En Banc : Decision

  • People v. CA: 144332 : June 10, 2004 : J. Callejo Sr : Second Division : Decision

  • People v. Tonog Jr : 144497 : June 29, 2004 : J. Callejo Sr : Second Division : Decision

  • People v. Werba : 144599 : June 9, 2004 : J. Corona : En Banc : Decision

  • PRC v. De Guzman : 144681 : June 21, 2004 : J. Tinga : Second Division : Decision

  • Ramos v. CA: 145405 : June 29, 2004 : J. Corona : Third Division : Decision

  • People v. Hua Dian : 145348 : June 14, 2004 : J. Azcuna : First Division : Decision

  • Ong v. Mazo : 145542 : June 4, 2004 : J. Carpio-Morales : Third Division : Decision

  • People v. Cagas : 145504 : June 30, 2004 : J. Carpio-Morales : Third Division : Decision

  • Villanueva v. Yap : 145793 : June 10, 2004 : J. Callejo Sr : Second Division : Decision

  • Lascano v. Universal Steel Smelting Co Inc : 146019 : June 8, 2004 : J. Quisumbing : Second Division : Decision

  • People v. Pabiona : 145803 : June 30, 2004 : J. Carpio-Morales : Third Division : Decision

  • Valte v. CA: 146825 : June 29, 2004 : J. Carpio-Morales : Third Division : Decision

  • Pajuyo v. CA: 146364 : June 3, 2004 : J. Carpio : First Division : Decision

  • Capitle v. Vda de Gaban : 146890 : June 8, 2004 : J. Carpio-Morales : Third Division : Decision

  • MWSS v. Act Theater Inc : 147076 : June 17, 2004 : J. Callejo Sr : Second Division : Decision

  • People v. Aquino : 147220 : June 9, 2004 : J. Callejo Sr : Second Division : Decision

  • People v. Dumadag : 147196 : June 4, 2004 : J. Callrjo Sr : Second Division : Decision

  • Odango v. NLRC : 147420 : June 10, 2004 : J. Carpio : First Division : Decision

  • Lorenzo Shipping Corp v. Chubb and Sons Inc : 147724 : June 8, 2004 : J. Puno : Second Division : Decision

  • Martillano v. CA: 148277 : June 29, 2004 : J. Ynares-Santiago : First Division : Decision

  • People v. Bustinera : 148233 : June 8, 2004 : J. Carpio-Morales : Third Division : Decision

  • Pleyto v. Lomboy : 148737 : June 16, 2004 : Second Division : Decision

  • Mitsubishi Motors Phils Corp v. Chrysler Phils Labor Union : 148738 : June 29, 2004 : J. Callejo : Second Division : Decision

  • Dueas v. Santos Subdivision Homeowners Association : 149417 : June 4, 2004 : J. Quisumbing : Second Division : Decision

  • Bruan v. People : 149428 : June 4, 2004 : J. Callejo Sr : Second Division : Decision

  • PHILACOR v. CA: 149434 : June 3, 2004 : J. Ynares-Santiago : First Division : Decision

  • People v. Dagpin : 149560 : June 10, 2004 : J. Callejo Sr : Second Division : Decision

  • Notre Dame of Greater Manila v. Laguesma : 149833 : June 29, 2004 : J. Panganiban : First Division : Decision

  • People v. Tuvera : 149811 : June 8, 2004 : En Banc : Decision

  • Alcira v. NLRC : 149859 : June 9, 2004 : J. Corona : Third Division : Decision

  • Lapuz v. People : 150050 : June 17, 2004 : J. Azcuna : First Division : Decision

  • Tichangco v. Enriquez : 150629 : June 30, 2004 : J. Panganiban : First Division : Decision

  • People v. Presiding Judge of the RTC of Muntinlupa Br 276 : 151005 : June 8, 2004 : J. Panganiban : First Division : Decision

  • Mayor v. Masangkay : 151035 : June 3, 2004 : J. Ynares-Santiago : First Division : Decision

  • People v. Beriber : 151198 : June 8, 2004 : J. Tinga : En Banc : Decision

  • People v. De Guzman : 151205 : June 9, 2004 : Per Curiam : En Banc : Decision

  • PDIC v. CA: 151280 : June 10, 2004 : J. Callejo Sr : Second Division : Decision

  • Rubia v. GSIS : 151439 : June 21, 2004 : J. Quisumbing : Second Division : Decision

  • People v. Bandang : 151314 : June 3,. 2004 : J. Sandoval-Gutierrez : Third Division : Decision

  • People v. Escote : 151834 : June 8, 2004 : C.J. Davide, Jr : First Division : Decision

  • Magbanua v. Tabusares Jr : 152134 : June 4, 2004 : J. Puno : Second Division : Decision

  • Ayson v. Enriquez : 152438 : June 17, 2004 : J. Panganiban : First Division : Decision

  • Arceta v. Mangrobang : 152895 : June 15, 2004 : J. Quisumbing : En Banc : Resolution

  • People v. Comadre : 153559 : June 8, 2004 : Per Curiam : En Banc : Decision

  • People v. Comadre : 153559 : June 8, 2004 : J. Callejo Sr : En Banc : Concurring and Dissenting Opinion

  • Dayrit v. Readycon Trading & Corp : 151406 : June 29, 2004 : J. Quisumbing : Second Division : Decision

  • TF Ventures v. Matsuura : 154177 : June 9, 2004 : J. Ynares-Santiago : First Division : Decision

  • People v. Dela Cruz : 154348-50 : June 8, 2004 : J. Ynares-Santiago : First Division : Decision

  • Sps Abrigo v. De Vera : 154409 : June 21, 2004 : J. Panganiban : First Division : Decision

  • People v. Sps Kalaw : 155138 : June 8, 2004 : C.J. Davide Jr : First Division : Decision

  • RP Dinglasan Construction Inc v. Atienza : 156104 : June 29, 2004 : J. Puno : Second Division : Decision

  • CSC v. Cortez : 155732 : June 3, 2004 : Per Curiam : En Banc : Decision

  • Vincoy v. CA: 156558 : June 14, 2004 : J. Puno : Second Division : Decision

  • Du v. Stronghold Insurance Co : 156580 : June 14, 2004 : J. Panganiban : First Division : Decision

  • Sps Barredo v. Sps Leao : 156627 : June 4, 2004 : J. Puno : Second Division : Decision

  • People v. Pateo : 156786 : June 3, 2004 : J. Ynares-Santiago : First Division : Decision

  • Montenegro v. Montenegro : 156829 : June 8, 2004 : C.J. Davide Jr : First Division : Decision

  • Sps Occea v. Esponilla : 156973 : June 4, 2004 : J. Puno : Second Division : Decision

  • Samahan ng Magsasaka sa San Jose v. Valisno : 158314 : June 3, 2004 : J. Ynares-Santiago : First Division : Decision

  • Chavez v. Romulo : 157036 : June 9, 2004 : J. Sandoval-Gutierrez : En Banc : Decision

  • Ocampo v. House of Rep Electoral Tribunal : 158466 : June 15, 2004 : J. Sandoval-Gutierrez : En Banc : Decision

  • GSIS v. Cuanang : 158846 : June 3, 2004 : J. Ynares-Santiago : First Division : Decision

  • Cuada v. Drilon : 159118 : June 28, 2004 : J. Tinga : Second Division : Resolution

  • Gallera De Guison Hermanos Inc v. Cruz : 159390 : June 10, 2004 : J. Tinga : Second Division : Resolution

  • Honasan II v. The Panel of Investigating Prosecutors of the DOJ : 159747 : June 15, 2004 : J. Austria-Martinez : En Banc : Resolution

  • Secosa v. Francisco : 160039 : June 29, 2004 : J. Ynares-Santiago : First Division : Decision

  • CSC v. Arseni : 160657 : June 30, 2004 : J. Tinga : En Banc : Resolution

  • MWSS v. Daway : 160732 : June 21, 2004 : J. Azcuna : First Division : Decision

  • Freedom from Debt Coalition v. Meralco : 161113 : June 15, 2004 : J. Austria-Martinez : En Banc : Concurring and Dissenting Opinion

  • Freesom from Debt Coalition v. Meralco : 161113 : June 15, 2004 : J. Tinga : En Banc : Decision

  • Freedom From Debt Coalition v. MERALCO : 161113 : June 15, 2004 : J. Sandoval-Gutierrez : En Banc : Separate Opinion

  • Freedom From Debt Coalition v. MERALCO : 161113 : June 15, 2004 : J. Puno : En Banc : Concurring and Dissenting Opinion

  • Brillantes Jr v. Concepcion : 163193 : June 15, 2004 : J. Callejo Sr : En Banc : Decision

  • Espino v. Prequito : AC 4762 : June 28, 2004 : J. Puno : Second Division : Resolution

  • De Guzman v. Basa : AC 5554 : June 29, 2004 : J. Sandoval-Gutierrez : Third Division : Decision

  • Re: Habitual Tardiness incurred by Mr Alibang for the 1st Sem of 2003 : AM 2003-11-SC : June 15, 2004 : J. Sandoval-Gutierrez : En Banc : Decision

  • Administrative liabilities of Security Personnel involved in the entry of unidentified person at the PHILJA: AM 2003-18-SC : June 3, 2004 : J. Corona : En Banc : Resolution

  • Kampana v. Josue : AM 2004-09-SC : June 30, 2004 : J. Tinga : En Banc : Decision

  • Re AC No 04-AM-2002 : AM CA-02-15-P : June 3, 2004 : J. Carpio-Morales : En Banc : Decision

  • Balagtas v. Sarmiento Jr : AM MTJ-01-1377 : June 17, 2004 : J. Tinga : Second Division : Decision

  • Rio v. Cawaling : AM MTJ-02-1391 : June 7, 2004 : J. Callejo Sr : Second Division : Decision

  • OCAD v. Villegas : AM RTJ-00-1526 : June 3, 2004 : J. Corona : En Banc : Resolution

  • City Prosecution Office of Gen Santos City v. Bersales : AM MTJ-04-1522 : June 9, 2004 : J. Ynares-Santiago : First Division : Decision

  • Talag v. Reyes : AM MTJ-04-1852 : June 3, 2004 : J. Ynares-Santiago : First Division : Decision

  • Dela Cruz v. : Villalon-Pornillos : AM RTJ-04-1853 : June 8, 2004 : J. Tinga : Second Division : Decision

  • Manguerra v. Arriesgado : AM RTJ-04-1854 : June 8, 2004 : J. Ynares-Santiago : En Banc : Decision

  • In the Matter of Disqualification of Haron Meling : BM 1154 : June 8,2004 : J. Tinga : En Banc : Resolution