Philippine Supreme Court Jurisprudence


Philippine Supreme Court Jurisprudence > Year 2016 > February 2016 Decisions > G.R. No. 194960, February 03, 2016 - PRO BUILDERS, INC., Petitioner, v. TG UNIVERSAL BUSINESS VENTURES, INC., Respondent.:




G.R. No. 194960, February 03, 2016 - PRO BUILDERS, INC., Petitioner, v. TG UNIVERSAL BUSINESS VENTURES, INC., Respondent.

PHILIPPINE SUPREME COURT DECISIONS

THIRD DIVISION

G.R. No. 194960, February 03, 2016

PRO BUILDERS, INC., Petitioner, v. TG UNIVERSAL BUSINESS VENTURES, INC., Respondent.

D E C I S I O N

PEREZ, J.:

This Petition for Review on Certiorari assails the Decision1 dated 13 October 2010 and Resolution2 dated 16 December 2010 issued by the Court of Appeals in CA-G.R. SP No. 106407 which modified the Decision of the Arbitral Tribunal of the Construction Industry Arbitration Commission. (CIAC)

On 29 May 2007, TG Universal Business Ventures, Inc. (TG) entered into an Owner-Contractor Agreement (Agreement) with Pro Builders, Inc. (Pro Builders) for the construction of a 15-storey building at Asiatown I.T. Park in Lahug, Cebu City. In consideration of the sum of Seventy Million Pesos (P70,000,000.00), Pro Builders undertook to provide the labor, materials and equipment, and to perform all structural works for the project. On the other hand, TG undertook to pay Pro Builders a down payment of Twenty-One Million Pesos (P21,000,000.00), or equivalent to 30% of the amount of contract. Pursuant to the Agreement, the completion of the project is slated on 31 May 2008 but is subject to extension upon request of Pro Builders to TG, through its Project Manager, Prime Edifice, Inc., on the grounds of force majeure or fortuitous event and/or additional work approved by TG, or any other special circumstances as may be determined by TG.3 Upon signing of the Agreement, Pro Builders posted a performance bond obtained from Prudential Guarantee and Assurance, Inc.

The Notice of Award was issued to Pro Builders on 15 May 2007. The project site was turned over to Pro Builders on 22 May 2007. The construction was set to officially begin on 1 June 2007.4

On 19 June 2007, Pro Builders received the 30% down payment equivalent to P21,000,000.00.

Extremely unsatisfied with the progress of the works, TG took over the project, hired another contractor to finish the work, and demanded the balance of its overpayment from Pro Builders. The parties failed to reach an amicable settlement, prompting TG to file a Request for Arbitration with the CIAC praying for the payment of cost to complete the project, amounting to P13,489,807.48.5

Request for Arbitration filed by TG

According to the Project Manager, Project Manager, Prime Edifice, Inc., Pro Builders missed its target milestone for July 2007. On 28 August 2007, Project Manager, Prime Edifice, Inc. wrote to Pro Builders raising, serious concerns on the latter's ability to complete the project as scheduled. Project Manager, Prime Edifice, Inc. presented a Performance Evaluation for the period ending 28 August 2007 showing that Pro Builders only accomplished 13.37% out of the 19.09% target accomplishment or a variance of 5.72%. Project Manager, Prime Edifice, Inc. attributed Pro Builders' failure to meet the target to its inability to deploy the required manpower and equipment. On 31 August 2007, Project Manager, Prime Edifice, Inc. recommended to TG a full takeover by a more competent contractor to take effect immediately. Pro Builders responded to Project Manager, Prime Edifice, Inc.'s letter and alleged that some of the delays were attributable to TG, such as the delayed release of down payment and delivery of owner-supplied materials, particularly the reinforcing bars (rebars). For September 2007, Project Manager, Prime Edifice, Inc. revealed that Pro Builders again failed to meet its September milestones, accomplishing only 18.11% out of the 33.42% target accomplishment or slippage of 15.32%.

Due to the dismal performance of Pro Builders, TG invoked Article 9 of the Agreement or the Option to Complete Work Takeover. Pro Builders refused to turn over the works and demanded the payment of its unpaid progress billings.

On 11 January 2008, TG sent a Statement of Account to Pro Builders demanding payment of the excess cost to complete the project amounting to P13,489,807.48, which is broken down as follows:
chanRoblesvirtualLawlibrary
P5,582,921.10 - unconsumed down payment (21,000,000.00-15,417,078.90 assessed value of Pro Builders accomplishment as of 15 October 2007)

P7,771,553.04 - additional expenses by engaging another contractor

P135,333.34 - miscellaneous expenses (violation of Asiatown's guidelines, damage to property, lot rental)6
On 26 February 2008, TG filed a claim against the surety bond and performance bond.

The summary of TG's claim is as follows:
chanRoblesvirtualLawlibrary
Unliquidated down payment
P5,582,921.10
Cost to complete
7,771,553.04
Miscellaneous expenses
135,333.34
Litigation expenses
700,000.00
Attorney's fees
300,000.00
Total Claims
P14,489,807.487
Pro Builder's Amended Answer with Counterclaims

In its Answer, Pro Builders claimed that TG incurred delay when it only delivered 16% of the total requirement of rebars, an owner-supplied material. Pro Builders insisted that the targeted milestones were duly accomplished. Pro Builders added that the reckoning date of the performance evaluation should be within seven days upon receipt of the 30% down payment. Pro Builders counterclaimed for the following amounts and damages:
chanRoblesvirtualLawlibrary
Unpaid work accomplishment
P2,104,642.11
Compensatory damages
5,000,000.00
Rental deposit of the forms & scaffoldings for the period of one year
1,500,000.00
Surety bond
157,000.00
Construction all risk bond
142,000.00
Performance bond
96,450.00
Litigation expenses
1,000,000.00
Exemplary damages
500,000.00
Attorney's fees
200,000.00
Total counterclaims
P10,700,092.118
An Arbitral Tribunal was created and composed of Jacinto M. Butalid, as Chairman, Guadalupe O. Mansueto and Kian Hun T. Tiu.

The Arbitral Tribunal limited the issues to the following:
chanRoblesvirtualLawlibrary
  1. Who between the parties failed to comply with the terms and conditions of the Contract Agreement?

    1.1. Was Respondent-CONTRACTOR in delay in the Performance of the Construction Agreement?

    1.2. Was CLAIMANT in delay in the release of down payment and delivery of the Owner-Supplied materials?

  2. Is CLAIMANT entitled to its claim for unliquidated down payment in the amount of Php5,582,921.10?

  3. Is CLAIMANT entitled to the amount of Php7,771,553.04 as cost to complete the Project?

    3.1. How much was CLAIMANT'S cost to complete the works?

    3.2. How much was the Claimant's cost to complete the works IN EXCESS of the balance of the original contract price?

  4. Is CLAIMANT entitled to its claim of Php135,333.34 as miscellaneous expenses'?

  5. Is CLAIMANT entitled to its claim for litigation expenses in the amount of Php700.000.00? If so, how much?

  6. Is CLAIMANT entitled to its claim for attorney's fees in the amount of Php300,000.00? If so, how much?

  7. Is Respondent-CONTRACTOR entitled to its counterclaim of Php2,104,642.11 as unpaid work accomplishment?

  8. Is Respondent-CONTRACTOR entitled to its counterclaim of Php5,000,000.00 as compensatory damages? If so, how much?

  9. Is Respondent-CONTRACTOR entitled to its counterclaim of Php1,500,000.00 as rental deposit of the forms & scaffoldings for the period of one year?

  10. Is Respondent-CONTRACTOR entitled to its counterclaim of Php157,000.00 as cost incurred for its surety bond?

  11. Is Respondent-CONTRACTOR entitled to its counterclaim of Php142,000.00 as cost incurred for the construction all risk bond?

  12. Is Respondent-CONTRACTOR entitled to its counterclaim of Php96,450.00 as cost incurred for the performance bond?

  13. Is Respondent-CONTRACTOR entitled to its counterclaim of Php1,000,000.00 as litigation expenses? If so, how much?

  14. Is Respondent-CONTRACTOR entitled to its counterclaim of Php500,000.00 as exemplary damages? If so, how much?

  15. Is Respondent-CONTRACTOR entitled to its counterclaim of Php200,000.00 as attorney's fees? If so, how much?

  16. Is Respondent-Surety solidarily liable on its performance and surety bonds up to the total amount thereof?

  17. Whether or not the right of the CLAIMANT to claim against the subject surety and performance bonds of the respondent PRUDENTIAL had already expired and/or become time-barred or deemed waived?

  18. Whether or not the CLAIMANT as well as the other third-party Respondents are legally obliged jointly and severally to indemnify, pay or reimburse PRUDENTIAL in the unlikely event that the latter is held liable to pay CLAIMANT by virtue of the subject surety and performance bonds.9
Arbitral Tribunal's Decision

On 1 October 2008, the Arbitral Tribunal rendered a Decision, the dispositive portion of which reads:
chanRoblesvirtualLawlibrary
In view of the foregoing, it is hereby ordered that:

1. [TG] to pay [Pro Builders] for unpaid accomplishment in the amount of Php2,104,642.11.

2. [Pro Builders] to pay [TG] the amount of Php58,333.34 miscellaneous expenses as reimbursement of the said amount paid by [TG] for the rental of the staging area used by the [Pro Builders].

OFFSETTING Number 1 and 2, [TG] shall pay CONTRACTOR PRO Builders, Inc. the amount of Php2,046,308.77.

[TG's] claim for Unliquidated Down Payment, Cost to Complete the works, miscellaneous expenses except rental of the staging area, exemplary damages, litigation expenses and attorney's fees are denied for lack of merits.

[Pro Builders'] claim for compensatory damages, exemplary damages, rental deposit of forms and scaffoldings, cost of Surety Bond, Performance Bond and All Risk Bond, litigation expenses and attorney's fees are denied for lack of merits.10ChanRoblesVirtualawlibrary
The Arbitral Tribunal found that both parties failed to comply with their respective obligations and responsibilities under the Agreement. The Arbitral Tribunal expounded that Pro Builders failed to meet its target due to inability to deploy the required resources, i.e. manpower and equipment. Pro Builders also committed violations of concrete protocol. On the other hand, TG made the down payment only on 19 June 2007 and not upon execution of the Agreement as provided therein. TG also did not pay Pro Builders' progress billings and change order and incurred delay in the delivery of the owner-supplied rebars.

The Arbitral Tribunal denied TG's claim of P5,582,921.10 representing the unliquidated portion of the dawn payment. The Arbitral Tribunal gave credence to Pro Builders' billed amount of P23,104,642.11 as the value of the accomplished works.

The Arbitral Tribunal did not agree with TG's claim of P7,771,553.04 as the cost to complete the project. The Arbitral Tribunal held that said value can only be determined after the project has been fully completed. The Arbitral Tribunal favored TG's claim of P58,333.34 for the advanced rental of the staging area after finding that TG paid in advance the rental for a property adjacent to the project site used by Pro Builders.

The Arbitral Tribunal did not find any justification to award cost of litigation and compensatory damages to both parties.

The Arbitral Tribunal ruled that Pro Builders is entitled to P2,104,642.11 as the amount of unpaid accomplishment by subtracting the P21,000.000.00 down payment from the total accomplishment of P23,104,642.11.

The Arbitral Tribunal found that Pro Builders is not entitled to its claim for rental deposit for the forms and scaffoldings.

With respect to the cost of the bonds, the Arbitral Tribunal held that there is no provision in the contract or in the policy issued by Prudential for the reimbursement of the costs of the bonds. But the Arbitral Tribunal held that Prudential and Pro Builders are solidarity liable on its performance and surety bonds upon the total amount thereof. In the event that Prudential would be made to pay any liability by virtue of the surety and performance bonds, the Arbitral Tribunal stressed that it is only the third-party respondents who will be legally obliged to pay or reimburse the bonding company.

Aggrieved, TG filed a petition for review with the Court of Appeals. challenging in part the Decision of the Arbitral Tribunal, specifically on the following points:
chanRoblesvirtualLawlibrary
  1. TG was remiss in its obligation when it failed to give Pro Builders the down payment on time.

  2. TG was not entitled to reimbursement of P5,582,921.10 which was the balance of the unspent 30% down payment.

  3. TG was not allowed to charge P7,771,553.04 to Pro Builders representing the cost of what it had spent in completing the construction.

  4. TG did not have any right to miscellaneous expenses of P77,200.00.

  5. TG was not entitled to attorney's fees and expenses for litigation, cost of rectification and exemplary damages.11
The Court of Appeals Decision

On 13 October 2010, the Court of Appeals rendered the assailed Decision favoring TG, the decretal portion reads:
chanRoblesvirtualLawlibrary
ACCORDINGLY, the petition is GRANTED IN PART. The Decision dated October 1, 2008 of the Arbitral Tribunal of the Construction Industry Arbitration Commission in CIAC Case No. 04-2008 is MODIFIED:

a) ordering Pro Builders, Inc. to pay petitioner TG Universal Business Ventures, Inc. P5,582,921.10 as balance of the unspent 30% down payment; P7,771,553.04 as petitioner's cost in completing the subject construction; P77,200.00 as additional miscellaneous expenses; and P500,000.00 as attorney's fees and expenses of litigation.

b) declaring that petitioner is NOT ENTITLED to cost of rectification and exemplary damages.

c) deleting the award of P2,104,642.11 to Pro Builders Inc.

The Decision is AFFIRMED IN ALL OTHER RESPECTS.12ChanRoblesVirtualawlibrary
The Court of Appeals found that all inadequate performance was attributable to Pro Builders alone.

The appellate court found no delay in the down payment of P21,000,000.00 as its release on 19 June 2007 coincided with Pro Builder's posting of the surety bond. The Court of Appeals found merit in the claim for P5,582,921.10 by subtracting the down payment of P21,000,000.00 by Pro Builder's accomplishments worth P15,417,078.90. The appellate court sustained TG's estimate of Pro Builder's accomplishment to P15,417,078.90 because it was supported by documentary evidence. The appellate court added that TG's receipt of Pro Builder's progress billings did not estop the former from disputing the real amount of the latter's undertakings in the project. As the cost to complete the balance of the construction, the Court of Appeals held that TG is entitled to payment of P7,771,553.04 when it took over the project. Said amount is supported by documents presented by TG but which were disregarded by the Arbitral Tribunal. The appellate court also awarded P77,200.00 to TG, which is the total cost of damages that Pro Builders caused upon the properties of Asiatown I.T. Park where the project was built. Attorney's fees and expenses of litigation were also awarded to TG by the appellate court because it found that TG was compelled to initiate the proceedings before the Arbitral Tribunal.

Pro Builders sought a reconsideration of the unfavorable Decision but it was denied by the Court of Appeals in its Resolution13 dated 16 December 2010.

Petition

At the outset, Pro Builders implores us to delve into the facts as an exception to the rule that this Court is not a trier of facts. Pro Builders cites as ground the conflicting findings of the Arbitral Tribunal and the Court of Appeals.

Pro Builders asserts that the Court of Appeals erred in declaring that its accomplishments is worth only P15,417,078.90. Pro Builders refuted the joint evaluation used as basis by the Court of Appeals in denying its valuation on the ground that said joint evaluation was done solely by Project Manager, Prime Edifice, Inc. while Pro Builders' engineers had no participation in the evaluation. Moreover, said evaluation was submitted only on 11 January 2008, long after the contract was terminated. Pro Builders also defend the finding of the Arbitral Tribunal that its progress billings are more accurate and reliable than TG's valuation. Consequently, Pro Builders asserts that it still has a collectible of P2,104,642.11 and from that amount, the sum of P58,333.34 representing the rental of the staging area, should be deducted. TG then is obliged to pay P2,046,308.77 to Pro Builders.

Pro Builders echoes the Arbitral Tribunal's ruling that the cost overrun cannot be computed because at the time the case was submitted to the Arbitral Tribunal, the project was still not finished.

Pro Builders questions the award of attorney's fees and expenses of litigation for lack of basis.

Finally, Pro Builders avers that TG availed of the wrong remedy when it filed a petition for partial review before the Court of Appeals. Pro Builders maintains that the arbitral award of the CIAC is appealable on. questions of law to this Court.

OUR RULING

Procedural Issue


Executive Order (EO) No. 1008 vests upon the CIAC original and exclusive jurisdiction over disputes arising from, or connected with, contracts entered into by parties involved in construction in the Philippines, whether the dispute arises before or after the completion of the contract, or after the abandonment or breach thereof. Section 19 thereof declares the arbitral award of the CIAC as final and unappealable, except on questions of law, which are appealable to the Supreme Court. By virtue of the amendments introduced by R.A. No. 7902 and promulgation of the 1997 Rules of Civil Procedure, as amended, the CIAC was included in the. enumeration of quasi-judicial agencies whose decisions or awards may be appealed to the Court of Appeals in a petition for review under Rule 43. Such review of the CIAC award may involve either questions of fact, of law, or of fact and law.

The CIAC Revised Rules of Procedure Governing Construction Arbitration provide for the manner and mode of appeal from CIAC decisions or awards in Section 18 thereof, which reads:
chanRoblesvirtualLawlibrary
SECTION 18.2 Petition for review. - A petition for review from a final award may be taken by any of the parties within fifteen (15) days from receipt thereof in accordance with the provisions of Rule 43 of the Rules of Court.14ChanRoblesVirtualawlibrary
Applying the aforestated rules, the Court of Appeals is correct in taking cognizance of TG's appeal filed via petiti6n for review.

Substantive Issues

The issues raised by Pro Builders involve a question of fact. A question of fact exists when the issue raised on appeal pertains to the truth or falsity of the alleged facts. If the question posed requires a re-evaluation of the credibility of witnesses, or the existence or relevance of surrounding circumstances and their relationship to each other, the issue is factual.15

The general rule that findings of facts of the Courts of Appeals are deemed conclusive is subject to certain exceptions, such as:
chanRoblesvirtualLawlibrary
(1) when the factual findings of the [Court of Appeals] and the trial court are contradictory;

(2) when the findings are grounded entirely on speculation, surmises, or conjectures;

(3) when the inference made by the [Court of Appeals] from its findings of fact is manifestly mistaken, absurd, or impossible;

(4) when there is grave abuse of discretion in the appreciation of facts;

(5) when the [Court of Appeals], in making its findings, goes beyond the issues of the case, and such findings are contrary to the admissions of both appellant and appellee;

(6) when the judgment of the [Court of Appeals] is premised on a misapprehension of facts;

(7) when the [Court of Appeals] fails to notice certain relevant facts which, if properly considered, will justify a different conclusion;

(8) when the findings of fact are themselves conflicting;

(9) when the findings of fact are conclusions without citation of the specific evidence on which they are based; and

(10) when the findings of fact of the [Court of Appeals] are premised on the absence of evidence but such findings are contradicted by the evidence on record.16ChanRoblesVirtualawlibrary
Indeed, the factual finding of the Court of Appeals is contrary to the Arbitral Tribunal. This necessitates a review of the evidence adduced in this case.

Valuation of Pro Builders' Accomplished Works

The focal point of this controversy is the monetary equivalent of the accomplished works of Pro Builders.

Based on Pro Builders' computation, which were wholly based on its progress billings, the monetary value of its accomplishments is P22,482,934.34, broken down as follows:
chanRoblesvirtualLawlibrary
Billing Period Billed Amount
June 1-July 31, 2007 7,187,694.16
August 1-31, 2007 6,142,108.17
Sept. 1-30, 2007 6,844,363.73
Oct. 1-15, 2007 2,308,777.28
SUBTOTAL 22,482,943.34
Change Order 621,698.77
TOTAL 23,104,642.1117
By deducting the downpayment of P21,000,000.00 from the estimate of P22,482,943.34 and adding the amount of the change order of P621,598.77, Pro Builders claims that it is entitled to additional payment of P2,104,642.11.

Per TG's computation, the amount of Pro Builder's accomplishments is only P15,417,078.90, as supported by documentary evidence such as the Joint Evaluation allegedly made by both parties' representatives; photographs showing suspended slabs at the second floor; letter taking note of a joint inspection of the construction; summary of additive and deductive works; and written computation made by Pro Builders of the value of its Work Accomplishment. Thus, TG contends that Pro Builders must return the amount of P5,582,921.10 in excess of the P21,000,000.00 down payment.

We are called to determine which of the parties' valuation of accomplished works should be credited.

The Arbitral Tribunal gave more credence to the valuation of Pro Builders on the ground that TG's valuation lacked details. On the contrary, the Court of Appeals favored TG's valuation.

We find Pro Builders' valuation of the accomplished works to be more accurate.

A joint evaluation was agreed upon by the parties. Pro Builders initially demanded for a joint assessment of its accomplishment. TG responded that it is amenable for a joint assessment and added that such assessment had already been completed.

As found by the Arbitral Tribunal however, the alleged joint evaluation conducted by TG is in fact one-sided. It need not be emphasized that the Arbitral Tribunal's expertise is well recognized in the field of construction arbitration, as CIAC is indeed the body upon which the law vested with exclusive jurisdiction over any dispute arising from, or connected with construction contracts.18 In a letter dated 28 November 2007, Engineer Glenn Realiza, TGU Project Inspector sent his evaluation to Pro Builders' Project-in-Charge, Engineer Jeffrey Blanco (Engr. Blanco), months after the takeover and asked for the latters' feedback. The letter reads:
chanRoblesvirtualLawlibrary
November 28, 2007

Engr. Jeffrey Blanco
BPI Project in Charge
TGU Project

Dear Jeff:

I am sending you my evaluation of your accomplishment (structural works only) from foundation to second floor. The additive portion is your accomplishment for the third floor while the deductive covers for your unaccomplished works from foundation to second floor.

Please give me your feedback regarding this matter within 3 days so I can finalize the evaluation and forward it to our project manager.

Truly yours,

Red Glenn H. Realiza
TGU Project Inspector19ChanRoblesVirtualawlibrary
Project Manager, Prime Edifice, Inc. was appointed as Project Manager by TG Universal and has "authority at the job site throughout the duration of the PROJECT and x x x to certify to the satisfactory completion and implementation of this Agreement."20

Still on 11 January 2008, Project Manager, Prime Edifice, Inc. President Engineer Ed Hitosis wrote to Pro Builders' President Architect Paul G. Morgia demanding the settlement of P13,489,807.48 and inadvertently admitted that assessment of Pro Builders' accomplishment was done only by Project Manager, Prime Edifice, Inc., thus:
chanRoblesvirtualLawlibrary
We have completed the assessment of your accomplishment for the above project as of October 15, 2007 as well as updated the cost of the project given your original scope of work as quoted by the new contractor, ALCCON pursuant to Article 9, "OPTION TO COMPLETE WORK TAKEOVER" of your contract with TG Universal Business Ventures which states:

x x x x

We have attached our computation for your review. We appreciate your prompt action regarding the settlement of the total amount of PESOS: Thirteen Million Four Hundred Eighty-Nine Thousand Eight Hundred Seven and 48/100 (P13,489,807.48) Only.21ChanRoblesVirtualawlibrary
Documents attached to the Joint Evaluation, such as numerous photographs showing the suspended slabs at the second floor and a detailed computation of the works accomplished from mobilization, excavation, concreting works and formworks are self-serving because there was no showing that Pro Builders participated in the computation of their accomplished works.

Pro Builders' contention that Engineer Blanco and Engineer Bucol had participated in the project survey but the computation and evaluation-were done solely by Project Manager, Prime Edifice, Inc. was sustained by the Arbitral Tribunal. We agree that:

The documents on cost overrun (official receipts, check disbursement vouchers, billings, etc.) mentioned by the CLAIMANT in its Memorandum/Draft Decision were not participated in by the CONTRACTOR, nor had been confronted by the'CLAIMANT during the hearing for the CONTRACTOR to deny, comment or admit.22

On the other hand, the progress billings prepared by Pro Builders provide an accurate summary of Pro Builders' accomplishments. Article 5.03 of the Agreement states:
chanRoblesvirtualLawlibrary
5.03 The CONTRACTOR shall submit to the OWNER through the PROJECT MANAGER progress billing based on actual accomplishment of the various phases of the PROJECT. The PROJECT MANAGER shall process, certify to the correctness of, and make appropriate recommendations, and based on the recommendations, the OWNER shall make the actual payments. The appropriate recommendation shall be completed within fifteen (15) calendar days from receipt of complete billing documents. Final Payment shall be made in accordance with Article 17 of this Agreement.23ChanRoblesVirtualawlibrary
Clearly, it is the Project Manager's responsibility to evaluate, certify and recommend the payment of the progress billings. Pursuant to the Agreement, the appropriate recommendation should be completed within fifteen (15) calendar days from receipt of complete billing documents. Pro Builders sent four (4) progress billings to TG from August to October 2007. None of these progress billings were acted upon, paid or contested by TG in violation of the Agreement. On account of TG's failure to act upon the progress billings, it had effectively waived its right to question the accuracy and veracity of Pro Builders' computation, thus the amounts stated in the progress billings are deemed valid and binding on TG, thus:
chanRoblesvirtualLawlibrary
Progress Billing Date % of Accomplishment Amount
1 August 2007 10.27% P4,312,616.4924
13 September 2007 19.04% P7,997,881.4125
1 October 2007 29.21% P12,104,449.6326
30 October 2007 32.65% P2,104,642.1127
In F.F. Cruz & Co., Inc. v. HR Construction Corp.,28 the Court held that the owner is barred from contesting the contractor's valuation of the completed works when it waived its right to demand the joint measurement requirement. In the same vein, truly with more reason should it be concluded that TG had effectively waived its right to contest the computations in the progress billings since it failed to even act, one way or the other, on the progress billings within the time allowed under the Agreement.

As shown by the numbers, Pro Builders is entitled to payment of P2,104,642.11 for unpaid accomplishment of works, which amount is arrived at by subtracting the 30% down payment from the total unpaid billings and adding the change order.

Necessarily, TG's claim for cost to complete project is denied in view of its own failure to comply with its obligations under the Agreement.

Both Parties were in Breach of the Agreement

We likewise affirm the Arbitral Tribunal's finding that both parties failed to comply with their obligations under the Agreement. Records reveal that in the Notice of Award, Pro Builders was instructed "to mobilize within 7 days upon receipt of the 30% down payment."29 TG Universal however failed to pay the down payment during the signing, as provided for in the Agreement. Pro Builders received the down payment only on 19 June 2007.30 Thereafter, Pro Builders sought a clarification from TG as to the exact date of Day 1 of the construction citing as grounds the delay in the receipt of down payment, delay in the delivery of rebars and cement, rebar testing and heavy rainfall causing soil erosion.31 Pro Builders was asked to support its claims with documents. Upon submission by Pro Builders, TG found these submitted documents lacking in particulars. It was also proven during the proceedings before the Arbitral Tribunal that Pro Builders had failed to provide sufficient manpower and equipment which caused further delay to the project. As culled from the circumstances cited above, it is clear that both parties had been remiss in their respective obligations. The respective violations of the parties were encapsulated in the Decision of the Arbitral Tribunal, to wit:
chanRoblesvirtualLawlibrary
[Pro Builders'] failure to comply with its Obligations/Responsibilities

Violations of concrete protocol as shown in the Concrete Pouring permits and Pouring Logs (Exhibit "C-26").

The [Pro Builders'] Technical and Financial Annexes (TFIA) showing the equipment it will provide, but was not able to do so for the project (Exhibit "C-5").

As testified by Engr. Hitosis and Engr. Realiza of the project Management Team, (Exhibit "R-31") the table below shows the type and the number of equipment required in the project, as well as, the actual number furnished by the [Pro Builders].

Equipment
June 1-30, 2007
July 1-31, 2007
August 1-31, 2007
Required
TFIA
Actual
TFIA
Actual
TFIA
Actual
4 Tower Crane
0
0
0
0
2
1
l POa4y2loader
1
0
1
0
0
0
Back Hoe hb 405
2
1
2
1
2
1
Mini Roller 1 ton
2
2
2
1
2
1
1 bagger mixer
1
0
1
0
1
0
Vibrator
0
2
5
4
5
1
Electric bar cutter
0
2
2
2
2
1
Mdale Crane 25TONE
0
1
0
1
0
1

The [Pro Builders'] Technical and Financial Annexes (TFIA) to the Contract show the number of men to carry out the various phases of work. The table below shows these and the actual number of workmen in the job site. (Joint Affidavit of [TG's] Engineers).

Period Covered No. of Manpower in TFIA No. of Manpower at Jobsite
June 1-30, 2007
55
45
July 1-31, 2007
83
81
August 1-31, 2007
158
110

x x x x

[TG's] failure to comply with the Obligations/Responsibilities

The 30% down payment was made on 19 June 2008, not upon execution of the Agreement on 29 May 2007 as provided therein.

Not one of the [Pro Builders'] progress billings (No. 1 to No. 4)� and the Change Order was ever paid by the [TG].

[Pro Builders] claims delay in the delivery of the owner-supplied rebars, as follows:
chanRoblesvirtualLawlibrary
  1. On 26 June 2007, [TG's] structural engineers, Aromin & Sy, computed bar requirements to be 1,091,964.53 kilograms (Exhibit "R-10-A"). As of 13 July 2007, only 437,990.08 kilograms or rebars were delivered (Exhibits "R-10-B").

  2. As of 13 August 2007, a total of 967,954.38 kilograms of rebars were delivered far short of the 1,431,637.36 kilograms Per cutting list of rebar requirements from the foundation to the third floor approved by the [TG's] structural engineers (Exhibit "R-12-A").

  3. The delivery of the balance of rebars required were done only on 09 October 2007 (Exhibit "C-17").

  4. The excavation works for the footings and the foundations of the building was completed by the [TG] only on 24 August 2007, not on 31 July 2007 as required (Affidavit of Arch. Paul G. Morgia, PBI President, and Engr. Jeffrey Blanco, Project Engineer of the [Pro Builders]).

Arbitral Tribunal's Findings

On the delay by the [Pro Builders] in the performance of the construction agreement, the [Pro Builders] contends that had [TG] approved their request for the adjustment of Day 1 of the contract in accordance with the Notice of Award, the slippage would have been insignificant, if any.

The Notice of Award (Exhibit "R-2") dated 15 May 2007 states, among others, that you are hereby instructed to mobilize within 7 days upon receipt of the 30% down payment x x x. Project duration shall be 360 calendar days.

One of the Admitted Facts (Item 5.1) states that during the Pre-Construction Meeting No. 2 held on 22 May 2007, "Day 1 of the Construction officially slated on June 1, 2007". (Annex B, Supplemental Complaint).

On 09 July 2007, [Pro Builders] asked for time extension without specifying the number of days, but was required by the project Manager to submit additional documents (Exhibit "R-8").

On 16 July 2007, [Pro Builders] complied with the submittal of the required documents and asked for the start of Day 1 of the construction to be 15 July 2007 (instead of June 26 as provided for in the Notice of Award). [Pro Builders] contends that this was never acted by the Project Manager of the [TG] (Exhibit "R-9").

What the [Pro Builders] submitted was a Revised Work Schedule, but did not take into account a lot of factors, most especially, the time allocation for each activity. (Annex K, Complaint).

There was no S-Curve or PERT/CPM Network diagram submitted by the [Pro Builders] from where the corresponding monthly accomplishment can be assessed.

On 02 August 2007, the [Pro Builders] submitted Progress Billing No. 1 covering the period from June 1 to July 31, 2007. (Exhibit "R-25B" & "R-29").

On 28 August 2007, the project Manager wrote the [Pro Builders] raising serious concerns on the latter's ability to complete the project as scheduled (No. 14, Complaint).

[Pro Builders'] failure to meet its target could be accounted by its inability to deploy the required resources, i.e. manpower and equipment both of which are major factors in the concrete production output of the [Pro Builders] (Exhibits "C-6" to "C-10").

[TG] assessed the [Pro Builders'], monthly accomplishment to be behind schedule. The slippage as of 28 August 2007 was (-) 5.72% (Annex "G", Complaint) and (-) 15.32% on 30 September 2007 (Annex "M", Complaint).

On the delivery of owner-supplied reinforcing bars, the fact that as of 13 August 2007, 967,954.38 kilograms or approximately 968 tons had been delivered is undisputed. However, the parties' disagreement is with respect to the quantity of rebars required for the project.

The [Pro Builders] presented the transmittal letter dated 25 September 2007 with the attached Rebar Requirement, to wit:
chanRoblesvirtualLawlibrary
a. From foundation to 3rd floor (Exhibit "C-125-c")
- 1,431,637.76 kilograms
b. From 4th floor to 9th floor� (Exhibit "C-125-b")
- 1, 225, 020.06 kilograms
c. From 10th floor to Helipad level (Exhibit "C-125-a") - 1, 263, 647.61 kilograms
TOTAL - 3, 920,505.33 kilograms
The rebar requirements from foundation to the 3rd floor as alleged by [Pro Builders] is 1,431,637.76 kilograms as against [TG's] 967,954,38 kilograms. On cross-examination by the Counsel of the [TG's]. Arch. Morgia confirmed that based on their Bill of Quantities the rebar requirement from foundation to the 3rd floor is more of less 900,000 kilograms (TSN, page 266.)

In the [Pro Builders'] Bid Form (Exhibit "C-117") and the Bill of Quantities (Exhibit "C-117-a") attached to the Contract, the total rebar requirement of the project from basement to roof deck is 2,705,850.33 kilograms only. During the hearing, Arch. Morgia alleged that the rebar requirements in the letter of PRO Builders dated 25 September 2007 was due to changes in design. However, there was no evidence presented to establish the [Pro Builders'] contention that there were indeed design changes approved by the [TG].

As to the alleged delay in the delivery of concrete, [TG's] Summary of concrete Pouring Activities (Exhibit "C-25") indicates the dates of delivery, volume of concrete delivered and location in the project of the concrete pouring activities. These data were based on the Concrete Pouring permits of the [Pro Builders], which bear the date of approval and signatures of [TG's] project inspectors.

Referring to the circumstances enumerated in the preceding paragraphs, the Arbitral Tribunal finds both parties had failures to comply with their respective obligations and responsibilities as provided for in the Owner-Contractor Agreement.32 (Emphasis supplied)
With respect to Pro Builders' counterclaims, the same are correctly denied for lack of factual and legal bases.

In sum, we resolve to reinstate in its entirety the 1 October 2008 Decision of the CIAC.chanrobleslaw

WHEREFORE, based on the foregoing, we GRANT the petition. The 13 October 2010 Decision of the Court of Appeals in CA-G.R. SP No. 106407 is REVERSED AND SET ASIDE. The Decision of the Construction Industry Arbitration Commission dated 1 October 2008 in CIAC Case No. 04-2008 is REINSTATED.

SO ORDERED.

Velasco, Jr., (Chairperson), Peralta, Reyes, and Jardeleza, JJ., concur.

Endnotes:


1Rollo, pp. 88-131; Penned by Associate Justice Amy C. Lazaro-Javier with Associate Justices Rebecca De Guia-Salvador and Sesinando E. Villon concurring.

2 Id. at 132.

3 Id. at 139; Article 10.02 of the Owner-Contractor Agreement.

4 Id. at 169; Admitted Facts as cited in the Arbitral Tribunal's Decision. These facts were indicated in the Minutes of the Construction Meeting No. 2 dated 22 May 2007.

5 Records, Folder No. 3; See Statement of Accounts.

6Rollo, p. 349.

7 Id. at 441; See Term of Reference.

8 Id. at 164-165; See Amended Answer with Counterclaims.

9 Id. at 173-174.

10 Id. at 188.

11 Id. at 119-120.

12 Id. at 51-52.

13 Id. at 132.

14 J Plus Asia Development Corporal ion v. Utility Assurance Corporation, G.R. No. 199650, 26 June 2013, 700 SCRA 134, 146-147.

15Bases Conversion Development Authority v. Reyes, G.R. No. 194247, 19 June 2013, 699 SCRA 217, 226.

16 National Transmission Commission v. Alphaomega Integrated Corporation, G.R. No. 184295, 30� July 2014, 731 SCRA 299, 309-310.

17Rollo, p. 180.

18 Executive Order No. 1008, Section 4.

19Rollo, p. 266.

20 Id. at 133; See Owner-Contractor Agreement. (Emphasis ours)

21 Id. at 348.

22 Id. at 182.

23 Id. at 137.

24 Records, Folder No. 5, Exhibit "R-25." The amount is based on the following computation:
chanRoblesvirtualLawlibrary
A. Total Contract Amount
P 70,000,000.00
B. 10.27% Accompishment to date
7,187,694.00
Less:
Downpayment (30.00%)
2,156,308.25
Retention 10%
718,769.42
C. Total Amount Due
P 4, 312,616.49
25 Id.; Exhibit "R.-26." The amount is based on the following computation:
chanRoblesvirtualLawlibrary
A. Total Contract Amount
P 70,000.000.00
B. 19.04% Accomplishment to date
13,329, 802.00
Less:
Downpayment (30.00%)
3,998,940.69
Retention 10%
1,332,980.23
C. Total Amount Due (plus billing # 1-not yet paid)
P7,997.881.41
26 Id.; Exhibit "R-28." The amount is based on the following computation:
chanRoblesvirtualLawlibrary
A. Total Contract Amount
P 70,000.000.00
B. 29.21% Accomplishment to date
20,174,166.06
Less:
Downpayment (30.00%)
6,052.249.82
Retention
2,107,416.61
C. Total Amount Due (plus billing #1 & 2- not yet paid)
P12,104,499,63
27 Id., Exhibit "R-29." The amount is based on the following computation:
chanRoblesvirtualLawlibrary
A. 32.65% Accomplishment to date
22,482.943.34
B. Additional & Change order work
621,698.77
Less:
Downpayment (30.00%)
21,000,000.00
C. Total Amount Due (billing # 1st up to 4th & RFI 11, 20, 25, 39 &40)
P2,104,642.11
28 684 Phil. 330, 353 (2012).

29Rollo, p. 357.

30 Records, Folder No. 3; Annex "D" of Supplemental Complaint.

31 Id., Folder No. 5; Exhibit "R-8."

32Rollo, pp. 177-179.



Back to Home | Back to Main




















chanrobles.com





ChanRobles On-Line Bar Review

ChanRobles Internet Bar Review : www.chanroblesbar.com

ChanRobles MCLE On-line

ChanRobles Lawnet Inc. - ChanRobles MCLE On-line : www.chanroblesmcleonline.com






February-2016 Jurisprudence                 

  • G.R. No. 212878, February 01, 2016 - MARLOW NAVIGATION PHILS., INC., MARLOW NAVIGATION CO., LTD., W. BOCKSTLEGEL REEDEREI (GERMANY), ORLANDO D. ALIDIO AND ANTONIO GALVEZ, JR., Petitioners, v. WILFREDO L. CABATAY, Respondent.

  • G.R. No. 213910, February 03, 2016 - VINSON* D. YOUNG A.K.A. BENZON ONG AND BENNY YOUNG A.K.A. BENNY ONG, Petitioners, v. PEOPLE OF THE PHILIPPINES, AS REPRESENTED BY THE OFFICE OF THE SOLICITOR GENERAL, Respondent.

  • G.R. No. 198994, February 03, 2016 - IRIS MORALES, Petitioners, v. ANA MARIA OLONDRIZ, ALFONSO JUAN OLONDRIZ, JR., ALEJANDRO MORENO OLONDRIZ, ISABEL ROSA OLONDRIZ AND FRANCISCO JAVIER MARIA OLONDRIZ, Respondent.

  • G.R. No. 181186, February 03, 2016 - SIGUION REYNA MONTECILLO AND ONGSIAKO LAW OFFICES, Petitioners, v. HON. NORMA CHIONLO-SIA, IN HER CAPACITY AS PRESIDING JUDGE OF BRANCH 56 OF THE REGIONAL TRIAL COURT OF LUCENA CITY, AND THE TESTATE ESTATE OF DECEASED SUSANO RODRIGUEZ, REPRESENTED BY THE SPECIAL ADMINISTRATRIX, Respondents.

  • A.M. No. RTJ-13-2361 [Formerly OCA IPI No. 13-4144-RTJ], February 02, 2016 - OFFICE OF THE COURT ADMINISTRATOR, Complainant, v. PRESIDING JUDGE JOSEPH CEDRICK O. RUIZ, REGIONAL TRIAL COURT, BRANCH 61, MAKATI CITY, Respondent.

  • OCA I.P.I. No. 13-4148-P, February 10, 2016 - SPS. JOSE AND MELINDA CAILIPAN, Complainants, v. LORENZO O. CASTA�EDA, SHERIFF IV, REGIONAL TRIAL COURT, BRANCH 96, QUEZON CITY, Respondents

  • G.R. No. 205814, February 15, 2016 - SPOUSES ALFREDO TEA�O* AND VERONICA TEA�O, Petitioners, v. THE MUNICIPALITY OF NAVOTAS, REPRESENTED BY MAYOR TOBIAS REYNALD M. TIANGCO, AND MUNICIPAL TREASURER MANUEL T. ENRIQUEZ, Respondents.

  • G.R. No. 195145, February 10, 2016 - MANILA ELECTRIC COMPANY, Petitioner, v. SPOUSES SULPICIO AND PATRICIA RAMOS, Respondents.

  • G.R. No. 192075, February 10, 2016 - ROBERTO PALO Y DE GULA, Petitioner, v. PEOPLE OF THE PHILIPPINES, Respondent.

  • G.R. No. 194548, February 10, 2016 - JUANA VDA. DE ROJALES, SUBSTITUTED BY HER HEIRS, REPRESENTED BY CELERINA ROJALES-SEVILLA, Petitioner, v. MARCELINO DIME, SUBSTITUTED BY HIS HEIRS, REPRESENTED BY BONIFACIA MANIBAY, Respondent.

  • G.R. No. 218396, February 10, 2016 - PEOPLE OF THE PHILIPPINES, Plaintiff-Appellee, v. NESTOR ROXAS Y CASTRO, Accused-Appellant.

  • G.R. No. 208343, February 03, 2016 - SPOUSES CEFERINO C. LAUS AND MONINA P. LAUS, AND SPOUSES ANTONIO O. KOH AND ELISA T. KOH, Petitioners, v. OPTIMUM SECURITY SERVICES, INC., Respondent.

  • G.R. No. 199194, February 10, 2016 - REPUBLIC OF THE PHILIPPINES, Petitioner, v. JOSE B. SARE�OGON, JR., Respondent.

  • A.C. No. 7618, February 02, 2016 - SPOUSES JONATHAN AND ESTER LOPEZ, Complainants, v. ATTY. SINAMAR E. LIMOS, Respondent.

  • G.R. No. 199371, February 03, 2016 - PETRON LPG DEALERS ASSOCIATION AND TOTAL GAZ LPG DEALERS ASSOCIATION, Petitioners, v. NENA C. ANG, ALISON C. SY, NELSON C. ANG, RENATO C. ANG, AND/OR OCCUPANTS OF NATIONAL PETROLEUM CORPORATION, Respondents.

  • G.R. No. 208451, February 03, 2016 - MANILA MEMORIAL PARK CEMETERY, INC., Petitioner, v. EZARD D. LLUZ, NORMAN CORRAL, ERWIN FUGABAN, VALDIMAR BALISI, EMILIO FABON, JOHN MARK APLICADOR, MICHAEL CURIOSO, JUNLIN ESPARES, GAVINO FARINAS, AND WARD TRADING AND SERVICES, Respondents.

  • G.R. No. 190846, February 03, 2016 - TOMAS P. TAN, JR., Petitioner, v. JOSE G. HOSANA, Respondent.

  • G.R. No. 204970, February 01, 2016 - SPOUSES CLAUDIO AND CARMENCITA TRAYVILLA, Petitioners, v. BERNARDO SEJAS AND JUVY PAGLINAWAN, REPRESENTED BY JESSIE PAGLINAWAN, Respondents.

  • G.R. No. 205764, February 03, 2016 - PEOPLE OF THE PHILIPPINES, Plaintiff-Appellee, v. LEE QUIJANO ENAD, Accused-Appellant.

  • G.R. No. 196651, February 03, 2016 - UWE MATHAEUS, Petitioner, v. SPOUSES ERIC AND GENEVIEVE MEDEQUISO, Respondents.

  • G.R. No. 207355, February 03, 2016 - JENNIFER A. AGUSTIN-SE AND ROHERMIA J. JAMSANI-RODRIGUEZ, Petitioners, v. OFFICE OF THE PRESIDENT, REPRESENTED BY EXECUTIVE SECRETARY PAQUITO N. OCHOA, JR., ORLANDO C. CASIMIRO, OVERALL DEPUTY OMBUDSMAN, OFFICE OF THE OMBUDSMAN, AND JOHN I.C. TURALBA, ACTING DEPUTY SPECIAL PROSECUTOR, OFFICE OF THE SPECIAL PROSECUTOR, Respondents.

  • G.R. No. 209212, February 10, 2016 - PEOPLE OF THE PHILIPPINES, Plintiff and Appellee, v. ROMEL SAPITULA Y PACULAN, Accused-Appellant.

  • G.R. No. 191185, February 01, 2016 - GUILBEMER FRANCO, Petitioner, v. PEOPLE OF THE PHILIPPINES, Respondent.

  • A.M. OCA IPI No. 09-3210-RTJ, February 03, 2016 - JUVY P. CIOCON-REER, ANGELINA P. CIOCON, MARIVIT P. CIOCON-HERNANDEZ, AND REMBERTO C. KARAAN, SR., Complainants, v. JUDGE ANTONIO C. LUBAO, REGIONAL TRIAL COURT, BRANCH 22, GENERAL SANTOS CITY, Respondent.

  • A.C. No. 7594, February 09, 2016 - ADELPHA E. MALABED, Complainant, v. ATTY. MELJOHN B. DE LA PE�A, Respondent.

  • G.R. No. 207535, February 10, 2016 - PEOPLE OF THE PHILIPPINES, Plaintiff-Appellee, v. RICARDO LAGBO A.K.A RICARDO LABONG Y MENDOZA, Accused-Appellant.

  • G.R. No. 201073, February 10, 2016 - PHILIPPINE AIRLINES, INC. Petitioner, v. PAL EMPLOYEES SAVINGS & LOAN ASSOCIATION, INC., Respondent.

  • G.R. No. 180402, February 10, 2016 - COMMISSIONER OF INTERNAL REVENUE, Petitioner, v. PILIPINAS SHELL PETROLEUM CORPORATION, Respondent.

  • G.R. No. 208021, February 03, 2016 - OSCAR S. VILLARTA, Petitioner, v. GAUDIOSO TALAVERA, JR., Respondent.

  • G.R. No. 193748, February 03, 2016 - MERVIC REALTY, INC. AND VICCY REALTY, INC., Petitioners, v. CHINA BANKING CORPORATION, Respondent.

  • G.R. No. 181789, February 03, 2016 - GMA NETWORK, INC., Petitioner, v. NATIONAL TELECOMMUNICATIONS COMMISSION, CENTRAL CATV, INC., PHILIPPINE HOME CABLE HOLDINGS, INC., AND PILIPINO CABLE CORPORATION, Respondents.

  • G.R. No. 202978, February 01, 2016 - PEOPLE OF THE PHILIPPINES, Plaintiff-Appellee, v. VICTOR P. PADIT, Accused-Appellant.

  • A.C. No. 9807, February 02, 2016 - ERLINDA SISTUAL, FLORDELISA S. LEYSA, LEONISA S. ESPABO AND ARLAN C. SISTUAL, Complainants, v. ATTY. ELIORDO OGENA, Respondent.

  • G.R. No. 180642, February 03, 2016 - NUEVA ECIJA I ELECTRIC COOPERATIVE INCORPORATED (NEECO I), Petitioner, v. ENERGY REGULATORY COMMISSION, Respondent.

  • G.R. No. 194134, February 01, 2016 - JOSE ROMULO L. FRANCISCO, Petitioner, v. LOYOLA PLANS CONSOLIDATED INC., JESUSA CONCEPCION AND GERARDO B. MONZON, Respondents.

  • G.R. No. 187417, February 24, 2016 - CHRISTINE JOY CAPIN-CADIZ, Petitioner, v. BRENT HOSPITAL AND COLLEGES, INC., Respondent.

  • G.R. No. 170192, February 10, 2016 - PEOPLE OF THE PHILIPPINES, Plaintiffs-Appellees, v. MARISSA BAYKER, Accused-Appellant.

  • G.R. No. 202187, February 10, 2016 - PEOPLE OF THE PHILIPPINES, Appellee, v. ELISEO D. VILLAMOR, Appellant.

  • G.R. No. 210542, February 24, 2016 - ROSALINA CARODAN, Petitioner, v. CHINA BANKING CORPORATION, Respondent.

  • G.R. No. 215014, February 29, 2016 - REBECCA FULLIDO, Petitioner, v. GINO GRILLI, Respondent.

  • G.R. No. 215107, February 24, 2016 - REPUBLIC OF THE PHILIPPINES, REPRESENTED BY THE TOLL REGULATORY BOARD, Petitioner, v. C.C. UNSON COMPANY, INC., Respondent.

  • A.M. No. P-15-3300 (Formerly OCA I.P.I. No.12-4011-P), February 10, 2016 - JOSEPHINE E. LAM, Complainant, v. NILA M. GARCIA, JUNIOR PROCESS SERVER, MUNICIPAL TRIAL COURT, SIATON, NEGROS ORIENTAL, Respondent.

  • A.M. No. P-16-3423 [Formerly A.M. No. 13-9-89-MTCC], February 16, 2016 - RE: CIVIL SERVICE EXAMINATION IRREGULARITY (IMPERSONATION) OF MS. ELENA T. VALDEROSO, CASH CLERK II, OFFICE OF THE CLERK OF COURT, MUNICIPAL TRIAL COURT IN CITIES, ANTIPOLO CITY.

  • G.R. No. 210233, February 15, 2016 - REPUBLIC OF THE PHILIPPINES, Petitioner, v. THE COURT OF APPEALS, SPOUSES RODOLFO SY AND BELEN SY, LOLITA SY, AND SPOUSES TEODORICO AND LEAH ADARNA, Respondents.

  • G.R. No. 206256, February 24, 2016 - ALBERT C. AUSTRIA, Petitioner, v. CRYSTAL SHIPPING, INC., AND/OR LARVIK SHIPPING A/S, AND EMILY MYLA A. CRISOSTOMO, Respondents.

  • G.R. No. 202695, February 29, 2016 - COMMISSIONER OF INTERNAL REVENUE, Petitioner, v. GJM PHILIPPINES MANUFACTURING, INC., Respondent.

  • A.C. No. 5325, February 09, 2016 - NEMESIO FLORAN AND CARIDAD FLORAN, Complainants, v. ATTY. ROY PRULE EDIZA, Respondent.

  • G.R. No. 201927, February 17, 2016 - VICENTE D. CABANTING AND LALAINE V. CABANTING, Petitioners, v. BPI FAMILY SAVINGS BANK, INC., Respondent.

  • G.R. No. 184332, February 17, 2016 - ANNA TENG, Petitioner, v. SECURITIES AND EXCHANGE COMMISSION (SEC) AND TING PING LAY, Respondents.

  • G.R. No. 198434, February 29, 2016 - HEIRS OF LEANDRO NATIVIDAD AND JULIANA V. NATIVIDAD, Petitioners, v. JUANA MAURICIO-NATIVIDAD, AND SPOUSES JEAN NATIVIDAD CRUZ AND JERRY CRUZ, Respondents.

  • G.R. No. 182629, February 24, 2016 - MERCEDES N. ABELLA, MA. THERESA A. BALLESTEROS AND MARIANITO N. ABELLA, Petitioners, v. HEIRS OF FRANCISCA C. SAN JUAN namely: GLICERIA SAN JUAN CAPISTRANO, BENIGNA SAN JUAN VASQUEZ, EVARISTO SAN JUAN, NIEVES SAN JUAN LUSTRE AND MATILDE SAN JUAN QUILONIO, Respondents.

  • G.R. No. 207389, February 17, 2016 - PEOPLE OF THE PHILIPPINES, Plaintiff-Appellee, v. FEDERICO DE LA CRUZ Y SANTOS, Accused-Appellant.

  • G.R. No. 216566, February 17, 2016 - MAGELLAN AEROSPACE CORPORATION, Petitioner, v. PHILIPPINE AIR FORCE, Respondent.

  • G.R. No. 175760, February 17, 2016 - REPUBLIC OF THE PHILIPPINES, Petitioner, v. SOGOD DEVELOPMENT CORPORATION, Respondent.

  • G.R. No. 199537, February 10, 2016 - REPUBLIC OF THE PHILIPPINES, Petitioner, v. ANDREA TAN, Respondent.

  • G.R. No. 179287, February 01, 2016 - PCI JIMMY M. FORTALEZA AND SPO2 FREDDIE A. NATIVIDAD, Petitioners, v. HON. RAUL M. GONZALEZ IN HIS CAPACITY AS THE SECRETARY OF JUSTICE AND ELIZABETH N. OROLA VDA. DE SALABAS, Respondents.; G.R. NO. 182090 - ELIZABETH N. OROLA VDA. DE SALABAS, Petitioner, v. HON. EDUARDO R. ERMITA, HON. MANUEL B. GAITE, P/INSP. CLARENCE DONGAIL, P/INSP. JONATHAN LORILLA,1 PO3 ALLEN WINSTON HULLEZA AND PO2 BERNARDO CIMATU, Respondent.

  • G.R. No. 206758, February 17, 2016 - MARICEL S. NONAY, Petitioner, v. BAHIA SHIPPING SERVICES, INC., FRED OLSEN LINES AND CYNTHIA MENDOZA, Respondents.

  • G.R. No. 195026, February 22, 2016 - CENTRAL MINDANAO UNIVERSITY, REPRESENTED BY ITS PRESIDENT, DR. MARIA LUISA R. SOLIVEN, Petitioner, v. REPUBLIC OF THE PHILIPPINES, REPRESENTED BY THE DEPARTMENT OF ENVIRONMENT AND NATURAL RESOURCES, Respondent.

  • G.R. No. 174462, February 10, 2016 - PHILIPPINE OVERSEAS TELECOMMUNICATIONS CORPORATION (POTC), PHILIPPINE COMMUNICATIONS SATELLITE CORPORATION (PHILCOMSAT), Petitioners, v. SANDIGANBAYAN (3rd DIVISION), REPUBLIC OF THE PHILIPPINES REPRESENTED BY PRESIDENTIAL COMMISSION ON GOOD GOVERNMENT (PCGG), Respondents.

  • G.R. No. 199683, February 10, 2016 - ARLENE T. SAMONTE, VLADIMIR P. SAMONTE, MA. AUREA S. ELEPANO, Petitioners, v. LA SALLE GREENHILLS, INC., BRO. BERNARD S. OCA, Respondents.

  • G.R. No. 183486, February 24, 2016 - THE HONGKONG & SHANGHAI BANKING CORPORATION, LIMITED, Petitioner, v. NATIONAL STEEL CORPORATION AND CITYTRUST BANKING CORPORATION (NOW BANK OF THE PHILIPPINE ISLANDS), Respondents.

  • G.R. No. 194960, February 03, 2016 - PRO BUILDERS, INC., Petitioner, v. TG UNIVERSAL BUSINESS VENTURES, INC., Respondent.

  • G.R. No. 203678, February 17, 2016 - CONCORDE CONDOMINIUM, INC., BY ITSELF AND COMPRISING THE UNIT OWNERS OF CONCORDE CONDOMINIUM BUILDING, Petitioner, v. AUGUSTO H. BACULIO; NEW PPI CORPORATION; ASIAN SECURITY AND INVESTIGATION AGENCY AND ITS SECURITY GUARDS; ENGR. NELSON B. MORALES, IN HIS CAPACITY AS BUILDING OFFICIAL OF THE MAKATI CITY ENGINEERING DEPARTMENT; SUPT. RICARDO C. PERDIGON, IN HIS CAPACITY AS CITY FIRE MARSHAL OF THE MAKATI CITY FIRE STATION; F/C SUPT. SANTIAGO E. LAGUNA, IN HIS CAPACITY AS REGIONAL DIRECTOR OF THE BUREAU OF FIRE PROTECTION-NCR, AND ANY AND ALL PERSONS ACTING WITH OR UNDER THEM, Respondents.

  • G.R. No. 174481, February 10, 2016 - THE PEOPLE OF THE PHILIPPINES, Plaintiff-Appellee, v. CRISTY DIMAANO Y TIPDAS, Accused-Appellant.

  • G.R. No. 218867, February 17, 2016 - SPOUSES EDMOND LEE AND HELEN HUANG, Petitioners, v. LAND BANK OF THE PHILIPPINES, Respondent.

  • G.R. No. 190534, February 10, 2016 - C.F. SHARP CREW MANAGEMENT, INC., RONALD AUSTRIA, AND ABU DHABI NATIONAL TANKER CO., Petitioners, v. LEGAL HEIRS OF THE LATE GODOFREDO REPISO, REPRESENTED BY HIS WIFE LUZVIMINDA REPISO, Respondents.

  • A.C. No. 10945 (Formerly CBD 09-2507), February 23, 2016 - ANGELITO RAMISCAL AND MERCEDES ORZAME, Complainants, v. ATTY. EDGAR S. ORRO, Respondent.

  • G.R. No. 208406, February 29, 2016 - PEOPLE OF THE PHILIPPINES, Appellee, v. ALLAN RODRIGUEZ Y GRAJO, Appellant.

  • G.R. No. 177382, February 17, 2016 - VIVA SHIPPING LINES, INC., Petitioner, v. KEPPEL PHILIPPINES MINING, INC., METROPOLITAN BANK & TRUST COMPANY, PILIPINAS SHELL PETROLEUM CORPORATION, CITY OF BATANGAS, CITY OF LUCENA, PROVINCE OF QUEZON, ALEJANDRO OLIT, NIDA MONTILLA, PIO HERNANDEZ, EUGENIO BACULO, AND HARLAN BACALTOS, Respondents.

  • G.R. No. 203322, February 24, 2016 - PEOPLE OF THE PHILIPPINES, Appellee, v. REMAN SARIEGO, Appellant.

  • G.R. No. 186102, February 24, 2016 - NATIONAL TRANSMISSION CORPORATION, Petitioner, v. HEIRS OF TEODULO EBESA, NAMELY: PORFERIA L. EBESA, EFREN EBESA, DANTE EBESA AND CYNTHIA EBESA, AND ATTY. FORTUNATO VELOSO, Respondents.

  • G.R. No. 192233, February 17, 2016 - PEOPLE OF THE PHILIPPINES, Plaintiff and Appellee, v. SPO1 CATALINO GONZALES, JR., Accused-Appellant.

  • A.M. No. P-15-3393 [Formerly OCA IPI No. 13-4055-P], February 23, 2016 - SEGUNDINA P. NOCES-DE LEON AND LEONOR P. ALAVE, Petitioners, v. TERENCIO G. FLORENDO, SHERIFF IV, BRANCH 21, REGIONAL TRIAL COURT, VIGAN CITY, ILOCOS SUR, Respondent.

  • IPI No. 15-35-SB-J, February 23, 2016 - RE: VERIFIED COMPLAINT DATED JULY 13, 2015 OF ALFONSO V. UMALI, JR., Complainant, v. HON. JOSE R. HERNANDEZ, ASSOCIATE JUSTICE, SANDIGANBAYAN, Respondent.

  • A.M. No. P-15-3361 [Formerly OCA IPI No. 10-3381-P], February 23, 2016 - ATTY. JOHN V. AQUINO, Petitioner, v. ELENA S. ALCASID, CLERK III, REGIONAL TRIAL COURT, OFFICE OF THE CLERK OF COURT, OLONGAPO CITY, Respondent.

  • G.R. No. 185603, February 10, 2016 - REPUBLIC OF THE PHILIPPINES, Petitioner, v. LOCAL SUPERIOR OF THE INSTITUTE OF THE SISTERS OF THE SACRED HEART OF JESUS OF RAGUSA, Respondent.

  • G.R. No. 208404, February 24, 2016 - PEOPLE OF THE PHILIPPINES, Plaintiff-Appellee, v. VICENTE LUGNASIN AND DEVINCIO GUERRERO, Accused-Appellants.

  • G.R. No. 183529, February 24, 2016 - OFELIA C. CAUNAN, Petitioner, v. PEOPLE OF THE PHILIPPINES AND THE SANDIGANBAYAN, Respondents.

  • G.R. No. 207816, February 24, 2016 - PEOPLE OF THE PHILIPPINES, Plaintiff-Appellee, v. RAUL YAMON TUANDO, Accused-Appellant.

  • G.R. No. 171041, February 10, 2016 - REPUBLIC OF THE PHILIPPINES, Petitioner, v. MOLDEX REALTY, INC., Respondent.

  • G.R. No. 188720, February 23, 2016 - QUEZON CITY PTCA FEDERATION, INC., Petitioner, v. DEPARTMENT OF EDUCATION, REPRESENTED BY SECRETARY JESLI A. LAPUS, Respondent.

  • A.C. No. 8037, February 17, 2016 - RE: DECISION DATED AUGUST 19, 2008, 3RD DIVISION, COURT OF APPEALS IN CA-G.R. SP NO. 79904 [HON. DIONISIO DONATO T. GARCIANO, ET AL. V. HON. PATERNO G. TIAMSON, ETC., ET AL.], Petitioner, v. ATTY. JOSE DE G. FERRER, Respondent.

  • G.R. No. 220481, February 17, 2016 - VICTOR S. LIMLINGAN AND EMMANUEL A. LEYCO, Petitioners, v. ASIAN INSTITUTE OF MANAGEMENT, INC., Respondent.; G.R. No. 220503 - ASIAN INSTITUTE OF MANAGEMENT, INC., Petitioner, v. VICTOR S. LIMLINGAN AND EMMANUEL A. LEYCO, Respondents.

  • G.R. No. 208976, February 22, 2016 - THE HONORABLE OFFICE OF THE OMBUDSMAN, Petitioner, v. LEOVIGILDO DELOS REYES, JR., Respondent.

  • A.C. No. 10605, February 17, 2016 - BIENVENIDO T. CANLAPAN, Complainant, v. ATTY. WILLIAM B. BALAYO, Respondent.

  • G.R. No. 209180, February 24, 2016 - REPUBLIC OF THE PHILIPPINES, Petitioner, v. REGHIS M. ROMERO II AND OLIVIA LAGMAN ROMERO, Respondents.; G.R. NO. 209253 - OLIVIA LAGMAN ROMERO, Petitioner, v. REGHIS M. ROMERO II, Respondent.

  • G.R. No. 208948, February 24, 2016 - JOSE B. LURIZ, Petitioner, v. REPUBLIC OF THE PHILIPPINES, Respondents.

  • G.R. No. 173921, February 24, 2016 - PHILIPPINE AIRLINES, INC., Petitioner, v. ISAGANI DAWAL, LORNA CONCEPCION, AND BONIFACIO SINOBAGO, Respondents.; G.R. No. 173952 - ISAGANI DAWAL, LORNA CONCEPCION, AND BONIFACIO SINOBAGO, Petitioners, v. NATIONAL LABOR RELATIONS COMMISSION, PHILIPPINE AIRLINES, INC., AVELINO L. ZAPANTA, AND CESAR B. LAMBERTE, Respondents.

  • A.M. No. P-16-3419 [Formerly OCAIPI No. 11-3648-P], February 23, 2016 - AUGUSTO V. SANTOS, Complainant, v. SHERIFF IV ANTONIO V. LEA�O, JR., SHERIFF III BENJIE E. LACSINA, SHERIFF III ALVIN S. PINEDA, Respondent.

  • G.R. No. 184288, February 16, 2016 - ERIC N. ESTRELLADO AND JOSSIE M. BORJA, Petitioners, v. KARINA CONSTANTINO DAVID, THE CIVIL SERVICE COMMISSION, HIPOLITO R. GABORNI AND ROBERTO S. SE, Respondents.

  • G.R. No. 175210, February 01, 2016 - MARIO JOSE E. SERENO, EXECUTIVE DIRECTOR OF THE ASSOCIATION OF PETROCHEMICAL MANUFACTURERS OF THE PHILIPPINES, INC. (APMP), Petitioner, v. COMMITTEE ON TRADE AND RELATED MATTERS (CTRM) OF THE NATIONAL ECONOMIC AND DEVELOPMENT AUTHORITY (NEDA), COMPOSED OF THE DIRECTOR-GENERAL OF THE NEDA SECRETARIAT, THE EXECUTIVE SECRETARY, THE SECRETARIES OF TRADE AND INDUSTRY, FINANCE, FOREIGN AFFAIRS, AGRICULTURE, ENVIRONMENT AND NATURAL RESOURCES, BUDGET AND MANAGEMENT, TRANSPORTATION AND COMMUNICATION, LABOR AND EMPLOYMENT, AGRARIAN REFORM, THE GOVERNOR OF THE BANGKO SENTRAL NG PILIPINAS AND THE CHAIRMAN OF THE TARIFF COMMISSION, AND BRENDA R. MENDOZA IN HER CAPACITY AS DIRECTOR OF THE TRADE, INDUSTRY & UTILITIES STAFF, Respondents.

  • G.R. No. 170631, February 10, 2016 - CARAVAN TRAVEL AND TOURS INTERNATIONAL, INC., Petitioner, v. ERMILINDA R. ABEJAR, Respondent.

  • A.C. No. 8667, February 03, 2016 - INOCENCIO I. BALISTOY, Petitioner, v. ATTY. FLORENCIO A. BRON, Respondent.

  • IPI No. 14-222-CA-J, February 23, 2016 - RE: COMPLAINT OF ATTY. MARIANO R. PEFIANCO AGAINST JUSTICES MARIA ELISA SEMPIO DIY, RAMON PAUL L. HERNANDO, AND CARMELITA SALANDANAN-MANAHAN, OF THE COURT OF APPEALS CEBU.

  • G.R. No. 193176, February 24, 2016 - PRESIDENTIAL COMMISSION ON GOOD GOVERNMENT, Petitioner, v. OFFICE OF THE OMBUDSMAN, RENATO D. TAYAG, ISMAEL M. REINOSO, GENEROSO TANSECO, MANUEL MORALES, RUBEN B. ANCHETA, GERONIMO Z. VELASCO, TROADIO T. QUIAZON, JR., FERNANDO MARAMAG, EDGARDO TORDESILLAS, ARTURO R. TANCO, JR., GERARDO SICAT, PANFILO O. DOMINGO, POTENCIANO ILUSORIO, MANUEL B. SYQUIO, RAFAEL M. ATAYDE, HONORIO POBLADOR, JR., GEORGE T. SCHOLEY,1 TIRSO ANTIPORDA, JR., CARLOS L. INDUCTIVO, AND TEODORO VALENCIA, Respondents.