US LAWS, STATUTES and CODES : Chan Robles Virtual Law Library USA Supreme Court Decisions | Resolutions : Chan Robles Virtual Law Library

ChanRobles™ Virtual Law Library™ |™   
Main Index Repository of Laws, Statutes and Codes Latest Philippine Supreme Court Decisions Chan Robles Virtual Law Library Latest Legal Updates Philippine Legal Resources Significant Philippine Legal Resources Worldwide Legal Resources Philippine Supreme Court Decisions United States Legal Resources United States Supreme Court Jurisprudence ChanRobles LawTube - Social Network

ChanRobles Internet Bar Review : DebtKollect Company, Inc. - Debt Collection Firm Intellectual Property Division - Chan Robles Law Firm

Philippine Supreme Court DecisionsChanRobles On-Line Bar Review

google search for chanrobles.comSearch for

DAY V. UNITED STATES, 245 U. S. 159 (1917)

Subscribe to Cases that cite 245 U. S. 159 RSS feed for this section

U.S. Supreme Court

Day v. United States, 245 U.S. 159 (1917)

Day v. United States

No. 43

Argued November 13, 1917

Decided November 26, 1917

245 U.S. 159


Modern tendencies to depart from the strict letter in discovering intent do not alter the principle that, within the scope of his undertaking, a party contracting assumes the risks of intervening obstacles.

A contractor agreed with the United States to furnish, at specified rates, such labor and material in place as might be necessary to complete a canal and locks, already built in part, the total payment not to exceed a sum fixed in acts of Congress authorizing the contract. The government had erected a bulkhead, deemed of sufficient height, to safeguard the work from river floods; the contract, however, did not guarantee protection, referring to freshets and other natural causes merely as grounds for time extension. The contractor had been required to base his proposal upon personal investigation, and the specifications provided that he should be held responsible, without expense to the government, for the preservation and good condition of the work already in place, and that to be added from time to time under the contract, until the contract should be terminated or the whole work turned over in a completed condition as required. To protect the work from an extraordinary flood which exceeded the bulkhead, the contractor necessarily expended work and materials in building new structures, for which he sought reimbursement in the Court of Claims. Held that the contract was for the completion of the works, and that the cost of protecting them from floods in the meantime was within the contractor's undertaking.

48 Ct.Clms. 128; 50 id. 421, affirmed. chanroblesvirtualawlibrary

Page 245 U. S. 160

The case is stated in the opinion.

ChanRobles™ LawTube

google search for Search for

Supreme Court Decisions Philippine Supreme Court DecisionsUS Supreme Court Decisions



Browse By ->> Volume


Browse By ->> Year


  Copyright © ChanRobles Publishing Company | Disclaimer | E-mail Restrictions
ChanRobles™ Virtual Law Library |™