CHANROBLES VIRTUAL LAW LIBRARY
US LAWS, STATUTES and CODES : Chan Robles Virtual Law Library USA Supreme Court Decisions | Resolutions : Chan Robles Virtual Law Library

ChanRobles™ Virtual Law Library™ | chanrobles.com™   
Main Index Repository of Laws, Statutes and Codes Latest Philippine Supreme Court Decisions Chan Robles Virtual Law Library Latest Legal Updates Philippine Legal Resources Significant Philippine Legal Resources Worldwide Legal Resources Philippine Supreme Court Decisions United States Legal Resources United States Supreme Court Jurisprudence ChanRobles LawTube - Social Network

ChanRobles Internet Bar Review : www.chanroblesbar.com DebtKollect Company, Inc. - Debt Collection Firm Intellectual Property Division - Chan Robles Law Firm

Philippine Supreme Court DecisionsChanRobles On-Line Bar Review

google search for chanrobles.comSearch for www.chanrobles.com


UNITED STATES V. BROOKS-CALLAWAY CO., 318 U. S. 120 (1943)

Subscribe to Cases that cite 318 U. S. 120 RSS feed for this section

U.S. Supreme Court

United States v. Brooks-Callaway Co., 318 U.S. 120 (1943)

United States v. Brooks-Callaway Co.

No. 366

Argued January 4, 1943

Decided February 1, 1943

318 U.S. 120

Syllabus

Under the proviso to Article 9 of the Standard Form of Government Construction Contract, which provides that the contractor shall not be charged with liquidated damages because of delays due to unforeseeable causes, including floods, the remission of liquidated damages is not warranted where the "flood" was not unforeseeable, but was due to conditions normally to be expected. P. 318 U. S. 122.

97 Ct.Cls. 689 reversed.

Certiorari, 317 U.S. 615, to review a judgment against the United States in a suit upon a contract.





Back
ChanRobles™ LawTube

google search for chanrobles.com Search for www.chanrobles.com


Supreme Court Decisions Philippine Supreme Court DecisionsUS Supreme Court Decisions



www.chanrobles.us




QUICK SEARCH

cralaw

Browse By ->> Volume


cralaw

Browse By ->> Year


cralaw

  Copyright © ChanRobles Publishing Company | Disclaimer | E-mail Restrictions
ChanRobles™ Virtual Law Library | chanrobles.com™
 
RED