UNITED STATES SUPREME COURT DECISIONS ON-LINE

SIX COMPANIES OF CALIFORNIA V. HIGHWAY DISTRICT, 311 U. S. 180 (1940)

Subscribe to Cases that cite 311 U. S. 180 RSS feed for this section

U.S. Supreme Court

Six Companies of California v. Highway District, 311 U.S. 180 (1940)

Six Companies of California v.

Highway District No. 13 of California

No. 267

Argued November 13, 14, 1940

Decided December 9, 1940

311 U.S. 180

Syllabus

1. An announcement of state law by an intermediate state appellate court, in the absence of a contrary ruling by the highest state court or of other convincing evidence that the state law is otherwise, should be followed by federal courts. P. 311 U. S. 188.

2. An intermediate appellate court of California had ruled that, in that State, a stipulation in a construction contract for liquidated damages in case of delay in completion was inapplicable after abandonment of the work. This, apparently, had not been disapproved, and there was no convincing evidence that the law of the State was otherwise. Held, that the ruling should have been followed by the federal courts, in a case involving the same questions, in California. P. 311 U. S. 188.

110 F.2d 620 reversed.

Certiorari, post, p. 631, to review the affirmance of a Judgment for damages awarded on a cross-complaint, against a building contractor for delay in completing chanrobles.com-red

Page 311 U. S. 181

a building. Jurisdiction was based on diversity of citizenship. chanrobles.com-red

Page 311 U. S. 184


chanrobles.com



ChanRobles Professional Review, Inc.

ChanRobles Professional Review, Inc. : www.chanroblesprofessionalreview.com
ChanRobles On-Line Bar Review

ChanRobles Internet Bar Review : www.chanroblesbar.com
ChanRobles CPA Review Online

ChanRobles CPALE Review Online : www.chanroblescpareviewonline.com
ChanRobles Special Lecture Series

ChanRobles Special Lecture Series - Memory Man : www.chanroblesbar.com/memoryman