23 C.F.R. PART 636—DESIGN-BUILD CONTRACTING
Title 23 - Highways
Authority: Sec. 1307 of Pub. L. 105–178, 112 Stat. 107; 23 U.S.C. 101, 109, 112, 113, 114, 115, 119, 128, and 315; 49 CFR 1.48(b).
Source: 67 FR 75926, Dec. 10, 2002, unless otherwise noted.
This part describes the FHWA's policies and procedures for approving design-build projects financed under title 23, United States Code (U.S.C.). This part satisfies the requirement of section 1307(c) of the Transportation Equity Act for the 21st Century (TEA–21), enacted on June 9, 1998. The contracting procedures of this part apply to all design-build project funded under title 23, U.S.C. (a) This part uses a plain language format to make the rule easier for the general public and business community to use. The section headings and text, often in the form of questions and answers, must be read together. (b) Unless otherwise noted, the pronoun “you” means the primary recipient of Federal-aid highway funds, the State Transportation Department (STD). Where the STD has an agreement with a local public agency (or other governmental agency) to administer a Federal-aid design-build project, the term “you” will also apply to that contracting agency. Unless otherwise specified in this part, the definitions in 23 U.S.C. 101(a) are applicable to this part. Also, the following definitions are used: Adjusted low bid means a form of best value selection in which qualitative aspects are scored on a 0 to 100 scale expressed as a decimal; price is then divided by qualitative score to yield an “adjusted bid” or “price per quality point.” Award is made to offeror with the lowest adjusted bid. Best value selection means any selection process in which proposals contain both price and qualitative components and award is based upon a combination of price and qualitative considerations. Clarifications means a written or oral exchange of information which takes place after the receipt of proposals when award without discussions is contemplated. The purpose of clarifications is to address minor or clerical revisions in a proposal. Communications are exchanges, between the contracting agency and offerors, after receipt of proposals, which lead to the establishment of the competitive range. Competitive acquisition means an acquisition process which is designed to foster an impartial and comprehensive evaluation of offerors' proposals, leading to the selection of the proposal representing the best value to the contracting agency. Competitive range means a list of the most highly rated proposals based on the initial proposal rankings. It is based on the rating of each proposal against all evaluation criteria. Contracting agency means the public agency awarding and administering a design-build contract. The contracting agency may be the STD or another State or local public agency. Deficiency means a material failure of a proposal to meet a contracting agency requirement or a combination of significant weaknesses in a proposal that increases the risk of unsuccessful contract performance to an unacceptable level. Design-bid-build means the traditional project delivery method where design and construction are sequential steps in the project development process. Design-build contract means an agreement that provides for design and construction of improvements by a contractor or private developer. The term encompasses design-build-maintain, design-build-operate, design-build-finance and other contracts that include services in addition to design and construction. Franchise and concession agreements are included in the term if they provide for the franchisee or concessionaire to develop the project which is the subject of the agreement. Design-builder means the entity contractually responsible for delivering the project design and construction. Discussions mean written or oral exchanges that take place after the establishment of the competitive range with the intent of allowing the offerors to revise their proposals. Fixed price/best design means a form of best value selection in which contract price is established by the owner and stated in the Request for Proposals document. Design solutions and other qualitative factors are evaluated and rated, with award going to the firm offering the best qualitative proposal for the established price. Intelligent Transportation System (ITS) services means services which provide for the acquisition of technologies or systems of technologies (e.g., computer hardware or software, traffic control devices, communications link, fare payment system, automatic vehicle location system, etc.) that provide or contribute to the provision of one or more ITS user services as defined in the National ITS Architecture. Modified design-build means a variation of design-build in which the contracting agency furnishes offerors with partially complete plans. The design-builders role is generally limited to the completion of the design and construction of the project. Organizational conflict of interest means that because of other activities or relationships with other persons, a person is unable or potentially unable to render impartial assistance or advice to the owner, or the person's objectivity in performing the contract work is or might be otherwise impaired, or a person has an unfair competitive advantage. Prequalification means the contracting agency's process for determining whether a firm is fundamentally qualified to compete for a certain project or class of projects. The prequalification process may be based on financial, management and other types of qualitative data. Prequalification should be distinguished from short listing. Price proposal means the price submitted by the offeror to provide the required design and construction services. Proposal modification means a change made to a proposal before the solicitation closing date and time, or made in response to an amendment, or made to correct a mistake at any time before award. Proposal revision means a change to a proposal made after the solicitation closing date, at the request of or as allowed by a contracting officer, as the result of negotiations. Qualified project means any design-build project with a total estimated cost greater than $50 million or an intelligent transportation system project greater than $5 million (23 U.S.C. 112 (b)(3)(C)). Request for Proposals (RFP) means the document that describes the procurement process, forms the basis for the final proposals and may potentially become an element in the contract. Request for Qualification (RFQ) means the document issued by the owner in Phase I of the two-phased selection process. It typically describes the project in enough detail to let potential offerors determine if they wish to compete and forms the basis for requesting qualifications submissions from which the most highly qualified offerors can be identified. Short listing means the narrowing of the field of offerors through the selection of the most qualified offerors who have responded to an RFQ. Single-phase selection process means a procurement process where price and/or technical proposals are submitted in response to an RFP. Short listing is not used. Solicitation means a public notification of an owner's need for information, qualifications, or proposals related to identified services. Stipend means a monetary amount sometimes paid to unsuccessful offerors. Technical proposal means that portion of a design-build proposal which contains design solutions and other qualitative factors that are provided in response to the RFP document. Tradeoff means an analysis technique involving a comparison of price and non-price factors to determine the best value when considering the selection of other than the lowest priced proposal. Two-phase selection process means a procurement process in which the first phase consists of short listing (based on qualifications submitted in response to an RFQ) and the second phase consists of the submission of price and technical proposals in response to an RFP. Weakness means a flaw in the proposal that increases the risk of unsuccessful contract performance. A significant weakness in the proposal is a flaw that appreciably increases the risk of unsuccessful contract performance. Weighted criteria process means a form of best value selection in which maximum point values are pre-established for qualitative and price components, and award is based upon high total points earned by the offerors. The provisions of this part apply to all Federal-aid design-build projects within the highway right-of-way or linked to a Federal-aid highway project (i.e., the project would not exist without another Federal-aid highway project). Projects that are not located within the highway right-of-way, and not linked to a Federal-aid highway project may utilize State-approved procedures. No, the FHWA is neither requiring nor promoting the use of the design-build contracting method. The design-build contracting technique is optional. You may use the design-build contracting technique for any qualified or non-qualified project which you deem to be appropriate on the basis of project delivery time, cost, construction schedule and/or quality. (a) No, the use of the term “qualified project” does not limit the use of design-build contracting. It merely determines the FHWA's procedures for approval. The FHWA Division Administrator may approve the design-build method for “qualified projects” which meet the requirements of this part. (b) The FHWA Division Administrator may also approve other design-build projects (which do not meet the “qualified projects” definition) by using Special Experimental Projects No. 14 (SEP–14), “Innovative Contracting Practices,”1 1 Information concerning Special Experimental Project No. 14 (SEP–14), “Innovative Contracting Practices,” is available on FHWA's home page: http://www.fhwa.dot.gov. Additional information may be obtained from the FHWA Division Administrator in each State. For the purpose of this part, a Federal-aid ITS design-build project meets the criteria of a “qualified project” if: (a) A majority of the scope of services provides ITS services (at least 50 percent of the scope of work is related to ITS services); and (b) The estimated contract value exceeds $5 million. In terms of the design-build procurement process: (a) The RFQ solicitation may be released prior to the conclusion of the NEPA review process as long as the RFQ solicitation informs proposers of the general status of the NEPA process. (b) The RFP must not be released prior to the conclusion of the NEPA process. The NEPA review process is concluded with either a Categorical Exclusion classification, an approved Finding of No Significant Impact, or an approved Record of Decision as defined in 23 CFR 771.113(a). (c) The RFP must address how environmental commitments and mitigation measures identified during the NEPA process will be implemented. You may use your own procedures for the solicitation and receipt of proposals and information including the following: (a) Exchanges with industry before receipt of proposals; (b) RFQ, RFP and contract format; (c) Solicitation schedules; (d) Lists of forms, documents, exhibits, and other attachments; (e) Representations and instructions; (f) Advertisement and amendments; (g) Handling proposals and information; and (h) Submission, modification, revisions and withdrawal of proposals. (a) Yes, the use of oral presentations as a substitute for portions of a written proposal can be effective in streamlining the source selection process. Oral presentations may occur at any time in the acquisition process, however, you must comply with the appropriate State procurement integrity standards. (b) Oral presentations may substitute for, or augment, written information. You must maintain a record of oral presentations to document what information you relied upon in making the source selection decision. You may decide the appropriate method and level of detail for the record (e.g., videotaping, audio tape recording, written record, contracting agency notes, copies of offeror briefing slides or presentation notes). A copy of the record should be placed in the contract file and may be provided to offerors upon request. At your discretion, you may elect to pay a stipend to unsuccessful offerors who have submitted responsive proposals. The decision to do so should be based on your analysis of the estimated proposal development costs and the anticipated degree of competition during the procurement process. (a) Yes, stipends are eligible for Federal-aid participation. Stipends are recommended on large projects where there is substantial opportunity for innovation and the cost of submitting a proposal is significant. On such projects, stipends are used to: (1) Encourage competition; (2) Compensate unsuccessful offerors for a portion of their costs (usually one-third to one-half of the estimated proposal development cost); and (3) Ensure that smaller companies are not put at a competitive disadvantage. (b) Unless prohibited by State law, you may retain the right to use ideas from unsuccessful offerors if they accept stipends. If stipends are used, the RFP should describe the process for distributing the stipend to qualifying offerors. (a) You may consider, identify, and allocate the risks in the RFP document and define these risks in the contract. Risk should be allocated with consideration given to the party who is in the best position to manage and control a given risk or the impact of a given risk. (b) Risk allocation will vary according to the type of project and location, however, the following factors should be considered: (1) Governmental risks, including the potential for delays, modifications, withdrawal, scope changes, or additions that result from multi-level Federal, State, and local participation and sponsorship; (2) Regulatory compliance risks, including environmental and third-party issues, such as permitting, railroad, and utility company risks; (3) Construction phase risks, including differing site conditions, traffic control, interim drainage, public access, weather issues, and schedule; (4) Post-construction risks, including public liability and meeting stipulated performance standards; and (5) Right-of-way risks including acquisition costs, appraisals, relocation delays, condemnation proceedings, including court costs and others. (a) Yes, information exchange at an early project stage is encouraged if it facilitates your understanding of the capabilities of potential offerors. However, any exchange of information must be consistent with State procurement integrity requirements. Interested parties include potential offerors, end users, acquisition and supporting personnel, and others involved in the conduct or outcome of the acquisition. (b) The purpose of exchanging information is to improve the understanding of your requirements and industry capabilities, thereby allowing potential offerors to judge whether or how they can satisfy your requirements, and enhancing your ability to obtain quality supplies and services, including construction, at reasonable prices, and increase efficiency in proposal preparation, proposal evaluation, negotiation, and contract award. (c) An early exchange of information can identify and resolve concerns regarding the acquisition strategy, including proposed contract type, terms and conditions, and acquisition planning schedules. This also includes the feasibility of the requirement, including performance requirements, statements of work, and data requirements; the suitability of the proposal instructions and evaluation criteria, including the approach for assessing past performance information; the availability of reference documents; and any other industry concerns or questions. Some techniques to promote early exchanges of information are as follows: (1) Industry or small business conferences; (2) Public hearings; (3) Market research; (4) One-on-one meetings with potential offerors (any meetings that are substantially involved with potential contract terms and conditions should include the contracting officer; also see paragraph (e) of this section regarding restrictions on disclosure of information); (5) Presolicitation notices; (6) Draft RFPs; (7) Request for Information (RFI) ; (8) Presolicitation or preproposal conferences; and (9) Site visits. (d) RFIs may be used when you do not intend to award a contract, but want to obtain price, delivery, other market information, or capabilities for planning purposes. Responses to these notices are not offers and cannot be accepted to form a binding contract. There is no required format for an RFI. (e) When specific information about a proposed acquisition that would be necessary for the preparation of proposals is disclosed to one or more potential offerors, that information shall be made available to all potential offerors as soon as practicable, but no later than the next general release of information, in order to avoid creating an unfair competitive advantage. Information provided to a particular offeror in response to that offeror's request must not be disclosed if doing so would reveal the potential offeror's confidential business strategy. When a presolicitation or preproposal conference is conducted, materials distributed at the conference should be made available to all potential offerors, upon request. (a) State statutes or policies concerning organizational conflict of interest should be specified or referenced in the design-build RFQ or RFP document as well as any contract for engineering services, inspection or technical support in the administration of the design-build contract. All design-build solicitations should address the following situations as appropriate: (1) Consultants and/or sub-consultants who assist the owner in the preparation of a RFP document will not be allowed to participate as an offeror or join a team submitting a proposal in response to the RFP. However, a contracting agency may determine there is not an organizational conflict of interest for a consultant or sub-consultant where: (i) The role of the consultant or sub-consultant was limited to provision of preliminary design, reports, or similar “low-level” documents that will be incorporated into the RFP, and did not include assistance in development of instructions to offerors or evaluation criteria, or (ii) Where all documents and reports delivered to the agency by the consultant or sub-consultant are made available to all offerors. (2) All solicitations for design-build contracts, including related contracts for inspection, administration or auditing services, must include a provision which: (i) Directs offerors attention to this subpart; (ii) States the nature of the potential conflict as seen by the owner; (iii) States the nature of the proposed restraint or restrictions (and duration) upon future contracting activities, if appropriate; (iv) Depending on the nature of the acquisition, states whether or not the terms of any proposed clause and the application of this subpart to the contract are subject to negotiation; and (v) Requires offerors to provide information concerning potential organizational conflicts of interest in their proposals. The apparent successful offerors must disclose all relevant facts concerning any past, present or currently planned interests which may present an organizational conflict of interest. Such firms must state how their interests, or those of their chief executives, directors, key project personnel, or any proposed consultant, contractor or subcontractor may result, or could be viewed as, an organizational conflict of interest. The information may be in the form of a disclosure statement or a certification. (3) Based upon a review of the information submitted, the owner should make a written determination of whether the offeror's interests create an actual or potential organizational conflict of interest and identify any actions that must be taken to avoid, neutralize, or mitigate such conflict. The owner should award the contract to the apparent successful offeror unless an organizational conflict of interest is determined to exist that cannot be avoided, neutralized, or mitigated. (b) The organizational conflict of interest provisions in this subpart provide minimum standards for STDs to identify, mitigate or eliminate apparent or actual organizational conflicts of interest. To the extent that State-developed organizational conflict of interest standards are more stringent than that contained in this subpart, the State standards prevail. State laws and procedures governing improper business practices and personal conflicts of interest will apply to the owner's selection team members. In the absence of such State provisions, the requirements of 48 CFR Part 3, Improper Business Practices and Personal Conflicts of Interest, will apply to selection team members. Where the offeror's qualifications are a major factor in the selection of the successful design-builder, team member switching (adding or switching team members) is discouraged after contract award. However, the owner may use its discretion in reviewing team changes or team enhancement requests on a case-by-case basis. Specific project rules related to changes in team members or changes in personnel within teams should be explicitly stated by the STD in all project solicitations. (a) In order for a project being developed under a public-private agreement to be eligible for Federal-aid funding (including traditional Federal-aid funds, direct loans, loan guarantees, lines of credit, or some other form of credit assistance), the contracting agency must have awarded the contract to the public-private entity through a competitive process that complies with applicable State and local laws. (b) If a contracting agency wishes to utilize traditional Federal-aid funds in a project under a public-private agreement, the applicability of Federal-aid procurement procedures will depend on the nature of the public-private agreement. (1) If the public-private agreement establishes price and an assignment of risk, then all subsequent contracts executed by the developer are considered to be subcontracts and are not subject to Federal-aid procurement requirements. (2) If the public-private agreement does not establish price and an assignment of risk, the developer is considered to be an agent of the owner, and the developer must follow the appropriate Federal-aid procurement requirements (23 CFR part 172 for engineering service contracts, 23 CFR part 635 for construction contracts and the requirements of this part for design-build contracts) for all prime contracts (not subcontracts). (c) The STD must ensure such public-private projects comply with all non-procurement requirements of 23 U. S. Code, regardless of the form of the FHWA funding (traditional Federal-aid funding or credit assistance). This includes compliance with all FHWA policies such as environmental and right-of-way requirements and compliance with such construction contracting requirements as Buy America, Davis-Bacon minimum wage rate requirements, for federally funded construction or design-build contracts under the public-private agreement. You should consider using two-phase selection procedures for all design-build projects. However, if you do not believe two-phase selection procedures are appropriate for your project (based on the criteria in §636.202), you may use a single phase selection procedure or the modified-design-build contracting method. The following procedures are available: You may consider the following criteria in deciding whether two-phase selection procedures are appropriate. A negative response may indicate that two-phase selection procedures are not appropriate. (a) Are three or more offers anticipated? (b) Will offerors be expected to perform substantial design work before developing price proposals? (c) Will offerors incur a substantial expense in preparing proposals? (d) Have you identified and analyzed other contributing factors, including: (1) The extent to which you have defined the project requirements? (2) The time constraints for delivery of the project? (3) The capability and experience of potential contractors? (4) Your capability to manage the two-phase selection process? (5) Other criteria that you may consider appropriate? The first phase consists of short listing based on a RFQ. The second phase consists of the receipt and evaluation of price and technical proposals in response to a RFP. You may consider including the following items in any phase-one solicitation: (a) The scope of work; (b) The phase-one evaluation factors and their relative weights, including: (1) Technical approach (but not detailed design or technical information); (2) Technical qualifications, such as— (i) Specialized experience and technical competence; (ii) Capability to perform (including key personnel); and (iii) Past performance of the members of the offeror's team (including the architect-engineer and construction members); (3) Other appropriate factors (excluding cost or price related factors, which are not permitted in phase-one); (c) Phase-two evaluation factors; and (d) A statement of the maximum number of offerors that will be short listed to submit phase-two proposals. (a) Yes, past performance information is one indicator of an offeror's ability to perform the contract successfully. Past performance information may be used as an evaluation criteria in either phase-one or phase-two solicitations. If you elect to use past performance criteria, the currency and relevance of the information, source of the information, context of the data, and general trends in contractor's performance may be considered. (b) Describe your approach for evaluating past performance in the solicitation, including your policy for evaluating offerors with no relevant performance history. You should provide offerors an opportunity to identify past or current contracts (including Federal, State, and local government and private) for efforts similar to the current solicitation. (c) If you elect to request past performance information, the solicitation should also authorize offerors to provide information on problems encountered on the identified contracts and the offeror's corrective actions. You may consider this information, as well as information obtained from any other sources, when evaluating the offeror's past performance. You may use your discretion in determining the relevance of similar past performance information. (d) The evaluation should take into account past performance information regarding predecessor companies, key personnel who have relevant experience, or subcontractors that will perform major or critical aspects of the requirement when such information is relevant to the current acquisition. In the case of an offeror without a record of relevant past performance or for whom information on past performance is not available, the offeror may not be evaluated favorably or unfavorably on past performance. Normally, three to five firms are short listed, however, the maximum number specified shall not exceed five unless you determine, for that particular solicitation, that a number greater than five is in your interest and is consistent with the purposes and objectives of two-phase design-build contracting. Yes, you may use your existing prequalification procedures for either construction or engineering design firms as a supplement to the procedures in this part. (a) You must include the requirements for technical proposals and price proposals in the phase-two solicitation. All factors and significant subfactors that will affect contract award and their relative importance must be stated clearly in the solicitation. Use your own procedures for the solicitation as long as it complies the requirements of this part. (b) At your discretion, you may allow proposers to submit alternate technical concepts in their proposals as long as these alternate concepts do not conflict with criteria agreed upon in the environmental decision making process. Alternate technical concept proposals may supplement, but not substitute for base proposals that respond to the RFP requirements. (a) Modified design-build selection procedures (lowest price technically acceptable source selection process) may be used for any project. (b) The solicitation must clearly state the following: (1) The identification of evaluation factors and significant subfactors that establish the requirements of acceptability. (2) That award will be made on the basis of the lowest evaluated price of proposals meeting or exceeding the acceptability standards for non-cost factors. (c) The contracting agency may forgo a short listing process and advertise for the receipt of proposals from all responsible offerors. The contract is then awarded to the lowest responsive bidder. (d) Tradeoffs are not permitted, however, you may incorporate cost-plus-time bidding procedures (A+B bidding), lane rental, or other cost-based provisions in such contracts. (e) Proposals are evaluated for acceptability but not ranked using the non-cost/price factors. (f) Exchanges may occur (see subpart D of this part). (a) At your discretion, you may consider the tradeoff technique when it is desirable to award to other than the lowest priced offeror or other than the highest technically rated offeror. (b) If you use a tradeoff technique, the following apply: (1) All evaluation factors and significant subfactors that will affect contract award and their relative importance must be clearly stated in the solicitation; and (2) The solicitation must also state, at a minimum, whether all evaluation factors other than cost or price, when combined, are— (i) Significantly more important than cost or price; or (ii) Approximately equal to cost or price; or (iii) Significantly less important than cost or price. [67 FR 75926, Dec. 10, 2002; 68 FR 7922, Feb. 19, 2003] When tradeoffs are performed, the source selection records must include the following: (a) An assessment of each offeror's ability to accomplish the technical requirements; and (b) A summary, matrix, or quantitative ranking, along with appropriate supporting narrative, of each technical proposal using the evaluation factors. (a) The proposal evaluation factors and significant subfactors should be tailored to the acquisition. (b) Evaluation factors and significant subfactors should: (1) Represent the key areas of importance and emphasis to be considered in the source selection decision; and (2) Support meaningful comparison and discrimination between and among competing proposals. (a) The selection of the evaluation factors, significant subfactors and their relative importance are within your broad discretion subject to the following requirements: (1) You must evaluate price in every source selection where construction is a significant component of the scope of work. (2) You must evaluate the quality of the product or service through consideration of one or more non-price evaluation factors. These factors may include (but are not limited to) such criteria as: (i) Compliance with solicitation requirements; (ii) Completion schedule (contractual incentives and disincentives for early completion may be used where appropriate); or (iii) Technical solutions. (3) At your discretion, you may evaluate past performance, technical experience and management experience (subject to §636.303(b)). (b) All factors and significant subfactors that will affect contract award and their relative importance must be stated clearly in the solicitation. (a) If you use a prequalification procedure or a two-phase selection procedure to develop a short list of qualified offerors, then pre-qualification criteria should not be included as proposal evaluation criteria. (b) The proposal evaluation criteria should be limited to the quality, quantity, value and timeliness of the product or service being proposed. However, there may be circumstances where it is appropriate to include prequalification standards as proposal evaluation criteria. Such instances include situations where: (1) The scope of work involves very specialized technical expertise or specialized financial qualifications; or (2) Where prequalification procedures or two-phase selection procedures are not used (short listing is not performed). (a) Proposal evaluation is an assessment of the offeror's proposal and ability to perform the prospective contract successfully. You must evaluate proposals solely on the factors and subfactors specified in the solicitation. (b) You may conduct evaluations using any rating method or combination of methods including color or adjectival ratings, numerical weights, and ordinal rankings. The relative strengths, deficiencies, significant weaknesses, and risks supporting proposal evaluation must be documented in the contract file. Normally, technical and price proposals are reviewed independently by separate evaluation teams. However, there may be occasions where the same experts needed to review the technical proposals are also needed in the review of the price proposals. This may occur where a limited amount of technical expertise is available to review proposals. Price information may be provided to such technical experts in accordance with your procedures. Verbal or written information exchanges (such as in the first-phase of a two-phase selection procedure) must be consistent with State and/or local procurement integrity requirements. See §636.115(a) for additional details. Certain types of information exchange may be desirable at different points after the release of the RFP document. The following table summarizes the types of communications that will be discussed in this subpart. These communication methods are optional. (a) You may wish to clarify any aspect of proposals which would enhance your understanding of an offeror's proposal. This includes such information as an offeror's past performance or information regarding adverse past performance to which the offeror has not previously had an opportunity to respond. Clarification exchanges are discretionary. They do not have to be held with any specific number of offerors and do not have to address specific issues. (b) You may wish to clarify and revise the RFP document through an addenda process in response to questions from potential offerors. If the solicitation notifies offerors that the competitive range can be limited for purposes of efficiency, you may limit the number of proposals to the greatest number that will permit an efficient competition. However, you must provide written notice to any offeror whose proposal is no longer considered to be included in the competitive range. Offerors excluded or otherwise eliminated from the competitive range may request a debriefing. Debriefings may be conducted in accordance with your procedures as long as you comply with §636.514. Yes, if you have developed a short list of firms, you may still establish a competitive range. The short list is based on qualifications criteria. The competitive range is based on the rating of technical and price proposals. Yes, prior to establishing the competitive range, you may conduct communications to: (a) Enhance your understanding of proposals; (b) Allow reasonable interpretation of the proposal; or (c) Facilitate your evaluation process. Yes, if you establish a competitive range, you must do the following: (a) Hold communications with offerors whose past performance information is the determining factor preventing them from being placed within the competitive range; (b) Address adverse past performance information to which an offeror has not had a prior opportunity to respond; and (c) Hold communications only with those offerors whose exclusion from, or inclusion in, the competitive range is uncertain. (a) No, communications must not be used to: (1) Cure proposal deficiencies or material omissions; (2) Materially alter the technical or cost elements of the proposal; and/or (3) Otherwise revise the proposal. (b) Communications may be considered in rating proposals for the purpose of establishing the competitive range. (a) No, communications shall not provide an opportunity for an offeror to revise its proposal, but may address the following: (1) Ambiguities in the proposal or other concerns (e.g., perceived deficiencies, weaknesses, errors, omissions, or mistakes); and (2) Information relating to relevant past performance. (b) Communications must address adverse past performance information to which the offeror has not previously had an opportunity to comment. In a competitive acquisition, discussions may include bargaining. The term bargaining may include: persuasion, alteration of assumptions and positions, give-and-take, and may apply to price, schedule, technical requirements, type of contract, or other terms of a proposed contract. You should use discussions to maximize your ability to obtain the best value, based on the requirements and the evaluation factors set forth in the solicitation. Yes, in competitive acquisitions, the solicitation must notify offerors of your intent. You should either: (a) Notify offerors that discussions may or may not be held depending on the quality of the proposals received (except clarifications may be used as described in §636.401). Therefore, the offeror's initial proposal should contain the offeror's best terms from a cost or price and technical standpoint; or (b) Notify offerors of your intent to establish a competitive range and hold discussions. Yes, you may still elect to hold discussions when circumstances dictate, as long as the rationale for doing so is documented in the contract file. Such circumstances might include situations where all proposals received have deficiencies, when fair and reasonable prices are not offered, or when the cost or price offered is not affordable. Yes, if discussions are held, they must be conducted with all offerors in the competitive range. If you wish to hold discussions and do not formally establish a competitive range, then you must hold discussions with all responsive offerors. (a) Discussions should be tailored to each offeror's proposal. Discussions must cover significant weaknesses, deficiencies, and other aspects of a proposal (such as cost or price, technical approach, past performance, and terms and conditions) that could be altered or explained to enhance materially the proposal's potential for award. You may use your judgment in setting limits for the scope and extent of discussions. (b) In situations where the solicitation stated that evaluation credit would be given for technical solutions exceeding any mandatory minimums, you may hold discussions regarding increased performance beyond any mandatory minimums, and you may suggest to offerors that have exceeded any mandatory minimums (in ways that are not integral to the design), that their proposals would be more competitive if the excesses were removed and the offered price decreased. You may not engage in conduct that: (a) Favors one offeror over another; (b) Reveals an offeror's technical solution, including unique technology, innovative and unique uses of commercial items, or any information that would compromise an offeror's intellectual property to another offeror; (c) Reveals an offerors price without that offeror's permission; (d) Reveals the names of individuals providing reference information about an offeror's past performance; or (e) Knowingly furnish source selection information which could be in violation of State procurement integrity standards. You may inform an offeror that its price is considered to be too high, or too low, and reveal the results of the analysis supporting that conclusion. At your discretion, you may indicate to all offerors your estimated cost for the project. (a) Yes, you may request or allow proposal revisions to clarify and document understandings reached during discussions. At the conclusion of discussions, each offeror shall be given an opportunity to submit a final proposal revision. (b) You must establish a common cut-off date only for receipt of final proposal revisions. Requests for final proposal revisions shall advise offerors that the final proposal revisions shall be in writing and that the contracting agency intends to make award without obtaining further revisions. Yes, you may further narrow the competitive range if an offeror originally in the competitive range is no longer considered to be among the most highly rated offerors being considered for award. That offeror may be eliminated from the competitive range whether or not all material aspects of the proposal have been discussed, or whether or not the offeror has been afforded an opportunity to submit a proposal revision. You must provide an offeror excluded from the competitive range with a written determination and notice that proposal revisions will not be considered. Yes, but only at the conclusion of discussions will the offerors be requested to submit a final proposal revision, also called best and final offer (BAFO). Thus, regardless of the length or number of discussions, there will be only one request for a revised proposal (i.e., only one BAFO). (a) You must base the source selection decision on a comparative assessment of proposals against all selection criteria in the solicitation. While you may use reports and analyses prepared by others, the source selection decision shall represent your independent judgment. (b) The source selection decision shall be documented, and the documentation shall include the rationale for any business judgments and tradeoffs made or relied on, including benefits associated with additional costs. Although the rationale for the selection decision must be documented, that documentation need not quantify the tradeoffs that led to the decision. Yes, after the source selection but prior to contract execution, you may conduct limited negotiations with the selected design-builder to clarify any remaining issues regarding scope, schedule, financing or any other information provided by that offeror. You must comply with the provisions of §636.507 in the exchange of this information. You may provide pre-award or post-award notifications in accordance with State approved procedures. If an offeror requests a debriefing, you may provide pre-award or post-award debriefings in accordance with State approved procedures.
Title 23: Highways
PART 636—DESIGN-BUILD CONTRACTING
Section Contents
§ 636.101 What does this part do?
§ 636.102 Does this part apply to me?
§ 636.103 What are the definitions of terms used in this part?
§ 636.104 Does this part apply to all Federal-aid design-build projects?
§ 636.105 Is the FHWA requiring the use of design-build?
§ 636.106 What type of projects may be used with design-build contracting?
§ 636.107 Does the definition of a qualified project limit the use of design-build contracting?
§ 636.108 How does the definition of a qualified project apply to ITS projects?
§ 636.109 How does the NEPA review process relate to the design-build procurement process?
§ 636.110 What procedures may be used for solicitations and receipt of proposals?
§ 636.111 Can oral presentations be used during the procurement process?
§ 636.112 May stipends be used?
§ 636.113 Is the stipend amount eligible for Federal participation?
§ 636.114 What factors should be considered in risk allocation?
§ 636.115 May I meet with industry to gather information concerning the appropriate risk allocation strategies?
§ 636.116 What organizational conflict of interest requirements apply to design-build projects?
§ 636.117 What conflict of interest standards apply to individuals who serve as selection team members for the owner?
§ 636.118 Is team switching allowed after contract award?
§ 636.119 How does this part apply to a project developed under a public-private partnership?
§ 636.201 What selection procedures and award criteria may be used?
§ 636.202 When are two-phase design-build selection procedures appropriate?
§ 636.203 What are the elements of two-phase selection procedures for competitive proposals?
§ 636.204 What items may be included in a phase-one solicitation?
§ 636.205 Can past performance be used as an evaluation criteria?
§ 636.206 How do I evaluate offerors who do not have a record of relevant past performance?
§ 636.207 Is there a limit on short listed firms?
§ 636.208 May I use my existing prequalification procedures with design-build contracts?
§ 636.209 What items must be included in a phase-two solicitation?
§ 636.210 What requirements apply to projects which use the modified design-build procedure?
§ 636.211 When and how should tradeoffs be used?
§ 636.212 To what extent must tradeoff decisions be documented?
§ 636.301 How should proposal evaluation factors be selected?
§ 636.302 Are there any limitations on the selection and use of proposal evaluation factors?
§ 636.303 May pre-qualification standards be used as proposal evaluation criteria in the RFP?
§ 636.304 What process may be used to rate and score proposals?
§ 636.305 Can price information be provided to analysts who are reviewing technical proposals?
§ 636.401 What types of information exchange may take place prior to the release of the RFP document?
§ 636.402 What types of information exchange may take place after the release of the RFP document?
§ 636.403 What information may be exchanged with a clarification?
§ 636.404 Can a competitive range be used to limit competition?
§ 636.405 After developing a short list, can I still establish a competitive range?
§ 636.406 Are communications allowed prior to establishing the competitive range?
§ 636.407 Am I limited in holding communications with certain firms?
§ 636.408 Can communications be used to cure proposal deficiencies?
§ 636.409 Can offerors revise their proposals during communications?
§ 636.501 What issues may be addressed in discussions?
§ 636.502 Why should I use discussions?
§ 636.503 Must I notify offerors of my intent to use/not use discussions?
§ 636.504 If the solicitation indicated my intent was to award contract without discussions, but circumstances change, may I still hold discussions?
§ 636.505 Must a contracting agency establish a competitive range if it intends to have discussions with offerors?
§ 636.506 What issues must be covered in discussions?
§ 636.507 What subjects are prohibited in discussions, communications and clarifications with offerors?
§ 636.508 Can price or cost be an issue in discussions?
§ 636.509 Can offerors revise their proposals as a result of discussions?
§ 636.510 Can the competitive range be further defined once discussions have begun?
§ 636.511 Can there be more than one round of discussions?
§ 636.512 What is the basis for the source selection decision?
§ 636.513 Are limited negotiations allowed prior to contract execution?
§ 636.514 How may I provide notifications and debriefings?
Subpart A—General
top
§ 636.101 What does this part do?
top
§ 636.102 Does this part apply to me?
top
§ 636.103 What are the definitions of terms used in this part?
top
§ 636.104 Does this part apply to all Federal-aid design-build projects?
top
§ 636.105 Is the FHWA requiring the use of design-build?
top
§ 636.106 What type of projects may be used with design-build contracting?
top
§ 636.107 Does the definition of a qualified project limit the use of design-build contracting?
top
§ 636.108 How does the definition of a qualified project apply to ITS projects?
top
§ 636.109 How does the NEPA review process relate to the design-build procurement process?
top
§ 636.110 What procedures may be used for solicitations and receipt of proposals?
top
§ 636.111 Can oral presentations be used during the procurement process?
top
§ 636.112 May stipends be used?
top
§ 636.113 Is the stipend amount eligible for Federal participation?
top
§ 636.114 What factors should be considered in risk allocation?
top
§ 636.115 May I meet with industry to gather information concerning the appropriate risk allocation strategies?
top
§ 636.116 What organizational conflict of interest requirements apply to design-build projects?
top
§ 636.117 What conflict of interest standards apply to individuals who serve as selection team members for the owner?
top
§ 636.118 Is team switching allowed after contract award?
top
§ 636.119 How does this part apply to a project developed under a public-private partnership?
top
Subpart B—Selection Procedures, Award Criteria
top
§ 636.201 What selection procedures and award criteria may be used?
top
------------------------------------------------------------------------ Criteria for using Selection procedure a selection Award criteria procedure options------------------------------------------------------------------------(a) Two-Phase Selection § 636.202.... Lowest price, Procedures (RFQ followed by Adjusted low-bid RFP). (price per quality point), meets criteria/ low bid, weighted criteria process, fixed price/best design, best value.(b) Single Phase (RFP).......... Project not All of the award meeting the criteria in item criteria in (a) of this § 636.202. table.(c) Modified Design-Build (may Any project....... Lowest price be one or two phases). technically acceptable.------------------------------------------------------------------------
§ 636.202 When are two-phase design-build selection procedures appropriate?
top
§ 636.203 What are the elements of two-phase selection procedures for competitive proposals?
top
§ 636.204 What items may be included in a phase-one solicitation?
top
§ 636.205 Can past performance be used as an evaluation criteria?
top
§ 636.206 How do I evaluate offerors who do not have a record of relevant past performance?
top
§ 636.207 Is there a limit on short listed firms?
top
§ 636.208 May I use my existing prequalification procedures with design-build contracts?
top
§ 636.209 What items must be included in a phase-two solicitation?
top
§ 636.210 What requirements apply to projects which use the modified design-build procedure?
top
§ 636.211 When and how should tradeoffs be used?
top
§ 636.212 To what extent must tradeoff decisions be documented?
top
Subpart C—Proposal Evaluation Factors
top
§ 636.301 How should proposal evaluation factors be selected?
top
§ 636.302 Are there any limitations on the selection and use of proposal evaluation factors?
top
§ 636.303 May pre-qualification standards be used as proposal evaluation criteria in the RFP?
top
§ 636.304 What process may be used to rate and score proposals?
top
§ 636.305 Can price information be provided to analysts who are reviewing technical proposals?
top
Subpart D—Exchanges
top
§ 636.401 What types of information exchange may take place prior to the release of the RFP document?
top
§ 636.402 What types of information exchange may take place after the release of the RFP document?
top
---------------------------------------------------------------------------------------------------------------- Type of information exchange When Purpose Parties involved----------------------------------------------------------------------------------------------------------------(a) Clarifications................... After receipt of Used when award without Any offeror whose proposals. discussions is proposal is not clear contemplated. Used to to the contracting clarify certain agency. aspects of a proposal (resolve minor errors, clerical errors, obtain additional past performance information, etc.).(b) Communications................... After receipt of Used to address issues Only those offerors proposals, prior to which might prevent a whose exclusion from, the establishment of proposal from being or inclusion in, the the competitive range. placed in the competitive range is competitive range. uncertain. All offerors whose past performance information is the determining factor preventing them from being placed in the competitive range.(c) Discussions (see Subpart E of After receipt of Enhance contracting Must be held with all this part). proposals and after agency understanding offerors in the the determination of of proposals and competitive range. the competitive range. offerors understanding of scope of work. Facilitate the evaluation process.----------------------------------------------------------------------------------------------------------------
§ 636.403 What information may be exchanged with a clarification?
top
§ 636.404 Can a competitive range be used to limit competition?
top
§ 636.405 After developing a short list, can I still establish a competitive range?
top
§ 636.406 Are communications allowed prior to establishing the competitive range?
top
§ 636.407 Am I limited in holding communications with certain firms?
top
§ 636.408 Can communications be used to cure proposal deficiencies?
top
§ 636.409 Can offerors revise their proposals during communications?
top
Subpart E—Discussions, Proposal Revisions and Source Selection
top
§ 636.501 What issues may be addressed in discussions?
top
§ 636.502 Why should I use discussions?
top
§ 636.503 Must I notify offerors of my intent to use/not use discussions?
top
§ 636.504 If the solicitation indicated my intent was to award contract without discussions, but circumstances change, may I still hold discussions?
top
§ 636.505 Must a contracting agency establish a competitive range if it intends to have discussions with offerors?
top
§ 636.506 What issues must be covered in discussions?
top
§ 636.507 What subjects are prohibited in discussions, communications and clarifications with offerors?
top
§ 636.508 Can price or cost be an issue in discussions?
top
§ 636.509 Can offerors revise their proposals as a result of discussions?
top
§ 636.510 Can the competitive range be further defined once discussions have begun?
top
§ 636.511 Can there be more than one round of discussions?
top
§ 636.512 What is the basis for the source selection decision?
top
§ 636.513 Are limited negotiations allowed prior to contract execution?
top
§ 636.514 How may I provide notifications and debriefings?
top
