25 C.F.R. PART 900—CONTRACTS UNDER THE INDIAN SELF-DETERMINATION AND EDUCATION ASSISTANCE ACT
Title 25 - Indians
Authority: 25 U.S.C. 450f et seq.
Source: 61 FR 32501, June 24, 1996, unless otherwise noted.
Editorial Note: Nomenclature changes to part 900 appear at 67 FR 34602, May 15, 2002.
These regulations are prepared, issued, and maintained jointly by the Secretary of Health and Human Services and the Secretary of the Interior, with the active participation and representation of Indian tribes, tribal organizations, and individual tribal members pursuant to the guidance of the Negotiated Rulemaking procedures required by section 107 of the Indian Self-Determination and Education Assistance Act. (a) General. These regulations codify uniform and consistent rules for contracts by the Department of Health and Human Services (DHHS) and the Department of the Interior (DOI) in implementing title I of the Indian Self-Determination and Education Assistance Act, Public Law 93–638, 25 U.S.C. 450 et seq., as amended and sections 1 through 9 preceding that title. (b) Programs funded by other Departments and agencies. Included under this part are programs administered (under current or future law or interagency agreement) by the DHHS and the DOI for the benefit of Indians for which appropriations are made to other Federal agencies. (c) This part included in contracts by reference. Each contract, including grants and cooperative agreements in lieu of contracts awarded under section 9 of the Act, shall include by reference the provisions of this part, and any amendment thereto, and they are binding on the Secretary and the contractor except as otherwise specifically authorized by a waiver under section 107(e) of the Act. (d) Freedom of Information. Access to records maintained by the Secretary is governed by the Freedom of Information Act (5 U.S.C. 552) and other applicable Federal law. Except for previously provided copies of tribal records that the Secretary demonstrates are clearly required to be maintained as part of the record keeping systems of the DHHS or the DOI, or both, records of the contractors (including archived records) shall not be considered Federal records for the purpose of the Freedom of Information Act. The Freedom of Information Act does not apply to records maintained solely by Indian tribes and tribal organizations. (e) Privacy Act. Section 108(b) of the Indian Self-Determination Act states that records of the tribal government or tribal organizations shall not be considered Federal records for the purposes of the Privacy Act. (f) Information collection. The Office of Management and Budget has approved, under 44 U.S.C. chapter 35, the information collection requirements in part 900 under assigned control number 1076–0136. The information for part 900 is being collected and used by the Departments to determine applicant eligibility, evaluate applicant capabilities, protect the service population, safeguard Federal funds and other resources, and permit the Departments to administer and evaluate contract programs. (a) Congressional policy. (1) Congress has recognized the obligation of the United States to respond to the strong expression of the Indian people for self-determination by assuring maximum Indian participation in the direction, planning, conduct and administration of educational as well as other Federal programs and services to Indian communities so as to render such programs and services more responsive to the needs and desires of those communities. (2) Congress has declared its commitment to the maintenance of the Federal Government's unique and continuing relationship with, and responsibility to, individual Indian tribes and to the Indian people as a whole through the establishment of a meaningful Indian self-determination policy which will permit an orderly transition from the Federal domination of programs for, and services to, Indians to effective and meaningful participation by the Indian people in the planning, conduct, and administration of those programs and services. In accordance with this policy, the United States is committed to supporting and assisting Indian tribes in the development of strong and stable tribal governments, capable of administering quality programs and developing the economies of their respective communities. (3) Congress has declared that a major national goal of the United States is to provide the quantity and quality of educational services and opportunities which will permit Indian children to compete and excel in the life areas of their choice, and to achieve the measure of self-determination essential to their social and economic well-being. (4) Congress has declared that the programs, functions, services, or activities that are contracted and funded under this Act shall include administrative functions of the Department of the Interior and the Department of Health and Human Services (whichever is applicable) that support the delivery of services to Indians, including those administrative activities supportive of, but not included as part of, the service delivery programs described in this paragraph that are otherwise contractible. The administrative functions referred to in the preceding sentence shall be contractible without regard to the organizational level within the Department that carries out such functions. Contracting of the administrative functions described herein shall not be construed to limit or reduce in any way the funding for any program, function, service, or activity serving any other tribe under the Act or any other law. The Secretary is not required to reduce funding for programs, projects, or activities serving a tribe to make funds available to another Indian tribe or tribal organization under this Act. (5) Congress has further declared that each provision of the Act and each provision of contracts entered into thereunder shall be liberally construed for the benefit of the tribes or tribal organizations to transfer the funding and the related functions, services, activities, and programs (or portions thereof), that are otherwise contractible under the Act, including all related administrative functions, from the Federal government to the contractor. (6) Congress has declared that one of the primary goals of the 1994 amendments to the Act was to minimize the reporting requirements applicable to tribal contractors and to eliminate excessive and burdensome reporting requirements. Reporting requirements over and above the annual audit report are to be negotiated with disagreements subject to the declination procedures of section 102 of the Act. (7) Congress has declared that there not be any threshold issues which would avoid the declination, contract review, approval, and appeal process. (8) Congress has declared that all self-determination contract proposals must be supported by the resolution of an Indian tribe(s). (9) Congress has declared that to the extent that programs, functions, services, and activities carried out by tribes and tribal organizations pursuant to contracts entered into under this Act reduce the administrative or other responsibilities of the Secretary with respect to the operation of Indian programs and result in savings that have not otherwise been included in the amount of contract funds determined under section 106(a) of the Act, the Secretary shall make such savings available for the provision of additional services to program beneficiaries, either directly or through contractors, in a manner equitable to both direct and contracted programs. (b) Secretarial policy. (1) It is the policy of the Secretary to facilitate the efforts of Indian tribes and tribal organizations to plan, conduct and administer programs, functions, services and activities, or portions thereof, which the Departments are authorized to administer for the benefit of Indians because of their status as Indians. The Secretary shall make best efforts to remove any obstacles which might hinder Indian tribes and tribal organizations including obstacles that hinder tribal autonomy and flexibility in the administration of such programs. (2) It is the policy of the Secretary to encourage Indian tribes and tribal organizations to become increasingly knowledgeable about the Departments' programs administered for the benefit of Indians by providing information on such programs, functions and activities and the opportunities Indian tribes have regarding them. (3) It is the policy of the Secretary to provide a uniform and consistent set of rules for contracts under the Act. The rules contained herein are designed to facilitate and encourage Indian tribes to participate in the planning, conduct, and administration of those Federal programs serving Indian people. The Secretary shall afford Indian tribes and tribal organizations the flexibility, information, and discretion necessary to design contractible programs to meet the needs of their communities consistent with their diverse demographic, geographic, economic, cultural, health, social, religious and institutional needs. (4) The Secretary recognizes that contracting under the Act is an exercise by Indian tribes of the government-to-government relationship between the United States and the Indian tribes. When an Indian tribe contracts, there is a transfer of the responsibility with the associated funding. The tribal contractor is accountable for managing the day-to-day operations of the contracted Federal programs, functions, services, and activities. The contracting tribe thereby accepts the responsibility and accountability to the beneficiaries under the contract with respect to use of the funds and the satisfactory performance of the programs, functions, services and activities funded under the contract. The Secretary will continue to discharge the trust responsibilities to protect and conserve the trust resources of Indian tribes and the trust resources of individual Indians. (5) The Secretary recognizes that tribal decisions to contract or not to contract are equal expressions of self-determination. (6) The Secretary shall maintain consultation with tribal governments and tribal organizations in the Secretary's budget process relating to programs, functions, services and activities subject to the Act. In addition, on an annual basis, the Secretary shall consult with, and solicit the participation of, Indian tribes and tribal organizations in the development of the budget for the Indian Health Service and the Bureau of Indian Affairs (including participation of Indian tribes and tribal organizations in formulating annual budget requests that the Secretary submits to the President for submission to Congress pursuant to section 1105 of title 31, United States Code). (7) The Secretary is committed to implementing and fully supporting the policy of Indian self-determination by recognizing and supporting the many positive and successful efforts and directions of tribal governments and extending the applicability of this policy to all operational components within the Department. By fully extending Indian self-determination contracting to all operational components within the Department having programs or portions of programs for the benefit of Indians under section 102(a)(1) (A) through (D) and for the benefit of Indians because of their status as Indians under section 102(a)(1)(E), it is the Secretary's intent to support and assist Indian tribes in the development of strong and stable tribal governments capable of administering quality programs that meet the tribally determined needs and directions of their respective communities. It is also the policy of the Secretary to have all other operational components within the Department work cooperatively with tribal governments on a government-to-government basis so as to expedite the transition away from Federal domination of Indian programs and make the ideals of Indian self-government and self-determination a reality. (8) It is the policy of the Secretary that the contractibility of programs under this Act should be encouraged. In this regard, Federal laws and regulations should be interpreted in a manner that will facilitate the inclusion of those programs or portions of those programs that are for the benefit of Indians under section 102(a)(1) (A) through (D) of the Act, and that are for the benefit of Indians because of their status of Indians under section 102(a)(1)(E) of the Act. (9) It is the Secretary's policy that no later than upon receipt of a contract proposal under the Act (or written notice of an Indian tribe or tribal organization's intention to contract), the Secretary shall commence planning such administrative actions, including but not limited to transfers or reductions in force, transfers of property, and transfers of contractible functions, as may be necessary to ensure a timely transfer of responsibilities and funding to Indian tribes and tribal organizations. (10) It is the policy of the Secretary to make available to Indian tribes and tribal organizations all administrative functions that may lawfully be contracted under the Act, employing methodologies consistent with the methodology employed with respect to such functions under titles III and IV of the Act. (11) The Secretary's commitment to Indian self-determination requires that these regulations be liberally construed for the benefit of Indian tribes and tribal organizations to effectuate the strong Federal policy of self-determination and, further, that any ambiguities herein be construed in favor of the Indian tribe or tribal organization so as to facilitate and enable the transfer of services, programs, functions, and activities, or portions thereof, authorized by the Act. Nothing in these regulations shall be construed as: (a) Affecting, modifying, diminishing, or otherwise impairing the sovereign immunity from suit enjoyed by Indian tribes; (b) Terminating, waiving, modifying, or reducing the trust responsibility of the United States to the Indian tribe(s) or individual Indians. The Secretary shall act in good faith in upholding this trust responsibility; (c) Mandating an Indian tribe to apply for a contract(s) or grant(s) as described in the Act; or (d) Impeding awards by other Departments and agencies of the United States to Indian tribes to administer Indian programs under any other applicable law. Except as specifically provided in the Act, or as specified in subpart J, an Indian tribe or tribal organization is not required to abide by any unpublished requirements such as program guidelines, manuals, or policy directives of the Secretary, unless otherwise agreed to by the Indian tribe or tribal organization and the Secretary, or otherwise required by law. Unless otherwise provided in this part: Act means secs. 1 through 9, and title I of the Indian Self-Determination and Education Assistance Act of 1975, Public Law 93–638, as amended. Annual funding agreement means a document that represents the negotiated agreement of the Secretary to fund, on an annual basis, the programs, services, activities and functions transferred to an Indian tribe or tribal organization under the Act. Appeal means a request by an Indian tribe or tribal organization for an administrative review of an adverse Agency decision. Awarding official means any person who by appointment or delegation in accordance with applicable regulations has the authority to enter into and administer contracts on behalf of the United States of America and make determinations and findings with respect thereto. Pursuant to the Act, this person can be any Federal official, including but not limited to, contracting officers. BIA means the Bureau of Indian Affairs of the Department of the Interior. Contract means a self-determination contract as defined in section 4(j) of the Act. Contract appeals board means the Interior Board of Contract Appeals. Contractor means an Indian tribe or tribal organization to which a contract has been awarded. Days means calendar days; except where the last day of any time period specified in these regulations falls on a Saturday, Sunday, or a Federal holiday, the period shall carry over to the next business day unless otherwise prohibited by law. Department(s) means the Department of Health and Human Services (HHS) or the Department of the Interior (DOI), or both. IHS means the Indian Health Service of the Department of Health and Human Services. Indian means a person who is a member of an Indian Tribe. Indian tribe means any Indian tribe, band, nation, or other organized group, or community, including pueblos, rancherias, colonies and any Alaska Native Village, or regional or village corporation as defined in or established pursuant to the Alaska Native Claims Settlement Act, which is recognized as eligible for the special programs and services provided by the United States to Indians because of their status as Indians. Indirect cost rate means the rate(s) arrived at through negotiation between an Indian tribe or tribal organization and the appropriate Federal Agency. Indirect costs means costs incurred for a common or joint purpose benefiting more than one contract objective or which are not readily assignable to the contract objectives specifically benefitted without effort disproportionate to the results achieved. Initial contract proposal means a proposal for programs, functions, services, or activities that the Secretary is authorized to perform but which the Indian tribe or tribal organization is not now carrying out. Real property means any interest in land together with the improvements, structures, and fixtures and appurtenances thereto. Reassumption means rescission, in whole or in part, of a contract and assuming or resuming control or operation of the contracted program by the Secretary without consent of the Indian tribe or tribal organization pursuant to the notice and other procedures set forth in subpart P. Retrocession means the voluntary return to the Secretary of a contracted program, in whole or in part, for any reason, before the expiration of the term of the contract. Secretary means the Secretary of Health and Human Services (HHS) or the Secretary of the Interior (DOI), or both (and their respective delegates). Tribal organization means the recognized governing body of any Indian tribe; any legally established organization of Indians which is controlled, sanctioned, or chartered by such governing body or which is democratically elected by the adult members of the Indian community to be served by such organization and which includes the maximum participation of Indians in all phases of its activities: provided, that, in any case where a contract is let or a grant made to an organization to perform services benefiting more than one Indian tribe, the approval of each such Indian tribe shall be a prerequisite to the letting or making of such contract or grant. Trust resources means an interest in land, water, minerals, funds, or other assets or property which is held by the United States in trust for an Indian tribe or an individual Indian or which is held by an Indian tribe or Indian subject to a restriction on alienation imposed by the United States. The Secretary shall, upon request of an Indian tribe or tribal organization and subject to the availability of appropriations, provide technical assistance on a non-reimbursable basis to such Indian tribe or tribal organization to develop a new contract proposal or to provide for the assumption by the Indian tribe or tribal organization of any program, service, function, or activity (or portion thereof) that is contractible under the Act. The Secretary may also make a grant to an Indian tribe or tribal organization for the purpose of obtaining technical assistance, as provided in section 103 of the Act. An Indian tribe or tribal organization may also request reimbursement for pre-award costs for obtaining technical assistance under sections 106(a) (2) and (5) of the Act. An initial contract proposal must contain the following information: (a) The full name, address and telephone number of the Indian tribe or tribal organization proposing the contract. (b) If the tribal organization is not an Indian tribe, the proposal must also include: (1) A copy of the tribal organization's organizational documents (e.g., charter, articles of incorporation, bylaws, etc.). (2) The full name(s) of the Indian tribe(s) with which the tribal organization is affiliated. (c) The full name(s) of the Indian tribe(s) proposed to be served. (d) A copy of the authorizing resolution from the Indian tribe(s) to be served. (1) If an Indian tribe or tribal organization proposes to serve a specified geographic area, it must provide authorizing resolution(s) from all Indian tribes located within the specific area it proposes to serve. However, no resolution is required from an Indian tribe located outside the area proposed to be served whose members reside within the proposed service area. (2) If a currently effective authorizing resolution covering the scope of an initial contract proposal has already been provided to the agency receiving the proposal, a reference to that resolution. (e) The name, title, and signature of the authorized representative of the Indian tribe or tribal organization submitting the contract proposal. (f) The date of submission of the proposal. (g) A brief statement of the programs, functions, services, or activities that the tribal organization proposes to perform, including: (1) A description of the geographical service area, if applicable, to be served. (2) The estimated number of Indian people who will receive the benefits or services under the proposed contract. (3) An identification of any local, Area, regional, or national level departmental programs, functions, services, or activities to be contracted, including administrative functions. (4) A description of the proposed program standards; (5) An identification of the program reports, data and financial reports that the Indian tribe or tribal organization will provide, including their frequency. (6) A description of any proposed redesign of the programs, services, functions, or activities to be contracted, (7) Minimum staff qualifications proposed by the Indian tribe and tribal organization, if any; and (8) A statement that the Indian tribe or tribal organization will meet the minimum procurement, property and financial management standards set forth in subpart F, subject to any waiver that may have been granted under subpart K. (h) The amount of funds requested, including: (1) An identification of the funds requested by programs, functions, services, or activities, under section 106(a)(1) of the Act, including the Indian tribe or tribal organization's share of funds related to such programs, functions, services, or activities, if any, from any Departmental local, area, regional, or national level. (2) An identification of the amount of direct contract support costs, including one-time start-up or preaward costs under section 106(a)(2) and related provisions of the Act, presented by major categories such as: (i) Personnel (differentiating between salary and fringe benefits); (ii) Equipment; (iii) Materials and supplies; (iv) Travel; (v) Subcontracts; and (vi) Other appropriate items of cost. (3) An identification of funds the Indian tribe or tribal organization requests to recover for indirect contract support costs. This funding request must include either: (i) A copy of the most recent negotiated indirect cost rate agreement; or (ii) An estimated amount requested for indirect costs, pending timely establishment of a rate or negotiation of administrative overhead costs. (4) To the extent not stated elsewhere in the budget or previously reported to the Secretary, any preaward costs, including the amount and time period covered or to be covered; and (5) At the option of the Indian tribe or tribal organization, an identification of programs, functions, services, or activities specified in the contract proposal which will be funded from sources other than the Secretary. (i) The proposed starting date and term of the contract. (j) In the case of a cooperative agreement, the nature and degree of Federal programmatic involvement anticipated during the term of the agreement. (k) The extent of any planned use of Federal personnel and Federal resources. (l) Any proposed waiver(s) of the regulations in this part; and (m) A statement that the Indian tribe or tribal organization will implement procedures appropriate to the programs, functions, services or activities proposed to be contracted, assuring the confidentiality of medical records and of information relating to the financial affairs of individual Indians obtained under the proposal contract, or as otherwise required by law. No. The Indian tribe or tribal organization submits a written request to the Secretary. The Secretary shall provide the requested information, including the condition of the property, within 60 days. The Indian tribe or tribal organization is encouraged to provide the Secretary, as early as possible, with: (a) A list of the following Federal property intended for use under the contract: (1) Equipment; (2) Furnishings; (3) Facilities; and (4) Other real and personal property. (b) A statement of how the Indian tribe or tribal organization will obtain each item by transfer of title under section 105(f)(2) of the Act and section 1(b)(8) of the model agreement set forth in section 108(c) of the Act, through a temporary use permit, similar arrangement, or otherwise; and (c) Where equipment is to be shared by contracted and non-contracted programs, services, functions, or activities, a proposal outlining proposed equipment sharing or other arrangements. No. In these situations, an Indian tribe or tribal organization should submit a renewal proposal (or notification of intent not to renew) or an annual funding agreement proposal at least 90 days before the expiration date of the contract or existing annual funding agreement. The proposal shall provide funding information in the same detail and format as the original proposal and may also identify any significant proposed changes. No, unless the parties agree. This subpart covers any proposal to enter into a self-determination contract, to amend an existing self-determination contract, to renew an existing self-determination contract, or to redesign a program through a self-determination contract. Upon receipt of a proposal, the Secretary shall: (a) Within two days notify the applicant in writing that the proposal has been received; (b) Within 15 days notify the applicant in writing of any missing items required by §900.8 and request that the items be submitted within 15 days of receipt of the notification; and (c) Review the proposal to determine whether there are declination issues under section 102(a)(2) of the Act. The Secretary has 90 days after receipt of a proposal to review and approve the proposal and award the contract or decline the proposal in compliance with section 102 of the Act and subpart E. At any time during the review period the Secretary may approve the proposal and award the requested contract. Yes, with written consent of the Indian tribe or tribal organization. If consent is not given, the 90-day deadline applies. A proposal that is not declined within 90 days (or within any agreed extension under §900.17) is deemed approved and the Secretary shall award the contract or any amendment or renewal within that 90-day period and add to the contract the full amount of funds pursuant to section 106(a) of the Act. Upon approval the Secretary shall award the contract and add to the contract the full amount of funds to which the contractor is entitled under section 106(a) of the Act. This subpart explains how and under what circumstances the Secretary may decline a proposal to contract, to amend an existing contract, to renew an existing contract, to redesign a program, or to waive any provisions of these regulations. For annual funding agreements, see §900.32. As explained in §§900.16 and 900.17, a proposal can only be declined within 90 days after the Secretary receives the proposal, unless that period is extended with the voluntary and express written consent of the Indian tribe or tribal organization. The Secretary may only decline to approve a proposal for one of five specific reasons: (a) The service to be rendered to the Indian beneficiaries of the particular program or function to be contracted will not be satisfactory; (b) Adequate protection of trust resources is not assured; (c) The proposed project or function to be contracted for cannot be properly completed or maintained by the proposed contract; (d) The amount of funds proposed under the contract is in excess of the applicable funding level for the contract, as determined under section 106(a) of the Act; or (e) The program, function, service, or activity (or a portion thereof) that is the subject of the proposal is beyond the scope of programs, functions, services, or activities covered under section 102(a)(1) of the Act because the proposal includes activities that cannot lawfully be carried out by the contractor. No. The Secretary may not decline to enter into a contract with an Indian tribe or tribal organization based on any objection that will be overcome through the contract. No. The Secretary may only decline a proposal based upon one or more of the five reasons listed above. If a contract affects the preexisting level of services to any other tribe, the Secretary shall address that effect in the Secretary's annual report to Congress under section 106(c)(6) of the Act. The Secretary must approve any severable portion of a proposal that does not support a declination finding described in §900.20, subject to any alteration in the scope of the proposal that the Secretary and the Indian tribe or tribal organization approve. In those situations the Secretary is required, as appropriate, to approve the portion of the program, function, service, or activity that is authorized under section 102(a) of the Act, or approve a level of funding that is authorized under section 106(a) of the Act. As noted in §900.25, the approval is subject to any alteration in the scope of the proposal that the Secretary and the Indian tribe or tribal organization approve. No, but the hearing and appeal procedures contained in these regulations only apply to the portion of the proposal that was declined. Yes. In accordance with section 103(d) of the Act, upon receiving a proposal, the Secretary shall provide any necessary requested technical assistance to an Indian tribe or tribal organization, and shall share all relevant information with the Indian tribe or tribal organization, in order to avoid declination of the proposal. If the Secretary decides to decline all or a severable portion of a proposal, the Secretary is required: (a) To advise the Indian tribe or tribal organization in writing of the Secretary's objections, including a specific finding that clearly demonstrates that (or that is supported by a controlling legal authority that) one of the conditions set forth in §900.22 exists, together with a detailed explanation of the reason for the decision to decline the proposal and, within 20 days, any documents relied on in making the decision; and (b) To advise the Indian tribe or tribal organization in writing of the rights described in §900.31. Yes. The Secretary shall provide additional technical assistance to overcome the stated objections, in accordance with section 102(b) of the Act, and shall provide any necessary requested technical assistance to develop any modifications to overcome the Secretary's stated objections. Yes. The Indian tribe or tribal organization is entitled to an appeal on the objections raised by the Secretary, with an agency hearing on the record, and the right to engage in full discovery relevant to any issue raised in the matter. The procedures for appeals are in subpart L of these regulations. Alternatively, at its option the Indian tribe or tribal organization has the right to sue in Federal district court to challenge the Secretary's decision. No. If it is substantially the same as the prior annual funding agreement (except for funding increases included in appropriations acts or funding reductions as provided in section 106(b) of the Act) and the contract is with DHHS or the BIA, the Secretary shall approve and add to the contract the full amount of funds to which the contractor is entitled, and may not decline, any portion of a successor annual funding agreement. Any portion of an annual funding agreement proposal which is not substantially the same as that which was funded previously (e.g., a redesign proposal; waiver proposal; different proposed funding amount; or different program, service, function, or activity), or any annual funding agreement proposal which pertains to a contract with an agency of DOI other than the BIA, is subject to the declination criteria and procedures in subpart E. If there is a disagreement over the availability of appropriations, the Secretary may decline the proposal in part under the procedure in subpart E. Department of Health and Human Services and the Bureau of Indian Affairs will not review the renewal of a term contract for declination issues where no material and substantial change to the scope or funding of a program, functions, services, or activities has been proposed by the Indian tribe or tribal organization. Proposals to renew term contracts with DOI agencies other than the Bureau of Indian Affairs may be reviewed under the declination criteria. This subpart contains the minimum standards for the management systems used by Indian tribes or tribal organizations when carrying out self-determination contracts. It provides standards for an Indian tribe or tribal organization's financial management system, procurement management system, and property management system. When carrying out self-determination contracts, Indian tribes and tribal organizations shall develop, implement, and maintain systems that meet these minimum standards, unless one or more of the standards have been waived, in whole or in part, under section 107(e) of the Act and subpart K. The only provisions of OMB Circulars and the only provisions of the “common rule” that apply to self-determination contracts are the provisions adopted in these regulations, those expressly required or modified by the Act, and those negotiated and agreed to in a self-determination contract. An Indian tribe or tribal organization may require that some or all of the standards in this subpart be imposed upon its subcontractors when carrying out a self-determination contract. (a) Standards are the minimum baseline requirements for the performance of an activity. Standards establish the “what” that an activity should accomplish. (b) Systems are the procedural mechanisms and processes for the day-to-day conduct of an activity. Systems are “how” the activity will be accomplished. (a) Management standards are evaluated by the Secretary when the Indian tribe or tribal organization submits an initial contract proposal. (b) Management systems are evaluated by an independent auditor through the annual single agency audit report that is required by the Act and OMB Circular A–128. The Indian tribe or tribal organization must retain financial, procurement and property records for the minimum periods described below. Electronic, magnetic or photographic records may be substituted for hard copies. (a) Financial records. Financial records include documentation of supporting costs incurred under the contract. These records must be retained for three years from the date of submission of the single audit report to the Secretary. (b) Procurement records. Procurement records include solicitations, purchase orders, contracts, payment histories and records applicable of significant decisions. These records must be retained for three years after the Indian tribe or tribal organization or subcontractors make final payment and all other pending matters are closed. (c) Property management records. Property management records of real and personal property transactions must be retained for three years from the date of disposition, replacement, or transfer. (d) Litigation, audit exceptions and claims. Records pertaining to any litigation, audit exceptions or claims requiring management systems data must be retained until the action has been completed. An Indian tribe shall expend and account for contract funds in accordance with all applicable tribal laws, regulations, and procedures. A tribal organization shall expend and account for contract funds in accordance with the procedures of the tribal organization. The fiscal control and accounting procedures of an Indian tribe or tribal organization shall be sufficient to: (a) Permit preparation of reports required by a self-determination contract and the Act; and (b) Permit the tracing of contract funds to a level of expenditure adequate to establish that they have not been used in violation of any restrictions or prohibitions contained in any statute that applies to the self-determination contract. An Indian tribe or tribal organization's financial management system shall include provisions for the following seven elements. (a) Financial reports. The financial management system shall provide for accurate, current, and complete disclosure of the financial results of self-determination contract activities. This includes providing the Secretary a completed Financial Status Report, SF 269A, as negotiated and agreed to in the self-determination contract. (b) Accounting records. The financial management system shall maintain records sufficiently detailed to identify the source and application of self-determination contract funds received by the Indian tribe or tribal organization. The system shall contain sufficient information to identify contract awards, obligations and unobligated balances, assets, liabilities, outlays, or expenditures and income. (c) Internal controls. The financial management system shall maintain effective control and accountability for all self-determination contract funds received and for all Federal real property, personal property, and other assets furnished for use by the Indian tribe or tribal organization under the self-determination contract. (d) Budget controls. The financial management system shall permit the comparison of actual expenditures or outlays with the amounts budgeted by the Indian tribe or tribal organization for each self-determination contract. (e) Allowable costs. The financial management system shall be sufficient to determine the reasonableness, allowability, and allocability of self-determination contract costs based upon the terms of the self-determination contract and the Indian tribe or tribal organization's applicable OMB cost principles, as amended by the Act and these regulations. (The following chart lists certain OMB Circulars and suggests the entities that may use each, but the final selection of the applicable circular may differ from those shown, as agreed to by the Indian tribe or tribal organization and the Secretary. Agreements between an Indian tribe or tribal organization and the Secretary currently in place do not require renegotiation.) Copies of these circulars are available from the Executive Office of the President, Publications Service, 725 17th Street N. W., Washington, D. C. 20503. (f) Source documentation. The financial management system shall contain accounting records that are supported by source documentation, e.g., canceled checks, paid bills, payroll records, time and attendance records, contract award documents, purchase orders, and other primary records that support self-determination contract fund expenditures. (g) Cash management. The financial management system shall provide for accurate, current, and complete disclosure of cash revenues disbursements, cash-on-hand balances, and obligations by source and application for each Indian tribe or tribal organization, and subcontractor if applicable, so that complete and accurate cash transactions may be prepared as required by the self-determination contract. The Secretary shall establish procedures, consistent with Treasury regulations as modified by the Act, for the transfer of funds from the United States to the Indian tribe or tribal organization in strict compliance with the self-determination contract and the annual funding agreement. Indian tribes and tribal organizations shall have standards that conform to the standards in this subpart. If the Indian tribe or tribal organization relies upon standards different than those described below, it shall identify the standards it will use as a proposed waiver in the initial contract proposal or as a waiver request to an existing contract. (a) The Indian tribe or tribal organization shall ensure that its vendors and/or subcontractors perform in accordance with the terms, conditions, and specifications of their contracts or purchase orders. (b) The Indian tribe or tribal organization shall maintain written standards of conduct governing the performance of its employees who award and administer contracts. (1) No employee, officer, elected official, or agent of the Indian tribe or tribal organization shall participate in the selection, award, or administration of a procurement supported by Federal funds if a conflict of interest, real or apparent, would be involved. (2) An employee, officer, elected official, or agent of an Indian tribe or tribal organization, or of a subcontractor of the Indian tribe or tribal organization, is not allowed to solicit or accept gratuities, favors, or anything of monetary value from contractors, potential contractors, or parties to sub-agreements, with the following exemptions. The Indian tribe or tribal organization may exempt a financial interest that is not substantial or a gift that is an unsolicited item of nominal value. (3) These standards shall also provide for penalties, sanctions, or other disciplinary actions for violations of the standards. (c) The Indian tribe or tribal organization shall review proposed procurements to avoid buying unnecessary or duplicative items and ensure the reasonableness of the price. The Indian tribe or tribal organization should consider consolidating or breaking out procurement to obtain more economical purchases. Where appropriate, the Indian tribe or tribal organization shall compare leasing and purchasing alternatives to determine which is more economical. (d) The Indian tribe or tribal organization shall conduct all major procurement transactions by providing full and open competition, to the extent necessary to assure efficient expenditure of contract funds and to the extent feasible in the local area. (1) Indian tribes or tribal organizations shall develop their own definition for “major procurement transactions.” (2) As provided in sections 7 (b) and (c) of the Act, Indian preference and tribal preferences shall be applied in any procurement award. (e) The Indian tribe or tribal organization shall make procurement awards only to responsible entities who have the ability to perform successfully under the terms and conditions of the proposed procurement. In making this judgment, the Indian tribe or tribal organization will consider such matters as the contractor's integrity, its compliance with public policy, its record of past performance, and its financial and technical resources. (f) The Indian tribe or tribal organization shall maintain records on the significant history of all major procurement transactions. These records may include, but are not limited to, the rationale for the method of procurement, the selection of contract type, the contract selection or rejection, and the basis for the contract price. (g) The Indian tribe or tribal organization is solely responsible, using good administrative practice and sound business judgment, for processing and settling all contractual and administrative issues arising out of a procurement. These issues include, but are not limited to, source evaluation, protests, disputes, and claims. (1) The settlement of any protest, dispute, or claim shall not relieve the Indian tribe or tribal organization of any obligations under a self-determination contract. (2) Violations of law shall be referred to the tribal or Federal authority having proper jurisdiction. Each subcontract entered into under the Act shall at a minimum: (a) Be in writing; (b) Identify the interested parties, their authorities, and the purposes of the contract; (c) State the work to be performed under the contract; (d) State the process for making any claim, the payments to be made, and the terms of the contract, which shall be fixed; and (e) Be subject to sections 7 (b) and (c) of the Act. Certain provisions of the Act as well as other applicable Federal laws, regulations, and Executive Orders apply to subcontracts awarded under self-determination contracts. As a result, subcontracts should contain a provision informing the recipient that their award is funded with Indian Self-Determination Act funds and that the recipient is responsible for identifying and ensuring compliance with applicable Federal laws, regulations, and Executive Orders. The Secretary and the Indian tribe or tribal organization may, through negotiation, identify all or a portion of such requirements in the self-determination contract and, if so identified, these requirements should be identified in subcontracts. An Indian tribe or tribal organization's property management system shall account for all property furnished or transferred by the Secretary for use under a self-determination contract or acquired with contract funds. The property management system shall contain requirements for the use, care, maintenance, and disposition of Federally-owned and other property as follows: (a) Where title vests in the Indian tribe, in accordance with tribal law and procedures; or (b) In the case of a tribal organization, according to the internal property procedures of the tribal organization. The property management system of the Indian tribe or tribal organization shall track: (a) Personal property with an acquisition value in excess of $5,000 per item; (b) Sensitive personal property, which is all personal property that is subject to theft and pilferage, as defined by the Indian tribe or tribal organization. All firearms shall be considered sensitive personal property; and (c) Real property provided by the Secretary for use under the contract. The property management system shall maintain records that accurately describe the property, including any serial number or other identification number. These records should contain information such as the source, titleholder, acquisition date, cost, share of Federal participation in the cost, location, use and condition of the property, and the date of disposal and sale price, if any. Yes. Effective internal controls should include procedures: (a) For the conduct of periodic inventories; (b) To prevent loss or damage to property; and (c) To ensure that property is used for an Indian tribe or tribal organization's self-determination contract(s) until the property is declared excess to the needs of the contract consistent with the Indian tribe or tribal organization's property management system. A physical inventory should be conducted at least once every 2 years. The results of the inventory shall be reconciled with the Indian tribe or tribal organization's internal property and accounting records. Required maintenance includes the performance of actions necessary to keep the property in good working condition, the procedures recommended by equipment manufacturers, and steps necessary to protect the interests of the contractor and the Secretary in any express warranties or guarantees covering the property. If the Indian tribe or tribal organization chooses not to take title to property furnished by the government or acquired with contract funds, title to the property remains vested in the Secretary. A list of Federally-owned property to be used under the contract shall be included in the contract. Yes, except that requirements for the inventory and disposal of Federal property are different. There are three additional requirements: (a) The Indian tribe or tribal organization shall conduct a physical inventory of the Federally-owned property and reconcile the results with the Indian tribe or tribal organization's property records annually, rather than every 2 years; (b) Within 90 days following the end of an annual funding agreement, the Indian tribe or tribal organization shall certify and submit to the Secretary an annual inventory of all Federally-owned real and personal property used in the contracted program; and (c) The inventory shall report any increase or decrease of $5,000 or more in the value of any item of real property. The Indian tribe or tribal organization shall report to the Secretary in writing any Federally-owned personal property that is worn out, lost, stolen, damaged beyond repair, or no longer needed for the performance of the contract. (a) The Indian tribe or tribal organization shall state whether the Indian tribe or tribal organization wants to dispose of or return the property. (b) If the Secretary does not respond within 60 days, the Indian tribe or tribal organization may return the property to the Secretary, who shall accept transfer, custody, control, and responsibility for the property (together with all associated costs). Unless required by statute, there are no mandatory reporting requirements. Each Indian tribe or tribal organization shall negotiate with the Secretary the type and frequency of program narrative and program data report(s) which respond to the needs of the contracting parties and that are appropriate for the purposes of the contract. The extent of available resources will be a consideration in the negotiations. Any disagreements over reporting requirements are subject to the declination criteria and procedures in section 102 of the Act and subpart E. IHS will work with Indian tribe or tribal organization representatives to develop a mutually defined uniform subset of data that is consistent with Congressional intent, imposes a minimal reporting burden, and which responds to the needs of the contracting parties. No. The uniform data set, applicable to the services to be performed, will serve as the target for the Secretary and the Indian tribes or tribal organizations during individual negotiations on program data reporting requirements. Section 105(l) of the Act requires the Secretary, at the request of an Indian tribe or tribal organization, to enter into a lease with the Indian tribe or tribal organization for a building owned or leased by the tribe or tribal organization that is used for administration or delivery of services under the Act. The lease is to include compensation as provided in the statute as well as “such other reasonable expenses that the Secretary determines, by regulation, to be allowable.” This subpart contains requirements for these leases. To the extent that no element is duplicative, the following elements may be included in the lease compensation: (a) Rent (sublease); (b) Depreciation and use allowance based on the useful life of the facility based on acquisition costs not financed with Federal funds; (c) Contributions to a reserve for replacement of facilities; (d) Principal and interest paid or accrued; (e) Operation and maintenance expenses, to the extent not otherwise included in rent or use allowances, including, but not limited to, the following: (1) Water, sewage; (2) Utilities; (3) Fuel; (4) Insurance; (5) Building management supervision and custodial services; (6) Custodial and maintenance supplies; (7) Pest control; (8) Site maintenance (including snow and mud removal); (9) Trash and waste removal and disposal; (10) Fire protection/fire fighting services and equipment; (11) Monitoring and preventive maintenance of building structures and systems, including but not limited to: (i) Heating/ventilation/air conditioning; (ii) Plumbing; (iii) Electrical; (iv) Elevators; (v) Boilers; (vi) Fire safety system; (vii) Security system; and (viii) Roof, foundation, walls, floors. (12) Unscheduled maintenance; (13) Scheduled maintenance (including replacement of floor coverings, lighting fixtures, repainting); (14) Security services; (15) Management fees; and (16) Other reasonable and necessary operation or maintenance costs justified by the contractor; (f) Repairs to buildings and equipment; (g) Alterations needed to meet contract requirements; (h) Other reasonable expenses; and (i) The fair market rental for buildings or portions of buildings and land, exclusive of the Federal share of building construction or acquisition costs, or the fair market rental for buildings constructed with Federal funds exclusive of fee or profit, and for land. Reserve funds must be accounted for as a capital project fund or a special revenue fund. (a) The Indian tribe or tribal organization is the guardian of the fund. (b) Funds may be invested in accordance with the laws, regulations and policies of the Indian tribe or tribal organization subject to the terms of the lease or the self-determination contract. No. With the exception of paragraph (i) in §900.70, the same types of costs may be recovered in whole or in part under section 106(a) of the Act as direct or indirect charges to a self-determination contract. There are three options available: (a) The lease may be based on fair market rental. (b) The lease may be based on a combination of fair market rental and paragraphs (a) through (h) of §900.70, provided that no element of expense is duplicated in fair market rental. (c) The lease may be based on paragraphs (a) through (h) of §900.70 only. This subpart implements section 105(f) of the Act regarding donation of Federal excess and surplus property to Indian tribes or tribal organizations and acquisition of property with funds provided under a self-determination contract or grant. The Secretary will exercise discretion in a way that gives maximum effect to the requests of Indian tribes or tribal organizations for donation of BIA or IHS excess property and excess or surplus Federal property, provided that the requesting Indian tribe or tribal organization shall state how the requested property is appropriate for use for any purpose for which a self-determination contract or grant is authorized. (a) For government-furnished personal property made available to an Indian tribe or tribal organization before October 25, 1994: (1) The Secretary, in consultation with each Indian tribe or tribal organization, shall develop a list of the property used in a self-determination contract. (2) The Indian tribe or tribal organization shall indicate any items on the list to which the Indian tribe or tribal organization wants the Secretary to retain title. (3) The Secretary shall provide the Indian tribe or tribal organization with any documentation needed to transfer title to the remaining listed property to the Indian tribe or tribal organization. (b) For government-furnished real property made available to an Indian tribe or tribal organization before October 25, 1994: (1) The Secretary, in consultation with the Indian tribe or tribal organization, shall develop a list of the property furnished for use in a self-determination contract. (2) The Secretary shall inspect any real property on the list to determine the presence of any hazardous substance activity, as defined in 41 CFR 101–47.202.2(b)(10). If the Indian tribe or tribal organization desires to take title to any real property on the list, the Indian tribe or tribal organization shall inform the Secretary, who shall take such steps as necessary to transfer title to the Indian tribe or tribal organization. (c) For government-furnished real and personal property made available to an Indian tribe or tribal organization on or after October 25, 1994: (1) The Indian tribe or tribal organization shall take title to all property unless the Indian tribe or tribal organization requests that the United States retain the title. (2) The Secretary shall determine the presence of any hazardous substance activity, as defined in 41 CFR 101–47.202.2(b)(10). If the land is owned by the United States but not held in trust for an Indian tribe or individual Indian, the Indian tribe or tribal organization shall specify whether it wants to acquire fee title to the land or whether it wants the land to be held in trust for the benefit of a tribe. (a) If the Indian tribe or tribal organization requests fee title, the Secretary shall take the necessary action under Federal law and regulations to transfer fee title. (b) If the Indian tribe or tribal organization requests beneficial ownership with fee title to be held by the United States in trust for an Indian tribe: (1) The Indian tribe or tribal organization shall submit with its request a resolution of support from the governing body of the Indian tribe in which the beneficial ownership is to be registered. (2) If the request is submitted to the Secretary of Health and Human Services for land under the jurisdiction of that Secretary, the Secretary shall take all necessary steps to effect a transfer of the land to the Secretary of the Interior and shall also forward the Indian tribe or tribal organization's request and the tribe's resolution. (3) The Secretary of the Interior shall expeditiously process all requests in accordance with applicable Federal law and regulations. (4) The Secretary shall not require the Indian tribe or tribal organization to furnish any information in support of a request other than that required by law or regulation. (a) Except as provided in paragraph (b) of this section, when a self-determination contract or grant agreement, or portion thereof, is retroceded, reassumed, terminated, or expires, the Secretary shall have the option to take title to any item of government-furnished property: (1) That title has been transferred to an Indian tribe or tribal organization; (2) That is still in use in the program; and (3) That has a current fair market value, less the cost of improvements borne by the Indian tribe or tribal organization in excess of $5,000. (b) If property referred to in paragraph (a) of this section is shared between one or more ongoing contracts or grant agreements and a contract or grant agreement that is retroceded, reassumed, terminated or expires and the Secretary wishes to use such property in the retroceded or reassumed program, the Secretary and the contractor or grantee using such property shall negotiate an acceptable arrangement for continued sharing of such property and for the retention or transfer of title. Yes. The contractor takes title to such property, unless the contractor chooses to have the United States take title. In that event, the contractor must inform the Secretary of the purchase and identify the property and its location in such manner as the contractor and the Secretary deem necessary. A request for the United States to take title to any item of contractor-purchased property may be made at any time. A request for the Secretary to take fee title to real property shall be expeditiously processed in accordance with applicable Federal law and regulation. The contractor shall submit a resolution of support from the governing body of the Indian tribe in which the beneficial ownership is to be registered. If the request to take contractor-purchased real property into trust is submitted to the Secretary of Health and Human Services, that Secretary shall transfer the request to the Secretary of the Interior. The Secretary of the Interior shall expeditiously process all requests in accord with applicable Federal law and regulation. (a) Except as provided in paragraph (b) of this section when a self-determination contract or grant agreement, or portion thereof, is retroceded, reassumed, terminated, or expires, the Secretary shall have the option to take title to any item of government-furnished property: (1) Whose title has been transferred to an Indian tribe or tribal organization; (2) That is still in use in the program; and (3) That has a current fair market value, less the cost of improvements borne by the Indian tribe or tribal organization, in excess of $5,000. (b) If property referred to in paragraph (a) of this section is shared between one or more ongoing contracts or grant agreements and a contract or grant agreement that is retroceded, reassumed, terminated or expires and the Secretary wishes to use such property in the retroceded or reassumed program, the Secretary and the contractor or grantee using such property shall negotiate an acceptable arrangement for continued sharing of such property and for the retention or transfer of title. Yes. BIA or IHS excess property means property under the jurisdiction of the BIA or IHS that is excess to the agency's needs and the discharge of its responsibilities. The Secretary shall not less than annually send to Indian tribes and tribal organizations a listing of all excess BIA or IHS personal property before reporting the property to GSA or to any other Federal agency as excess. The listing shall identify the agency official to whom a request for donation shall be submitted. (a) The Indian tribe or tribal organization shall submit to the appropriate Secretary a request for specific property that includes a statement of how the property is intended for use in connection with a self-determination contract or grant. The Secretary shall expeditiously process the request and shall exercise discretion in a way that gives maximum effect to the request of Indian tribes or tribal organizations for the donation of excess BIA or IHS property. (b) If more than one request for the same item of personal property is submitted, the Secretary shall award the item to the requestor whose request is received on the earliest date. If two or more requests are received on the same date, the Secretary shall award the item to the requestor with the lowest transportation costs. The Secretary shall make the donation as expeditiously as possible. (c) If more than one request for the same parcel of real property is submitted, the Secretary shall award the property to the Indian tribe or tribal organization whose reservation or trust land is closest to the real property requested. The Indian tribe or tribal organization takes title to donated excess BIA or IHS property. The Secretary shall provide the Indian tribe or tribal organization with all documentation needed to vest title in the Indian tribe or tribal organization. (a) If an Indian tribe or tribal organization requests donation of fee title to excess real property that includes land not held in trust for an Indian tribe, the Indian tribe or tribal organization shall so specify in its request for donation. The Secretary shall take the necessary action under Federal law and regulations to transfer the title to the Indian tribe or tribal organization. (b) If an Indian tribe or tribal organization asks the Secretary to donate excess real property that includes land and requests that fee title to the land be held by the United States in trust for an Indian tribe, the requestor shall submit a resolution of support from the governing body of the Indian tribe in which the beneficial ownership is to be registered. (1) If the donation request is submitted to the Secretary of Health and Human Services, that Secretary shall take all steps necessary to transfer the land to the Secretary of the Interior with the Indian tribe or tribal organization's request and the Indian tribe's resolution. The Secretary of the Interior shall expeditiously process all requests in accordance with applicable Federal law and regulations. (2) The Secretary shall not require the Indian tribe or tribal organization to furnish any information in support of a request other than that required by law or regulation. Yes. When a self-determination contract or grant agreement, or portion—thereof, is retroceded, reassumed, terminated, or expires, the Secretary shall have the option to take title to any item of the property; (a) Except as provided in paragraph (b) of this section when a self-determination contract or grant agreement, or portion thereof, is retroceded, reassumed, terminated, or expires, the Secretary shall have the option to take title to any item of government-furnished property: (1) Whose title has been transferred to an Indian tribe or tribal organization; (2) That is still in use in the program; and (3) That has a current fair market value, less the cost of improvements borne by the Indian tribe or tribal organization, in excess of $5,000. (b) To the extent that any property referred to in paragraph (a) of this section is shared between one or more ongoing contracts or grant agreements and a contract or grant agreement that is retroceded, reassumed, terminated or expires and the Secretary wishes to use such property in the retroceded or reassumed program, the Secretary and the contractor or grantee using such property shall negotiate an acceptable arrangement for continued sharing of such property and for the retention or transfer of title. Yes. (a) “Excess government property” is real or personal property under the control of a Federal agency, other than BIA and IHS, which is not required for the agency's needs and the discharge of its responsibilities. (b) “Surplus government property” means excess real or personal property that is not required for the needs of and the discharge of the responsibilities of all Federal agencies that has been declared surplus by the General Services Administration (GSA). The Secretary shall furnish, not less than annually, to Indian tribes or tribal organizations listings of such property as may be made available from time to time by GSA or other Federal agencies, and shall obtain listings upon the request of an Indian tribe or tribal organization. (a) The Indian tribe or tribal organization shall file a request for specific property with the Secretary, and shall state how the property is appropriate for use for a purpose for which a self-determination contract or grant is authorized under the Act. (b) The Secretary shall expeditiously process such request and shall exercise discretion to acquire the property in the manner described in §900.86 of this subpart. (c) Upon approval of the Indian tribe or tribal organization's request, the Secretary shall immediately request acquisition of the property from the GSA or the holding agency, as appropriate, by submitting the necessary documentation in order to acquire the requested property prior to the expiration of any “freeze” placed on the property by the Indian tribe or tribal organization. (d) The Secretary shall specify that the property is requested for donation to an Indian tribe or tribal organization pursuant to authority provided in section 105(f)(3) of the Act. (e) The Secretary shall request a waiver of any fees for transfer of the property in accordance with applicable Federal regulations. (a) Title to any donated excess or surplus Federal personal property shall vest in the Indian tribe or tribal organization upon taking possession. (b) Legal title to donated excess or surplus Federal real property shall vest in the Indian tribe or tribal organization upon acceptance by the Indian tribe or tribal organization of a proper deed of conveyance. (c) If the donation of excess or surplus Federal real property includes land owned by the United States but not held in trust for an Indian tribe, the Indian tribe or tribal organization shall specify whether it wants to acquire fee title to the land or whether it wants the land to be held in trust for the benefit of an Indian tribe. (1) If the Indian tribe or tribal organization requests fee title, the Secretary shall take the necessary action under Federal law and regulations to transfer fee title to the Indian tribe or tribal organization. (2) If the Indian tribe or tribal organization requests beneficial ownership with fee title to be held by the United States in trust for an Indian tribe: (i) The Indian tribe or tribal organization shall submit with its request a resolution of support from the governing body of the Indian tribe in which the beneficial ownership is to be registered. (ii) If the donation request of the Indian tribe or tribal organization is submitted to the Secretary of Health and Human Services, that Secretary shall take all necessary steps to acquire the land and transfer it to the Secretary of the Interior and shall also forward the Indian tribe or tribal organization's request and the Indian tribe's resolution. (iii) The Secretary of the Interior shall expeditiously process all requests in accord with applicable Federal law and regulations. (iv) The Secretary shall not require submission of any information other than that required by Federal law and regulation. No. Section 105(f)(3) of the Act does not give the Secretary the authority to reacquire title to excess or surplus government property acquired from other agencies for donation to an Indian tribe or tribal organization. Government-furnished property, contractor-purchased property and excess BIA and IHS property donated to an Indian tribe or tribal organization to which an Indian tribe or tribal organization holds title shall remain eligible for replacement funding to the same extent as if title to that property were held by the United States. (a) This subpart establishes requirements for issuing fixed-price or cost-reimbursable contracts to provide: design, construction, repair, improvement, expansion, replacement, erection of new space, or demolition and other related work for one or more Federal facilities. It applies to tribal facilities where the Secretary is authorized by law to design, construct and/or renovate, or make improvements to such tribal facilities. (b) Activities covered by construction contracts under this subpart are: design and architectural/engineering services, construction project management, and the actual construction of the building or facility in accordance with the construction documents, including all labor, materials, equipment, and services necessary to complete the work defined in the construction documents. (1) Such contracts may include the provision of movable equipment, telecommunications and data processing equipment, furnishings (including works of art), and special purpose equipment, when part of a construction contract let under this subpart. (2) While planning services and construction management services as defined in §900.113 may be included in a construction contract under this subpart, they may also be contracted separately using the model agreement in section 108 of the Act. The Secretary shall, upon the request of any Indian tribe or tribal organization authorized by tribal resolution, enter into a self-determination contract to plan, conduct, and administer construction programs or portions thereof. (a) Construction programs generally include the following activities in phases which can vary by funding source (an Indian tribe or tribal organization should contact its funding source for more information regarding the conduct of its program): (1) The preplanning phase. The phase during which an initial assessment and determination of project need is made and supporting information collected for presentation in a project application. This project application process is explained in more detail in §900.122; (2) The planning phase. The phase during which planning services are provided. This phase can include conducting and preparing a detailed needs assessment, developing justification documents, completing and/or verifying master plans, conducting predesign site investigations and selection, developing budget cost estimates, conducting feasibility studies, and developing a project Program of Requirements (POR); (3) The design phase. The phase during which licensed design professional(s) using the POR as the basis for design of the project, prepare project plans, specifications, and other documents that are a part of the construction documents used to build the project. Site investigation and selection activities are completed in this phase if not conducted as part of the planning phase. (4) The construction phase. The phase during which the project is constructed. The construction phase includes providing the labor, materials, equipment, and services necessary to complete the work in accordance with the construction documents prepared as part of the design phase. (b) The following activities may be part of phases described in paragraphs (a)(2), (a)(3), and (a)(4) of this section: (1) Management; and (2) Environmental, archeological, cultural resource, historic preservation, and similar assessments and associated activities. (a) Construction contract means a fixed-price or cost-reimbursement self-determination contract for a construction project, except that such term does not include any contract: (1) That is limited to providing planning services and construction management services (or a combination of such services); (2) For the Housing Improvement Program or roads maintenance program of the Bureau of Indian Affairs administered by the Secretary of the Interior; or (3) For the health facility maintenance and improvement program administered by the Secretary of Health and Human Services. (b) Construction management services (CMS) means activities limited to administrative support services; coordination; and monitoring oversight of the planning, design, and construction process. An Indian tribe or tribal organization's employee or construction management services consultant (typically an engineer or architect) performs such activities as: (1) Coordination and information exchange between the Indian tribe or tribal organization and the Federal government; (2) Preparation of Indian tribe or tribal organization's construction contract proposals; (3) Indian tribe or tribal organization subcontract scope of work identification and subcontract preparation, and competitive selection of Indian tribe or tribal organization construction contract subcontractors (see §900.110); (4) Review of work to ensure compliance with the POR and/or the construction contract. This does not involve construction project management as defined in paragraph (d) of this section. (c) Construction programs include programs for the planning, design, construction, repair, improvement, and expansion of buildings or facilities, including but not limited to, housing, law enforcement and detention facilities, sanitation and water systems, roads, schools, administration and health facilities, irrigation and agricultural work, water conservation, flood control, and port facilities, and environmental, archeological, cultural resource, historic preservation, and conduct of similar assessments. (d) Construction project management means direct responsibility for the construction project through day-to-day on-site management and administration of the project. Activities may include cost management, project budgeting, project scheduling, procurement services. (e) Design means services performed by licensed design professionals related to preparing drawings, specifications, and other design submissions specified in the contract, as well as services provided by or for licensed design professionals during the bidding/negotiating, construction, and operational phases of the project. (f) Planning services means activities undertaken to support agency and/or Congressional funding of a construction project. Planning services may include performing a needs assessment, completing and/or verifying master plans, developing justification documents, conducting pre-design site investigations, developing budget cost estimates, conducting feasibility studies as needed and completion of approved justification documents and a program of requirements (POR) for the project. (g) Program of Requirements (POR) is a planning document developed during the planning phase for an individual project. It provides background about the project; site information; programmatic needs; and, for facilities projects, a detailed room-by-room listing of spaces, including net and gross sizes, finish materials to be used, furnishings and equipment, and other information and design criteria on which to base the construction project documents. (h) Scope of work means the description of the work to be provided through a contract issued under this subpart and the methods and processes to be used to accomplish that work. A scope of work is typically developed based on criteria provided in a POR during the design phase, and project construction documents (plans and specifications) during the construction phase. There is a separate subpart because the Act differentiates between construction contracts and the model agreement in section 108 of the Act which is required for contracting other activities. Construction contracts are separately defined in the Act and are subject to a separate proposal and review process. (a) A self-determination construction contract is a government-to-government agreement that transfers control of the construction project, including administrative functions, to the contracting Indian tribe or tribal organization to facilitate effective and meaningful participation by the Indian tribe or tribal organization in planning, conducting, and administering the construction project, and so that the construction project is responsive to the true needs of the Indian community. The Secretary's role in the conduct of a contracted construction project is limited to the Secretary's responsibilities set out in §900.131. (b) Self-determination construction contracts are not traditional “procurement” contracts. (1) With respect to a construction contract (or a subcontract of such a construction contract), the provisions of the Office of Federal Procurement Policy Act (41 U.S.C. 401 et seq.) and the regulations promulgated under that Act, shall apply to a construction contract or subcontract only to the extent that application of the provision is: (i) Necessary to ensure that the contract may be carried out in a satisfactory manner; (ii) Directly related to the construction activity; and (iii) Not inconsistent with the Act. (2) A list of the Federal requirements that meet the requirements of this paragraph shall be included in an attachment to the contract under negotiations between the Secretary and the Indian tribe or tribal organization. (3) Except as provided in paragraph (b)(2) of this section, no Federal law listed in section 105(3)(C)(ii) of the Act or any other provision of Federal law (including an Executive order) relating to acquisition by the Federal government shall apply to a construction contract that an Indian tribe or tribal organization enters into under this Act, unless expressly provided in the law. (c) Provisions of a construction contract under this subpart shall be liberally construed in favor of the contracting Indian tribe or tribal organization. Yes, except that in negotiated fixed-price construction contracts, appropriate clauses shall be negotiated to allocate properly the contract risks between the government and the contractor. (a) These regulations apply to planning services contracts only as provided in this section. (1) The Indian tribe or tribal organization shall submit to the Secretary for review and approval the POR documents produced as a part of a model contract under section 108 of the Act or under a construction contract under this subpart. (i) Within 60 days after receipt of the POR from the Indian tribe or tribal organization for a project that has achieved priority ranking or that is funded, the Secretary shall: (A) Approve the POR; (B) Notify the Indian tribe or tribal organization of and make available any objections to the POR that the Secretary may have; or (C) Notify the Indian tribe or tribal organization of the reasons why the Secretary will be unable either to approve the POR or to notify the Indian tribe or tribal organization of any objections within 60 days, and state the time within which the notification will be made, provided that the extended time shall not exceed 60 additional days. (ii) Within a maximum of 180 days after receipt of a POR from an Indian tribe or tribal organization for a project that is not funded and is not described in paragraph (a)(1)(i) of this section, the Secretary shall: (A) Approve the POR; or (B) Notify the Indian tribe or tribal organization of and make available any objections to the POR; or (C) Notify the Indian tribe or tribal organization of the reasons why the Secretary will be unable either to approve the POR or to notify the Indian tribe or tribal organization of any objections within 180 days, and state the time within which the notification will be made, provided that the extended time shall not exceed 60 additional days. (2) Any failure of the Secretary to act on a POR within the applicable period required in paragraph (a)(1) of this section will be deemed a rejection of the POR and will authorize the commencement of any appeal as provided in section 110 of the Act, or, if a model agreement under section 108 of the Act is used, the disputes provision of that agreement. (3) If an Indian tribe or tribal organization elects to provide planning services as part of a construction contract rather than under a model agreement as set out in section 108 of the Act, the regulations in this subpart shall apply. (b) The parties to the contract are encouraged to consult during the development of the POR and following submission of the POR to the Secretary. No. Construction management services may be contracted separately under section 108 of the Act. Construction management services consultants and/or Indian tribe or tribal organization employees assist and advise the Indian tribe or tribal organization to implement construction contracts, but have no contractual relationship with or authority to direct construction contract subcontractors. (a) If the Indian tribe or tribal organization chooses to contract solely for construction management services, these services shall be limited to: (1) Coordination and exchange of information between the Indian tribe or tribal organization and the Secretary; (2) Review of work produced by the Secretary to determine compliance with: (i) The POR and design contract during the design stage; or (ii) The project construction documents during the construction stage; (3) Disputes shall be resolved in accordance with the disputes clause of the CMS contract. (b) If the Indian tribe or tribal organization conducts CMS under section 108 of the Act and the Indian tribe or tribal organization contracts separately under this subpart for all or some of the activities in §900.110, the contracted activities shall be limited to: (1) Coordination and exchange of information between the Indian tribe or tribal organization and Secretary; (2) Preparation of tribal or tribal organization construction subcontract scope of work identification and subcontract preparation, and competitive selection of tribal or tribal organization construction contract subcontractors; (3) Review of work produced by tribal or tribal organization construction subcontractors to determine compliance with: (i) The POR and the design contract during the design stage; or (ii) The project construction documents during the construction stage. Before spending any funds for a planning, design, construction, or renovation project, whether subject to a competitive application and ranking process or not, the Secretary shall consult with any Indian tribe or tribal organization(s) that would be significantly affected by the expenditure to determine and to follow tribal preferences to the greatest extent feasible concerning: size, location, type, and other characteristics of the project. Within 30 days after the Secretary's allocation of funds for planning phase, design phase, or construction phase activities for a specific project, the Secretary shall notify, by registered mail with return receipt in order to document mailing, the Indian tribe or tribal organization(s) to be benefitted by the availability of the funds for each phase of a project. The Secretarial notice of fund allocation shall offer technical assistance in the preparation of a contract proposal. (a) The Secretary shall, within 30 days after receiving a request from an Indian tribe or tribal organization, furnish the Indian tribe or tribal organization with all information available to the Secretary about the project including, but not limited to: construction drawings, maps, engineering reports, design reports, plans of requirements, cost estimates, environmental assessments, or environmental impact reports and archeological reports. (b) An Indian tribe or tribal organization is not required to request this information prior to submitting a notification of intent to contract or a contract proposal. (c) The Secretary shall have a continuing responsibility to furnish information. (a) The application and ranking process for developing a priority listing of projects varies between agencies. There are, however, steps in the selection process that are common to most selection processes. An Indian tribe or tribal organization that wishes to secure a construction project should contact the appropriate agency to determine the specific steps involved in the application and selection process used to fund specific types of projects. When a priority process is used in the selection of construction projects, the steps involved in the application and ranking process are as follows: (1) Application. The agency solicits applications from Indian tribes or tribal organizations. In the request for applications, the Secretary provides specific information regarding the type of project to be funded, the objective criteria that will be used to evaluate applications, the points or weight that each criterion will be assigned, and the time when applications are due. An Indian tribe or tribal organization may prepare the application (technical assistance from the agency, within resources available, shall be provided upon request from an Indian tribe or tribal organization) or may rely upon the agency to prepare the application. (2) Ranking/Prioritization. The Secretary evaluates the applications based on the criteria provided as part of the application preparation process. The Secretary applies only criteria and weights assigned to each criteria that were disclosed to the Indian tribe or tribal organization during the application stage. The applications are then ranked in order from the application that best meets application criteria to the application that least meet the application criteria. (3) Validation. Before final acceptance of a ranked application, the information, such as demographic information, deficiency levels reported in application, the condition of existing facilities, and program housing needs, is validated. During this process, additional information may be developed by the Indian tribe or tribal organization in support of the original information or the Secretary may designate a representative of the Department to conduct an on-site review of the information contained in the application. (b) [Reserved] (a) The Act establishes a special process for review and negotiation of proposals for construction contracts which is different than that for other self-determination contract proposals. The Indian tribe or tribal organization should notify the Secretary of its intent to contract. After notification, the Indian tribe or tribal organization should prepare its contract proposal in accordance with the sections of this subpart. While developing its construction contract proposal, the Indian tribe or tribal organization can request technical assistance from the Secretary. Not later than 30 days after receiving a request from an Indian tribe or tribal organization, the Secretary shall provide to the Indian tribe or tribal organization all information available about the construction project, including construction drawings, maps, engineering reports, design reports, plans of requirements, cost estimates, environmental assessments, or environmental impact reports, and archaeological reports. The responsibility of the Secretary to furnish this information shall be a continuing one. (b) At the request of the Indian tribe or tribal organization and before finalizing its construction contract proposal, the Secretary shall provide for a precontract negotiation phase during the development of a contract proposal. Within 30 days the Secretary shall acknowledge receipt of the proposal and, if requested by the Indian tribe or tribal organization, shall confer with the Indian tribe or tribal organization to develop a negotiation schedule. The negotiation phase shall include, at a minimum: (1) The provision of technical assistance under section 103 of the Act and paragraph (a) of this section; (2) A joint scoping session between the Secretary and the Indian tribe or tribal organization to review all plans, specifications, engineering reports, cost estimates, and other information available to the parties, for the purpose of identifying all areas of agreement and disagreement; (3) An opportunity for the Secretary to revise plans, designs, or cost estimates of the Secretary in response to concerns raised, or information provided by, the Indian tribe or tribal organization; (4) A negotiation session during which the Secretary and the Indian tribe or tribal organization shall seek to develop a mutually agreeable contract proposal; and (5) Upon the request of the Indian tribe or tribal organization, the use of alternative dispute resolution to resolve remaining areas of disagreement under the dispute resolution provisions under subchapter IV of chapter 5 of the United States Code. (a) If the Secretary and the Indian tribe or tribal organization are unable to develop a mutually agreeable construction contract proposal under the procedures in §900.122, the Indian tribe or tribal organization may submit a final contract proposal to the Secretary. Not later than 30 days after receiving the final contract proposal, the Secretary shall approve the contract proposal and award the contract, unless, during the period the Secretary declines the proposal under sections 102(a)(2) and 102(b) of the Act (including providing opportunity for an appeal under section 102(b)). (b) Whenever the Secretary declines to enter into a self-determination contract or contracts under section 102(a)(2) of the Act, the Secretary shall: (1) State any objections to the contract proposal (as submitted by the Indian tribe or tribal organization) in writing and provide all documents relied on in making the declination decision within 20 days of such decision to the Indian tribe or tribal organization; (2) Provide assistance to the Indian tribe or tribal organization to overcome the stated objections; (3) Provide the Indian tribe or tribal organization with a hearing on the record with the right to engage in full discovery relevant to any issue raised in the matter and the opportunity for appeal on the objections raised, under the regulations set forth in subpart L, except that the Indian tribe or tribal organization may, in lieu of filing the appeal, initiate an action in a Federal district court and proceed directly under section 110(a) of the Act. Yes. A grant agreement or a cooperative agreement may be used in lieu of a contract under sections 102 and 103 of the Act when agreed to by the Secretary and the Indian tribe or tribal organization. Under the grant concept, the grantee will assume full responsibility and accountability for design and construction performance within the funding limitations. The grantee will manage and administer the work with minimal involvement by the government. The grantee will be expected to have acceptable management systems for finance, procurement, and property. The Secretary may issue Federal construction guidelines and manuals applicable to its construction programs, and the government shall accept tribal proposals for alternatives which are consistent with or exceed Federal guidelines or manuals applicable to construction programs. (a) In addition to the full name, address, and telephone number of the Indian tribe or tribal organization submitting the construction proposal, a construction contract proposal shall contain descriptions of the following standards under which they propose to operate the contract: (1) The use of licensed and qualified architects; (2) Applicable health and safety standards; (3) Adherence to applicable Federal, State, local, or tribal building codes and engineering standards; (4) Structural integrity; (5) Accountability of funds; (6) Adequate competition for subcontracting under tribal or other applicable law; (7) The commencement, performance, and completion of the contract; (8) Adherence to project plans and specifications (including any applicable Federal construction guidelines and manuals and the Secretary shall accept tribal proposals for alternatives which are consistent with or exceed Federal guidelines or manuals applicable to construction programs); (9) The use of proper materials and workmanship; (10) Necessary inspection and testing; (11) With respect to the self-determination contract between the Indian tribe or tribal organization and Federal government, a process for changes, modifications, stop work, and termination of the work when warranted; (b) In addition to provisions regarding the program standards listed in paragraph (a) of this section or the assurances listed in paragraph (c) of this section, the Indian tribe or tribal organization shall also include in its construction contract proposal the following: (1) In the case of a contract for design activities, this statement, “Construction documents produced as part of this contract will be produced in accordance with the Program of Requirements and/or Scope of Work,” and the POR and/or Scope of Work shall be attached to the contract proposal. If tribal construction procedures, standards and methods (including national, regional, state, or tribal building codes or construction industry standards) are consistent with or exceed applicable Federal standards then the Secretary shall accept the tribally proposed standards; and (2) In the case of a contract for construction activities, this statement, “The facility will be built in accordance with the construction documents produced as a part of design activities. The project documents, including plans and specifications, are hereby incorporated into this contract through this reference.” If tribal construction procedures, standards and methods (including national, regional, state, or tribal building codes or construction industry standards) are consistent with or exceed applicable Federal standards then the Secretary shall accept the tribally proposed standards; and (3) Proposed methods to accommodate the responsibilities of the Secretary provided in §900.131; and (4) Proposed methods to accommodate the responsibilities of the Indian tribe or tribal organization provided in §900.130 unless otherwise addressed in paragraph (a) of this section and minimum staff qualifications proposed by the Indian tribe or tribal organization, if any; (5) A contract budget as described in §900.127; and (6) A period of performance for the conduct of all activities to be contracted; (7) A payment schedule as described in §900.132; (8) A statement indicating whether or not the Indian tribe or tribal organization has a CMS contract related to this project; (9) Current (unrevoked) authorizing resolutions in accordance with §900.5(d) from all Indian tribes benefitting from the contract proposal; and (10) Any responsibilities, in addition to the Federal responsibilities listed in §900.131, which the Indian tribe or tribal organization proposes the Federal government perform to assist with the completion of the scope of work; (c) The Indian tribe or tribal organization will provide the following assurances in its contract proposal: (1) If the Indian tribe or tribal organization elects not to take title (pursuant to subpart I) to Federal property used in carrying out the contract, “The Indian tribe or tribal organization will not dispose of, modify the use of, or change the terms of the real property title, or other interest in the site and facilities without permission and instructions from the awarding agency. The Indian tribe or tribal organization will record the Federal interest in the title of real property in accordance with awarding agency directives and will include a covenant in the title of real property acquired in whole or in part with Federal assistance funds to assure nondiscrimination during the useful life of the project”; and (2) “The Indian tribe or tribal organization will comply with the Lead-Based Paint Poisoning Prevention Act (42 U.S.C. 4801 et seq.)” which prohibits the use of lead based paint in construction or rehabilitation of residential structures; (3) “The Indian tribe or tribal organization will comply, or has already complied, with the requirements of titles II and III of the Uniform Relocation Assistance and Real Property Acquisition Policies Act of 1970 (Pub. L. 91–646),” which provides for fair and equitable treatment of persons displaced or whose property is acquired as a result of Federal participation in purchases; and (4) “Except for work performed by tribal or tribal organization employees, the Indian tribe or tribal organization will comply, as applicable, with the provisions of the Davis-Bacon Act (40 U.S.C. 276c and 18 U.S.C. 874),” for Federally assisted construction subagreements; (5) “The Indian tribe or tribal organization will comply with the flood insurance purchase requirements of section 102(a) of the Flood Disaster Protection Act of 1973 (Pub. L. 93–234),” which requires recipients in a special flood hazard area to participate in the program and to purchase flood insurance if the total cost of insurable construction and acquisition is $10,000 or more; (6) “The Indian tribe or tribal organization will comply with all applicable Federal environmental laws, regulations, and Executive Orders;” (7) “The Indian tribe or tribal organization will comply with the Wild and Scenic Rivers Act of 1968 (16 U.S.C. 1271 et seq.) related to protecting the components or potential components of the national wild and scenic rivers system;” (8) “The Indian tribe or tribal organization will assist the awarding agency in assuring compliance with section 106 of the National Historic Preservation Act of 1966, as amended (16 U.S.C. 470), EO 11593 (identification and preservation of historic properties), and the Archaeological and Historic Preservation Act of 1974 (16 U.S.C. 469a–1 et seq.).” (d) The Indian tribe or tribal organization and the Secretary will both make a good faith effort to identify any other applicable Federal laws, Executive Orders, or regulations applicable to the contract, share them with the other party, and refer to them in the construction contract. The parties will make a good faith effort to identify tribal laws, ordinances, and resolutions which may affect either party in the performance of the contract. Each agency may provide or the Indian tribe or tribal organization may request Federal construction guidelines and manuals for consideration by the Indian tribe or tribal organization in the preparation of its contract proposal. If tribal construction procedures, standards and methods (including national, regional, State, or tribal building codes or construction industry standards) are consistent with or exceed applicable Federal standards, the Secretary shall accept the tribally proposed standards. (a) The costs incurred will vary depending on which phase (see §900.112) of the construction process the Indian tribe or tribal organization is conducting and the type of contract that will be used. The total amount awarded under a construction contract shall reflect an overall fair and reasonable price to the parties (see §900.129). (b) Costs for activities under this subpart that have not been billed, allocated, or recovered under a contract issued under section 108 of the Act should be included. (c) The Indian tribe or tribal organization's budget should include the cost elements that reflect an overall fair and reasonable price. These costs include: (1) The reasonable costs to the Indian tribe or tribal organization of performing the contract, taking into consideration the terms of the contract and the requirements of the Act and any other applicable law; (2) The costs of preparing the contract proposal and supporting cost data; (3) The costs associated with auditing the general and administrative costs of the Indian tribe or tribal organization associated with the management of the construction contract; and (4) In cases where the Indian tribe or tribal organization is submitting a fixed-price construction contract: (i) The reasonable costs to the Indian tribe or tribal organization for general administration incurred in connection with the project that is the subject of the contract; (ii) The ability of the contractor that carries out the construction contract to make a reasonable profit, taking into consideration the risks associated with carrying out the contract, local market conditions, and other relevant considerations. (d) In establishing a contract budget for a construction project, the Secretary shall not be required to identify separately the components described in paragraphs (c)(4)(i) and (c)(4)(ii) of this section. (e) The Indian tribe or tribal organization's budget proposal includes a detailed budget breakdown for performing the scope of work including a total “not to exceed” dollar amount with which to perform the scope of work. Specific budget line items, if requested by the Indian tribe or tribal organization, can include the following: (1) The administrative costs the Indian tribe or tribal organization may incur including: (i) Personnel needed to provide administrative oversight of the contract; (ii) Travel costs incurred, both local travel incurred as a direct result of conducting the contract and remote travel necessary to review project status with the Secretary; (iii) Meeting costs incurred while meeting with community residents to develop project documents; (iv) Fees to be paid to consultants, such as demographic consultants, planning consultants, attorneys, accountants, and personnel who will provide construction management services; (2) The fees to be paid to architects and engineers to assist in preparing project documents and to assist in oversight of the construction process; (3) The fees to be paid to develop project surveys including topographical surveys, site boundary descriptions, geotechnical surveys, archeological surveys, and NEPA compliance, and; (4) In the case of a contract to conduct project construction activities, the fees to provide a part-time or full-time on-site inspector, depending on the terms of the contract, to monitor construction activities; (5) In the case of a contract to conduct project construction activities, project site development costs; (6) In the case of a contract to conduct project construction activities, project construction costs including those costs described in paragraph (c)(4), of this section; (7) The cost of securing and installing moveable equipment, telecommunications and data processing equipment, furnishings, including works of art, and special purpose equipment when part of a construction contract; (8) A contingency amount for unanticipated conditions of the construction phase of cost-reimbursable contracts. The amount of the contingency provided shall be 3 percent of activities being contracted or 50 percent of the available contingency funds, whichever is greater. In the event provision of required contingency funds will cause the project to exceed available project funds, the discrepancy shall be reconciled in accordance with §900.129(e). Any additional contingency funds for the construction phase will be negotiated on an as-needed basis subject to the availability of funds and the nature, scope, and complexity of the project. Any contingency for other phases will be negotiated on a contract-by-contract basis. Unused contingency funds obligated to the contract and remaining at the end of the contract will be considered savings. (9) Other costs incurred that are directly related to the conduct of contract activities. The Secretary shall provide an amount under a construction contract that reflects an overall fair and reasonable price to the parties. These costs include: (a) The reasonable costs to the Indian tribe or tribal organization of performing the contract, taking into consideration the terms of the contract and the requirements of the Act and any other applicable law; (b) The costs of preparing the contract proposal and supporting cost data; and (c) The costs associated with auditing the general and administrative costs of the tribal organization associated with the management of the construction contract; and (d) If the Indian tribe or tribal organization is submitting a fixed-price construction contract: (1) The reasonable costs to the Indian tribe or tribal organization for general administration incurred in connection with the project that is the subject of the contract; (2) The ability of the contractor that carries out the construction contract to make a reasonable profit, taking into consideration the risks associated with carrying out the contract, local market conditions, and other relevant considerations including but not limited to contingency. (3) In establishing a contract budget for a construction project, the Secretary is not required to identify separately the components described in paragraph (d) (1) and (d) (2) of this sections. (a) Throughout the contract award process, the Secretary and Indian tribe or tribal organization shall share all construction project cost information available to them in order to facilitate reaching agreement on an overall fair and reasonable price for the project or part thereof. In order to enhance this communication, the government's estimate of an overall fair and reasonable price shall: (1) Contain a level of detail appropriate to the nature and phase of the work and sufficient to allow comparisons to the Indian tribe or tribal organization's estimate; (2) Be prepared in a format coordinated with the Indian tribe or tribal organization; and (3) Include the cost elements contained in section 105(m)(4) of the Act. (b) The government's cost estimate shall be an independent cost estimate based on such information as the following: (1) Prior costs to the government for similar projects adjusted for comparison to the target location, typically in unit costs, such as dollars per pound, square meter cost of building, or other unit cost that can be used to make a comparison; (2) Actual costs previously incurred by the Indian tribe or tribal organization for similar projects; (3) Published price lists, to include regional adjustment factors, for materials, equipment, and labor; and (4) Projections of inflation and cost trends, including projected changes such as labor, material, and transportation costs. (c) The Secretary shall provide the initial government cost estimate to the Indian tribe or tribal organization and make appropriate revisions based on concerns raised or information provided by the Indian tribe or tribal organization. The Secretary and the Indian tribe or tribal organization shall continue to revise, as appropriate, their respective cost estimates based on changed or additional information such as the following: (1) Actual subcontract bids; (2) Changes in inflation rates and market conditions, including local market conditions; (3) Cost and price analyses conducted by the Secretary and the Indian tribe or tribal organization during negotiations; (4) Agreed-upon changes in the size, scope and schedule of the construction project; and (5) Agreed-upon changes in project plans and specifications. (d) Considering all of the information available, the Secretary and the Indian tribe or tribal organization shall negotiate the amount of the construction contract. The objective of the negotiations is to arrive at an amount that is fair under current market conditions and reasonable to both the government and the Indian tribe or tribal organization. As a result, the agreement does not necessarily have to be in strict conformance with either party's cost estimate nor does agreement have to be reached on every element of cost, but only on the overall fair and reasonable price of each phase of the work included in the contract. (e) If the fair and reasonable price arrived at under paragraph (d) of this section would exceed the amount available to the Secretary, then: (1) If the Indian tribe or tribal organization elects to submit a final proposal, the Secretary may decline the proposal under section 105(m)(4)(C)(v) of the Act or if the contract has been awarded, dispute the matter under the Contract Disputes Act; or (2) If requested by the Indian tribe or tribal organization: (i) The Indian tribe or tribal organization and the Secretary may jointly explore methods of expanding the available funds through the use of contingency funds, advance payments in accordance with §900.132, rebudgeting, or seeking additional appropriations; or (ii) The Indian tribe or tribal organization may elect to propose a reduction in project scope to bring the project price within available funds; or (iii) The Secretary and Indian tribe or tribal organization may agree that the project be executed in phases. (a) The Indian tribe or tribal organization is responsible for the successful completion of the project in accordance with the approved contract documents. (b) If the Indian tribe or tribal organization is contracting to perform design phase activities, the Indian tribe or tribal organization shall have the following responsibilities: (1) The Indian tribe or tribal organization shall subcontract with or provide the services of licensed and qualified architects and other consultants needed to accomplish the self-determination construction contract. (2) The Indian tribe or tribal organization shall administer and disburse funds provided through the contract in accordance with subpart F, §900.42 through §900.45 and implement a property management system in accordance with subpart F, §900.51 through §900.60. (3) The Indian tribe or tribal organization shall direct the activities of project architects, engineers, and other project consultants, facilitate the flow of information between the Indian tribe or tribal organization and its subcontractors, resolve disputes between the Indian tribe or tribal organization and its subcontractors or between its subcontractors, and monitor the work produced by its subcontractors to ensure compliance with the POR. (4) The Indian tribe or tribal organization shall direct the work of its subcontractors so that work produced is provided in accordance with the contract budget and contract performance period as negotiated between and agreed to by the parties. (5) The Indian tribe or tribal organization shall provide the Secretary with an opportunity to review and provide written comments on the project plans and specifications only at the concept phase, the schematic phase (or the preliminary design), the design development phase, and the final construction documents phase and approve the project plans and specifications for general compliance with contract requirements only at the schematic phase (or the preliminary design) and the final construction documents phase or as otherwise negotiated. (6) The Indian tribe or tribal organization shall provide the Secretary with the plans and specifications after their final review so, if needed, the Secretary may obtain an independent government cost estimate in accordance with §900.131(b)(4) for the construction of the project. (7) The Indian tribe or tribal organization shall retain project records and design documents for a minimum of 3 years following completion of the contract. (8) The Indian tribe or tribal organization shall provide progress reports and financial status reports quarterly, or as negotiated, that contain a narrative of the work accomplished, including but not limited to descriptions of contracts, major subcontracts, and modifications implemented during the report period and A/E service deliverables, the percentage of the work completed, a report of funds expended during the reporting period, and total funds expended for the project. The Indian tribe or tribal organization shall also provide copies, for the information of the Secretary, of an initial work and payment schedule and updates as they may occur. (c) If the Indian tribe or tribal organization is contracting to perform project construction phase activities, the Indian tribe or tribal organization shall have the following responsibilities: (1) The Indian tribe or tribal organization shall subcontract with or provide the services of licensed and qualified architects and other consultants as needed to accomplish the self-determination construction contract. (2) The Indian tribe or tribal organization shall administer and dispense funds provided through the contract in accordance with subpart F, §900.42 through §900.45 and implement a property management system in accordance with subpart F, §900.51 through §900.60. (3) The Indian tribe or tribal organization shall subcontract with or provide the services of construction contractors or provide its own forces to conduct construction activities in accordance with the project construction documents or as otherwise negotiated between and agreed to by the parties. (4) The Indian tribe or tribal organization shall direct the activities of project architects, engineers, construction contractors, and other project consultants, facilitate the flow of information between the Indian tribe or tribal organization and its subcontractors, resolve disputes between itself and its subcontractors or between its subcontractors, and monitor the work produced by its subcontractors to assure compliance with the project plans and specifications. (5) The Indian tribe or tribal organization shall manage or provide for the management of day-to-day activities of the contract including the issuance of construction change orders to subcontractors except that, unless the Secretary agrees: (i) The Indian tribe or tribal organization may not issue a change order to a construction subcontractor that will cause the Indian tribe or tribal organization to exceed its self-determination contract budget; (ii) The Indian tribe or tribal organization may not issue a change order to a construction subcontractor that will cause the Indian tribe or tribal organization to exceed the performance period in its self-determination contract budget; or (iii) The Indian tribe or tribal organization may not issue to a construction subcontractor a change order that is a significant departure from the scope or objective of the project. (6) The Indian tribe or tribal organization shall direct the work of its subcontractors so that work produced is provided in accordance with the contract budget and performance period as negotiated between and agreed to by the parties. (7) The Indian tribe or tribal organization shall provide to the Secretary progress and financial status reports. (i) The reports shall be provided quarterly, or as negotiated, and shall contain a narrative of the work accomplished, the percentage of the work completed, a report of funds expended during the reporting period, and total funds expended for the project. (ii) The Indian tribe or tribal organization shall also provide copies, for the information of the Secretary, of an initial schedule of values and updates as they may occur, and an initial construction schedule and updates as they occur. (8) The Indian tribe or tribal organization shall maintain on the job-site or project office, and make available to the Secretary during monitoring visits: contracts, major subcontracts, modifications, construction documents, change orders, shop drawings, equipment cut sheets, inspection reports, testing reports, and current redline drawings. (d) Upon completion of the project, the Indian tribe or tribal organization shall provide to the Secretary a reproducible copy of the record plans and a contract closeout report. (e) For cost-reimbursable projects, the Indian tribe or tribal organization shall not be obligated to continue performance that requires an expenditure of more funds than were awarded under the contract. If the Indian tribe or tribal organization has a reason to believe that the total amount required for performance of the contract will be greater than the amount of funds awarded, it shall provide reasonable notice to the Secretary. If the Secretary does not increase the amount of funds awarded under the contract, the Indian tribe or tribal organization may suspend performance of the contract until sufficient additional funds are awarded. (a) If the Indian tribe or tribal organization is contracting solely to perform construction management services either under this subpart or section 108 of the Act, the Secretary has the following responsibilities: (1) The Secretary is responsible for the successful completion of the project in accordance with the approved contract documents. In fulfilling those responsibilities, the Secretary shall consult with the Indian tribe or tribal organization on a regular basis as agreed to by the parties to facilitate the exchange of information between the Indian tribe or tribal organization and Secretary; (2) The Secretary shall provide the Indian tribe or tribal organization with regular opportunities to review work produced to determine compliance with the following documents: (i) The POR, during the conduct of design phase activities. The Secretary shall provide the Indian tribe or tribal organization with an opportunity to review the project construction documents at the concept phase, the schematic phase, the design development phase, and the final construction documents phase, or as otherwise negotiated. Upon receipt of project construction documents for review, the Indian tribe or tribal organization shall not take more than 21 days to make available to the Secretary any comments or objections to the construction documents as submitted by the Secretary. Resolution of any comments or objections shall be in accordance with dispute resolution procedures as agreed to by the parties and contained in the contract; or (ii) The project construction documents, during conduct of the construction phase activities. The Indian tribe or tribal organization shall have the right to conduct monthly or critical milestone on-site monitoring visits or as negotiated with the Secretary; (b) If the Indian tribe or tribal organization is contracting to perform design and/or construction phase activities, the Secretary shall have the following responsibilities: (1) In carrying out the responsibilities of this section, and specifically in carrying out review, comment, and approval functions under this section, the Secretary shall provide for full tribal participation in the decision making process and shall honor tribal preferences and recommendations to the greatest extent feasible. This includes promptly notifying the Indian tribe or tribal organization of any concerns or issues in writing that may lead to disapproval, meeting with the Indian tribe or tribal organization to discuss these concerns and issues and to share relevant information and documents, and making a good faith effort to resolve all issues and concerns of the Indian tribe or tribal organization. The time allowed for Secretarial review, comment, and approval shall be no more than 21 days per review unless a different time period is negotiated and specified in individual contracts. The 21-day time period may be extended if the Indian tribe or tribal organization agrees to the extension in writing. Disagreements over the Secretary's decisions in carrying out these responsibilities shall be handled under subpart N governing contract disputes under the Contract Disputes Act. (2) To the extent the construction project is subject to NEPA or other environmental laws, the appropriate Secretary shall make the final determination under such laws. All other environmentally related functions are contractible. (3) If the Indian tribe or tribal organization conducts planning activities under this subpart, the Secretary shall review and approve final planning documents for the project to ensure compliance with applicable planning standards. (4) When a contract or portion of a contract is for project construction activities, the Secretary may rely on the Indian tribe or tribal organization's cost estimate or the Secretary may obtain an independent government cost estimate that is derived from the final project plans and specifications. The Secretary shall obtain the cost estimate, if any, within 90 days or less of receiving the final plans and specifications from the Indian tribe or tribal organization and shall provide all supporting documentation of the independent cost estimate to the Indian tribe or tribal organization within the 90 day time limit. (5) If the contracted project involves design activities, the Secretary shall have the authority to review for general compliance with the contract requirements and provide written comments on the project plans and specifications only at the concept phase, the schematic phase, the design development phase and the final construction documents phase, and approve for general compliance with contract requirements the project plans and specifications only at the schematic phase and the final construction documents phase or as otherwise negotiated. (6) If the contracted project involves design activities, the Secretary reserves a royalty-free, nonexclusive, and irrevocable license to reproduce, publish or otherwise use, for Federal government purposes: (i) The copyright in any work developed under a contract or subcontract of this subpart; and (ii) Any rights of copyright to which an Indian tribe or tribal organization or a tribal subcontractor purchases ownership through this contract. (7) Changes that require an increase to the negotiated contract budget or an increase in the negotiated performance period or are a significant departure from the scope or objective of the project shall require approval of the Secretary. (8) Review and comment on specific shop drawings as negotiated and specified in individual contracts. (9) The Secretary may conduct monthly on-site monitoring visits, or alternatively if negotiated with the Indian tribe or tribal organization, critical milestone on-site monitoring visits. (10) The Secretary retains the right to conduct final project inspections jointly with the Indian tribe or tribal organization and to accept the building or facility. If the Secretary identifies problems during final project inspections the information shall be provide to the Indian tribe or tribal organization and shall be limited to items that are materially noncompliant. (11) The Secretary can require an Indian tribe or tribal organization to suspend work under a contract in accordance with this paragraph. The Secretary may suspend a contract for no more than 30 days unless the Indian tribe or tribal organization has failed to correct the reason(s) for the suspension or unless the cause of the suspension cannot be resolved through either the efforts of the Secretary or the Indian tribe or tribal organization. (i) The following are reasons the Secretary may suspend work under a self-determination contract for construction: (A) Differing site conditions encountered upon commencement of construction activities that impact health or safety concerns or shall require an increase in the negotiated project budget; (B) The Secretary discovers materially non-compliant work; (C) Funds allocated for the project that is the subject of this contract are rescinded by Congressional action; or (D) Other Congressional actions occur that materially affect the subject matter of the contract. (ii) If the Secretary wishes to suspend the work, the Secretary shall first provide written notice and an opportunity for the Indian tribe or tribal organization to correct the problem. The Secretary may direct the Indian tribe or tribal organization to suspend temporarily work under a contract only after providing a minimum of 5 working days' advance written notice to the Indian tribe or tribal organization describing the nature of the performance deficiencies or imminent safety, health or environmental issues which are the cause for suspending the work. (iii) The Indian tribe or tribal organization shall be compensated for reasonable costs, including but not limited to overhead costs, incurred due to any suspension of work that occurred through no fault of the Indian tribe or tribal organization. (iv) Disputes arising as a result of a suspension of the work by the Secretary shall be subject to the Contract Disputes Act or any other alternative dispute resolution mechanism as negotiated between and agreed to by the parties and contained in the contract. (12) The Secretary can terminate the project for cause in the event non-compliant work is not corrected through the suspension process specified in paragraph (11) of this section. (13) The Secretary retains authority to terminate the project for convenience for the following reasons: (i) Termination for convenience is requested by the Indian tribe or tribal organization; (ii) Termination for convenience is requested by the Secretary and agreed to by the Indian tribe or tribal organization; (iii) Funds allocated for the project that is the subject of the contract are rescinded by Congressional action; (iv) Other Congressional actions take place that affect the subject matter of the contract; (v) If the Secretary terminates a self-determination construction contract for convenience, the Secretary shall provide the Indian tribe or tribal organization 21 days advance written notice of intent to terminate a contract for convenience; or (vi) The Indian tribe or tribal organization shall be compensated for reasonable costs incurred due to termination of the contract. (a) A schedule for advance payments shall be developed based on progress, need, and other considerations in accordance with applicable law. The payment schedule shall be negotiated by the parties and included in the contract. The payment schedule may be adjusted as negotiated by the parties during the course of the project based on progress and need. (b) Payments shall be made to the Indian tribe or tribal organization according to the payment schedule contained in the contract. If the contract does not provide for the length of each allocation period, the Secretary shall make payments to the Indian tribe or tribal organization at least quarterly. Each allocation shall be adequate to provide funds for the contract activities anticipated to be conducted during the allocation period, except that: (1) The first allocation may be greater than subsequent allocations and include mobilization costs, and contingency funds described in §900.128(e)(8); and (2) Any allocation may include funds for payment for materials that will be used during subsequent allocation periods. (c) The Indian tribe or tribal organization may propose a schedule of payment amounts measured by time or measured by phase of the project (e.g., planning, design, construction). (d) The amount of each payment allocation shall be stated in the Indian tribe or tribal organization's contract proposal. Upon award of the contract, the Secretary shall transfer the amount of the first allocation to the Indian tribe or tribal organization within 21 days after the date of contract award. The second allocation shall be made not later than 7 days before the end of the first allocation period. (e) Not later than 7 days before the end of each subsequent allocation period after the second allocation, the Secretary shall transfer to the Indian tribe or tribal organization the amount for the next allocation period, unless the Indian tribe or tribal organization is delinquent in submission of allocation period progress reports and financial reports or the Secretary takes action to suspend or terminate the contract in accordance with §900.131(b)(11), §900.131(b)(12), or §900.131(b)(13). The Contract Disputes Act generally applies to such amendments. However, the declination process and the procedures in §900.122 and §900.123 apply to the proposal by an Indian tribe or tribal organization when the proposal is for a new project, a new phase or discreet stage of a phase of a project, or an expansion of a project resulting from an additional allocation of funds by the Secretary under §900.120. The savings shall be used by the Indian tribe or tribal organization to provide additional services or benefits under the contract. Unexpended contingency funds obligated to the contract, and remaining at the end of the contract, are savings. No further approval or justifying documentation by the Indian tribe or tribal organization shall be required before expenditure of funds. Yes. The time frames in this subpart are intended to be maximum times and may be reduced based on urgency and need, by agreement of the parties. If the Indian tribe or tribal organization requests reduced time frames for action due to unusual or special conditions (such as limited construction periods), the Secretary shall make a good faith effort to accommodate the requested time frames. Yes. Tribal employment rights ordinances do apply to construction contracts and subcontracts pursuant to section 7(b) and section 7(c) of the Act. Yes, except as otherwise provided in this subpart and unless excluded as follows: programmatic reports and data requirements, reassumption, contract review and approval process, contract proposal contents, and §900.150 (d) and (e) of these regulations. Yes. Upon the request of an Indian tribe or tribal organization, the Secretary shall waive any provision of these regulations, including any cost principles adopted by the regulations under this part, if the Secretary finds that granting the waiver is either in the best interest of the Indians served by the contract, or is consistent with the policies of the Act and is not contrary to statutory law. To obtain a waiver, an Indian tribe or tribal organization shall submit a written request to the Secretary identifying the regulation to be waived and the basis for the request. The Indian tribe or tribal organization shall explain the intended effect of the waiver, the impact upon the Indian tribe or tribal organization if the waiver is not granted, and the specific contract(s) to which the waiver will apply. No. Although a waiver request may be included in a contract proposal, it can also be submitted separately. The Secretary shall approve or deny a waiver within 90 days after the Secretary receives a written waiver request. The Secretary's decision shall be in writing. If the requested waiver is denied, the Secretary shall include in the decision a full explanation of the basis for the decision. The waiver request is deemed approved. Consistent with section 107(e) of the Act, the Secretary may only deny a waiver request based on a specific written finding. The finding must clearly demonstrate (or be supported by controlling legal authority) that if the waiver is granted: (a) The service to be rendered to the Indian beneficiaries of the particular program or function to be contracted will not be satisfactory; (b) Adequate protection of trust resources is not assured; (c) The proposed project or function to be contracted for cannot be properly completed or maintained by the proposed contract; (d) The amount of funds proposed under the contract is in excess of the applicable funding level for the contract, as determined under section 106(a) of the Act; or (e) The program, function, service, or activity (or portion of it) that is the subject of the proposal is beyond the scope of programs, functions, services, or activities that are contractible under the Act because the proposal includes activities that cannot lawfully be carried out by the contractor. Yes. Technical assistance is available as provided in §900.7 to prepare a waiver request or to overcome any stated objection which the Secretary might have to the request. If the Secretary denies a waiver request, the Indian tribe or tribal organization has the right to appeal the decision and request a hearing on the record under the procedures for hearings and appeals contained in subpart L of these regulations. Alternatively, the Indian tribe or tribal organization may sue in Federal district court to challenge the Secretary's action. Any Indian tribe or tribal organization may at any time submit a request to the Secretary for a determination that any law or regulation has been superseded by the Act and that the law has no applicability to any contract or proposed contract under the Act. The Secretary is required to provide an initial decision on such a request within 90 days after receipt. If such a request is denied, the Indian tribe or tribal organization may appeal under subpart L of these regulations. The Secretary shall provide notice of each determination made under this subpart to all Indian tribes and tribal organizations. (a) A decision to decline to award a self-determination contract, or a portion thereof, under section 102 of the Act; (b) A decision to decline to award a construction contract, or a portion thereof, under sections 105(m) and 102 of the Act; (c) A decision to decline a proposed amendment to a self-determination contract, or a portion thereof, under section 102 of the Act; (d) A decision not to approve a proposal, in whole or in part, to redesign a program; (e) A decision to rescind and reassume a self-determination contract, in whole or in part, under section 109 of the Act except for emergency reassumptions; (f) A decision to refuse to waive a regulation under section 107(e) of the Act; (g) A disagreement between an Indian tribe or tribal organization and the Federal government over proposed reporting requirements; (h) A decision to refuse to allow an Indian tribe or tribal organization to convert a contract to mature status, under section 4(h) of the Act; (i) All other appealable pre-award decisions by a Federal official as specified in these regulations, whether an official of the Department of the Interior or the Department of Health and Human Services; or (j) A decision relating to a request for a determination that a law or regulation has been superseded by the Act. This subpart does not cover: (a) Disputes which arise after a self-determination contract has been awarded, or emergency reassumption of self-determination contracts or suspension of payments under self-determination contracts, which are covered under §900.170 through §900.176 of these regulations. (b) Other post-award contract disputes, which are covered under subpart N. (c) Denials under the Freedom of Information Act, 5 U.S.C. 552, which may be appealed under 43 CFR 2 for the Department of the Interior and 45 CFR 5 for the Department of Health and Human Services; and (d) Decisions relating to the award of discretionary grants under section 103 of the Act, which may be appealed under 25 CFR 2 for the Department of the Interior, and under 45 CFR 5 for the Department of Health and Human Services. Every decision in any of the ten areas listed above shall contain information which shall tell the Indian tribe or tribal organization where and when to file the Indian tribe or tribal organization's appeal. Each decision shall include the following statement:
Within 30 days of the receipt of this decision, you may request an informal conference under 25 CFR 900.154, or appeal this decision under 25 CFR 900.158 to the Interior Board of Indian Appeals (IBIA). Should you decide to appeal this decision, you may request a hearing on the record. An appeal to the IBIA under 25 CFR 900.158 shall be filed with the IBIA by certified mail or by hand delivery at the following address: Board of Indian Appeals, U.S. Department of the Interior, 801 North Quincy Street, Arlington, VA 22203. You shall serve copies of your Notice of Appeal on the Secretary and on the official whose decision is being appealed. You shall certify to the IBIA that you have served these copies. Yes. The Indian tribe or tribal organization may request an informal conference. An informal conference is a way to resolve issues as quickly as possible, without the need for a formal hearing. The Indian tribe or tribal organization may also choose to sue in U.S. District Court under section 102(b)(3) and section 110(a) of the Act. The Indian tribe or tribal organization shall file its request for an informal conference with the office of the person whose decision it is appealing, within 30 days of the day it receives the decision. The Indian tribe or tribal organization may either hand-deliver the request for an informal conference to that person's office, or mail it by certified mail, return receipt requested. If the Indian tribe or tribal organization mails the request, it will be considered filed on the date the Indian tribe or tribal organization mailed it by certified mail. (a) The informal conference shall be held within 30 days of the date the request was received, unless the Indian tribe or tribal organization and the authorized representative of the Secretary agree on another date. (b) If possible, the informal conference will be held at the Indian tribe or tribal organization's office. If the meeting cannot be held at the Indian tribe or tribal organization's office and is held more than fifty miles from its office, the Secretary shall arrange to pay transportation costs and per diem for incidental expenses to allow for adequate representation of the Indian tribe or tribal organization. (c) The informal conference shall be conducted by a designated representative of the Secretary. (d) Only people who are the designated representatives of the Indian tribe or tribal organization, or authorized by the Secretary of Health and Human Services or by the appropriate agency of the Department of the Interior, are allowed to make presentations at the informal conference. (a) Within 10 days of the informal conference, the person who conducted the informal conference shall prepare and mail to the Indian tribe or tribal organization a written report which summarizes what happened at the informal conference and a recommended decision. (b) Every report of an informal conference shall contain the following language:
Within 30 days of the receipt of this recommended decision, you may file an appeal of the initial decision of the DOI or DHHS agency with the Interior Board of Indian Appeals (IBIA) under 25 CFR 900.157. You may request a hearing on the record. An appeal to the IBIA under 25 CFR 900.157 shall be filed with the IBIA by certified mail or hand delivery at the following address: Board of Indian Appeals, U.S. Department of the Interior, 801 North Quincy Street, Arlington, VA 22203. You shall serve copies of your Notice of Appeal on the Secretary and on the official whose decision is being appealed. You shall certify to the IBIA that you have served these copies. No. If the Indian tribe or tribal organization is dissatisfied with the recommended decision, it may still appeal the initial decision within 30 days of receiving the recommended decision and the report of the informal conference. If the Indian tribe or tribal organization does not file a notice of appeal within 30 days, or before the expiration of the extension it has received under §900.159, the recommended decision becomes final. (a) If the Indian tribe or tribal organization decides to appeal, it shall file a notice of appeal with the IBIA within 30 days of receiving either the initial decision or the recommended decision. (b) The Indian tribe or tribal organization may either hand-deliver the notice of appeal to the IBIA, or mail it by certified mail, return receipt requested. If the Indian tribe or tribal organization mails the Notice of Appeal, it will be considered filed on the date the Indian tribe or tribal organization mailed it by certified mail. The Indian tribe or tribal organization should mail the notice of appeal to: Board of Indian Appeals, U.S. Department of the Interior, 801 North Quincy Street, Arlington, VA 22203. (c) The Notice of Appeal shall: (1) Briefly state why the Indian tribe or tribal organization thinks the initial decision is wrong; (2) Briefly identify the issues involved in the appeal; and (3) State whether the Indian tribe or tribal organization wants a hearing on the record, or whether the Indian tribe or tribal organization wants to waive its right to a hearing. (d) The Indian tribe or tribal organization shall serve a copy of the notice of appeal upon the official whose decision it is appealing. The Indian tribe or tribal organization shall certify to the IBIA that it has done so. (e) The authorized representative of the Secretary of Health and Human Services or the authorized representative of the Secretary of the Interior will be considered a party to all appeals filed with the IBIA under the Act. Yes. If the Indian tribe or tribal organization needs more time, it can request an extension of time to file its Notice of Appeal within 60 days of receiving either the initial decision or the recommended decision resulting from the informal conference. The request of the Indian tribe or tribal organization shall be in writing, and shall give a reason for not filing its notice of appeal within the 30-day time period. If the Indian tribe or tribal organization has a valid reason for not filing its notice of appeal on time, it may receive an extension from the IBIA. (a) Within 5 days of receiving the Indian tribe or tribal organization's notice of appeal, the IBIA will decide whether the appeal falls under §900.150(a) through §900.150(g). If so, the Indian tribe or tribal organization is entitled to a hearing. (1) If the IBIA determines that the appeal of the Indian tribe or tribal organization falls under §900.150(h), §900.150(i), or §900.150(j), and the Indian tribe or tribal organization has requested a hearing, the IBIA will grant the request for a hearing unless the IBIA determines that there are no genuine issues of material fact to be resolved. (2) If the IBIA cannot make that decision based on the information included in the notice of appeal, the IBIA may ask for additional statements from the Indian tribe or tribal organization, or from the appropriate Federal agency. If the IBIA asks for more statements, it will make its decision within 5 days of receiving those statements. (b) If the IBIA decides that the Indian tribe or tribal organization is not entitled to a hearing or if the Indian tribe or tribal organization has waived its right to a hearing on the record, the IBIA will ask for the administrative record under 43 CFR 4.335. The IBIA shall tell the parties that the appeal will be considered under the regulations at 43 CFR 4, subpart D, except the case shall be docketed immediately, without waiting for the 20-day period described in 43 CFR 4.336. (a) If a hearing is to be held, the IBIA will refer the Indian tribe or tribal organization's case to the Hearings Division of the Office of Hearings and Appeals of the U.S. Department of the Interior. The case will then be assigned to an Administrative Law Judge (ALJ), appointed under 5 U.S.C. 3105. (b) Within 15 days of the date of the referral, the ALJ will hold a pre-hearing conference, by telephone or in person, to decide whether an evidentiary hearing is necessary, or whether it is possible to decide the appeal based on the written record. At the pre-hearing conference the ALJ will provide for: (1) A briefing and discovery schedule; (2) A schedule for the exchange of information, including, but not limited to witness and exhibit lists, if an evidentiary hearing is to be held; (3) The simplification or clarification of issues; (4) The limitation of the number of expert witnesses, or avoidance of similar cumulative evidence, if an evidentiary hearing is to be held; (5) The possibility of agreement disposing of all or any of the issues in dispute; and (6) Such other matters as may aid in the disposition of the appeal. (c) The ALJ shall order a written record to be made of any conference results that are not reflected in a transcript. (a) The ALJ shall hold a hearing within 60 days of the date of the order referring the appeal to the ALJ, unless the parties agree to have the hearing on a later date. (b) At least 30 days before the hearing, the government agency shall file and serve the Indian tribe or tribal organization with a response to the notice of appeal. (c) If the hearing is held more than 50 miles from the Indian tribe or tribal organization's office, the Secretary shall arrange to pay transportation costs and per diem for incidental expenses to allow for adequate representation of the Indian tribe or tribal organization. (d) The hearing shall be conducted in accordance with the Administrative Procedure Act, 5 U.S.C. 556. For those appeals, the Secretary has the burden of proof (as required by section 102(e)(1) of the Act) to establish by clearly demonstrating the validity of the grounds for declining the contract proposal. Both the Indian tribe or tribal organization and the government agency have the same rights during the appeal process. These rights include the right to: (a) Be represented by legal counsel; (b) Have the parties provide witnesses who have knowledge of the relevant issues, including specific witnesses with that knowledge, who are requested by either party; (c) Cross-examine witnesses; (d) Introduce oral or documentary evidence, or both; (e) Require that oral testimony be under oath; (f) Receive a copy of the transcript of the hearing, and copies of all documentary evidence which is introduced at the hearing; (g) Compel the presence of witnesses, or the production of documents, or both, by subpoena at hearings or at depositions; (h) Take depositions, to request the production of documents, to serve interrogatories on other parties, and to request admissions; and (i) Any other procedural rights under the Administrative Procedure Act, 5 U.S.C. 556. (a) Within 30 days of the end of the formal hearing or any post-hearing briefing schedule established by the ALJ, the ALJ shall send all the parties a recommended decision, by certified mail, return receipt requested. The recommended decision shall contain the ALJ's findings of fact and conclusions of law on all the issues. The recommended decision shall also state that the Indian tribe or tribal organization has the right to object to the recommended decision. (b) If the appeal involves the Department of Health and Human Services, the recommended decision shall contain the following statement:
Within 30 days of the receipt of this recommended decision, you may file an objection to the recommended decision with the Secretary of Health and Human Services under 25 CFR 900.165(b). An appeal to the Secretary under 25 CFR 900.165(b) shall be filed at the following address: Department of Health and Human Services, 200 Independence Ave. S.W., Washington, DC, 20201. You shall serve copies of your notice of appeal on the official whose decision is being appealed. You shall certify to the Secretary that you have served this copy. If neither party files an objection to the recommended decision within 30 days, the recommended decision will become final. (c) If the appeal involves the Department of the Interior, the recommended decision shall contain the following statement:
Within 30 days of the receipt of this recommended decision, you may file an objection to the recommended decision with the Interior Board of Indian Appeals (IBIA) under 25 CFR 900.165(c). An appeal to the IBIA under 25 CFR 900.165(c) shall be filed at the following address: Board of Indian Appeals, 801 North Quincy Street, Arlington, VA 22203. You shall serve copies of your notice of appeal on the Secretary of the Interior, and on the official whose decision is being appealed. You shall certify to the IBIA that you have served these copies. If neither party files an objection to the recommended decision within 30 days, the recommended decision will become final. No. Any party to the appeal may file precise and specific written objections to the recommended decision, or any other comments, within 30 days of receiving the recommended decision. Objections shall be served on all other parties. The recommended decision shall become final 30 days after the Indian tribe or tribal organization receives the ALJ's recommended decision, unless a written statement of objections is filed with the Secretary of Health and Human Services or the IBIA during the 30-day period. If no party files a written statement of objections within 30 days, the recommended decision shall become final. (a) The Secretary of Health and Human Services or the IBIA has 20 days from the date it receives any timely written objections to modify, adopt, or reverse the recommended decision. If the Secretary of Health and Human Services or the IBIA does not modify or reverse the recommended decision during that time, the recommended decision automatically becomes final. (b) When reviewing the recommended decision, the IBIA or the Secretary may consider and decide all issues properly raised by any party to the appeal, based on the record. (c) The decision of the Secretary or the IBIA shall: (1) Be in writing; (2) Specify the findings of fact or conclusions of law which are modified or reversed; (3) Give reasons for the decision, based on the record; and (4) State that the decision is final for the Department. No. A pending appeal will not affect or prevent the negotiation or award of another contract. Yes. The Secretary shall publish all final decisions from the ALJs, the IBIA, and the Secretary of Health and Human Services. (a) This subpart applies when the Secretary gives notice to an Indian tribe or tribal organization that the Secretary intends to: (1) Immediately rescind a contract or grant and reassume a program; or (2) Suspend, withhold, or delay payment under a contract. (b) When the Secretary advises an Indian tribe or tribal organization that the Secretary intends to take an action referred to in paragraph (a)(1) of this section, the Secretary shall also notify the Deputy Director of the Office of Hearings and Appeals, Department of the Interior, 801 North Quincy Street, Arlington, VA 22203. Yes. The Deputy Director of the Office of Hearings and Appeals shall appoint an Administrative Law Judge (ALJ) to hold a hearing. (a) The hearing shall be held within 10 days of the date of the notice referred to in §900.170 unless the Indian tribe or tribal organization agrees to a later date. (b) If possible, the hearing will be held at the office of the Indian tribe or tribal organization. If the hearing is held more than 50 miles from the office of the Indian tribe or tribal organization, the Secretary shall arrange to pay transportation costs and per diem for incidental expenses. This will allow for adequate representation of the Indian tribe or tribal organization. (a) Within 30 days after the end of the hearing or any post-hearing briefing schedule established by the ALJ, the ALJ shall send all parties a recommended decision by certified mail, return receipt requested. The recommended decision shall contain the ALJ's findings of fact and conclusions of law on all the issues. The recommended decision shall also state that the Indian tribe or tribal organization has the right to object to the recommended decision. (b) If the appeal involves the Department of Health and Human Services, the recommended decision shall contain the following statement:
Within 15 days of the receipt of this recommended decision, you may file an objection to the recommended decision with the Secretary of Health and Human Services under 25 CFR 900.165(b). An appeal to the Secretary under 25 CFR 900.165(b) shall be filed at the following address: Department of Health and Human Services, 200 Independence Ave. S.W., Washington, DC 20201. You shall serve copies of your notice of appeal on the official whose decision is being appealed. You shall certify to the Secretary that you have served this copy. If neither party files an objection to the recommended decision within 15 days, the recommended decision will become final. (c) If the appeal involves the Department of the Interior, the recommended decision shall contain the following statement:
Within 15 days of the receipt of this recommended decision, you may file an objection to the recommended decision with the Interior Board of Indian Appeals (IBIA) under 25 CFR 900.165(c). An appeal to the IBIA under 25 CFR 900.165(c) shall be filed at the following address: Board of Indian Appeals, 801 North Quincy Street, Arlington, VA 22203. You shall serve copies of your notice of appeal on the Secretary of the Interior, and on the official whose decision is being appealed. You shall certify to the IBIA that you have served these copies. If neither party files an objection to the recommended decision within 15 days, the recommended decision will become final. No. Any party to the appeal may file precise and specific written objections to the recommended decision, or any other comments, within 15 days of receiving the recommended decision. You shall serve a copy of your objections on the other party. The recommended decision will become final 15 days after the Indian tribe or tribal organization receives the ALJ's recommended decision, unless a written statement of objections is filed with the Secretary of Health and Human Services or the IBIA during the 15-day period. If no party files a written statement of objections within 15 days, the recommended decision will become final. (a) The Secretary or the IBIA has 15 days from the date he/she receives timely written objections to modify, adopt, or reverse the recommended decision. If the Secretary or the IBIA does not modify or reverse the recommended decision during that time, the recommended decision automatically becomes final. (b) When reviewing the recommended decision, the IBIA or the Secretary may consider and decide all issues properly raised by any party to the appeal, based on the record. (c) The decision of the Secretary or of the IBIA shall: (1) Be in writing; (2) Specify the findings of fact or conclusions of law which are modified or reversed; (3) Give reasons for the decision, based on the record; and (4) State that the decision is final for the Department. No. A pending appeal will not affect or prevent the negotiation or award of another contract. Yes. The Secretary shall publish all final decisions from the ALJs, the IBIA, and the Secretary of Health and Human Services. Yes. EAJA claims against the DOI or the DHHS will be heard by the IBIA under 43 CFR 4.601–4.619. For DHHS, appeals from the EAJA award will be according to 25 CFR 900.165(b). This subpart explains the applicability of the Federal Tort Claims Act (FTCA). This section covers: (a) Coverage of claims arising out of the performance of medical-related functions under self-determination contracts; (b) Coverage of claims arising out of the performance of non-medical-related functions under self-determination contracts; and (c) Procedures for filing claims under FTCA. Indian contractor means: (1) In California, subcontractors of the California Rural Indian Health Board, Inc. or, subject to approval of the IHS Director after consultation with the DHHS Office of General Counsel, subcontractors of an Indian tribe or tribal organization which are: (i) Governed by Indians eligible to receive services from the Indian Health Service; (ii) Which carry out comprehensive IHS service programs within geographically defined service areas; and (iii) Which are selected and identified through tribal resolution as the local provider of Indian health care services. (2) Subject to the approval of the IHS Director after consultation with the DHHS Office of General Counsel, Indian tribes and tribal organizations which meet in all respects the requirements of the Indian Self-Determination Act to contract directly with the Federal Government but which choose through tribal resolution to subcontract to carry out IHS service programs within geographically defined service areas with another Indian tribe or tribal organization which contracts directly with IHS. (3) Any other contractor that qualifies as an “Indian contractor” under the Indian Self-Determination Act. A number of other statutes and regulations apply to FTCA coverage, including the Federal Tort Claims Act (28 U.S.C. 1346(b), 2401, 2671–2680) and related Department of Justice regulations in 28 CFR part 14. Yes. There are claims against self-determination contractors which are not covered by FTCA, claims which may not be pursued under FTCA, and remedies that are excluded by FTCA. General guidance is provided below as to these matters but is not intended as a definitive description of coverage, which is subject to review by the Department of Justice and the courts on a case-by-case basis. (a) What claims are expressly barred by FTCA and therefore may not be made against the United States, an Indian tribe or tribal organization? Any claim under 28 U.S.C. 2680, including claims arising out of assault, battery, false imprisonment, false arrest, malicious prosecution, abuse of process, libel, slander, misrepresentation, deceit, or interference with contract rights, unless otherwise authorized by 28 U.S.C. 2680(h). (b) What claims may not be pursued under FTCA? (1) Except as provided in §900.181(a)(1) and §900.189, claims against subcontractors arising out of the performance of subcontracts with a self-determination contractor; (2) Claims for on-the-job injuries which are covered by workmen's compensation; (3) Claims for breach of contract rather than tort claims; or (4) Claims resulting from activities performed by an employee which are outside the scope of employment. (c) What remedies are expressly excluded by FTCA and therefore are barred? (1) Punitive damages, unless otherwise authorized by 28 U.S.C. 2674; and (2) Other remedies not permitted under applicable state law. Yes. Claims shall be filed within 2 years of the date of accrual. (28 U.S.C. 2401). Six months. No, it is optional. At the request of Indian tribes and tribal organizations, self-determination contracts shall include the following clauses to clarify the scope of FTCA coverage: (a) The following clause may be used for all contracts:
For purposes of Federal Tort Claims Act coverage, the contractor and its employees (including individuals performing personal services contracts with the contractor to provide health care services) are deemed to be employees of the Federal government while performing work under this contract. This status is not changed by the source of the funds used by the contractor to pay the employee's salary and benefits unless the employee receives additional compensation for performing covered services from anyone other than the contractor. (b) The following clause is for IHS contracts only:
Under this contract, the contractor's employee may be required as a condition of employment to provide health services to non-IHS beneficiaries in order to meet contractual obligations. These services may be provided in either contractor or non-contractor facilities. The employee's status for Federal Tort Claims Act purposes is not affected. Yes. (a) The contractor shall designate an individual to serve as tort claims liaison with the Federal government. (b) As part of the notification required by 28 U.S.C. 2679(c), the contractor shall notify the Secretary immediately in writing of any tort claim (including any proceeding before an administrative agency or court) filed against the contractor or any of its employees that relates to performance of a self-determination contract or subcontract. (c) The contractor, through its designated tort claims liaison, shall assist the appropriate Federal agency in preparing a comprehensive, accurate, and unbiased report of the incident so that the claim may be properly evaluated. This report should be completed within 60 days of notification of the filing of the tort claim. The report should be complete in every significant detail and include as appropriate: (1) The date, time and exact place of the accident or incident; (2) A concise and complete statement of the circumstances of the accident or incident; (3) The names and addresses of tribal and/or Federal employees involved as participants or witnesses; (4) The names and addresses of all other eyewitnesses; (5) An accurate description of all government and other privately-owned property involved and the nature and amount of damage, if any; (6) A statement as to whether any person involved was cited for violating a Federal, State or tribal law, ordinance, or regulation; (7) The contractor's determination as to whether any of its employees (including Federal employees assigned to the contractor) involved in the incident giving rise to the tort claim were acting within the scope of their employment in carrying out the contract at the time the incident occurred; (8) Copies of all relevant documentation, including available police reports, statements of witnesses, newspaper accounts, weather reports, plats and photographs of the site or damaged property, such as may be necessary or useful for purposes of claim determination by the Federal agency; and (9) Insurance coverage information, copies of medical bills, and relevant employment records. (d) The contractor shall cooperate with and provide assistance to the U.S. Department of Justice attorneys assigned to defend the tort claim, including, but not limited to, case preparation, discovery, and trial. (e) If requested by the Secretary, the contractor shall make an assignment and subrogation of all the contractor's rights and claims (except those against the Federal government) arising out of a tort claim against the contractor. (f) If requested by the Secretary, the contractor shall authorize representatives of the Secretary to settle or defend any claim and to represent the contractor in or take charge of any action. If the Federal government undertakes the settlement or defense of any claim or action the contractor shall provide all reasonable additional assistance in reaching a settlement or asserting a defense. No. Subcontractors or subgrantees providing services to a Public Law 93–638 contractor or grantee are generally not covered. The only exceptions are Indian contractors such as those under subcontract with the California Rural Indian Health Board to carry out IHS programs in geographically defined service areas in California and personal services contracts under §900.193 (for §900.183(b)(1)) or §900.183(b) (for §900.190). Yes, except as explained in §900.183(b). No claim may be filed against a self-determination contractor or employee for personal injury or death arising from the performance of medical, surgical, dental, or related functions by the contractor in carrying out self-determination contracts under the Act. Related functions include services such as those provided by nurses, laboratory and x-ray technicians, emergency medical technicians and other health care providers including psychologists and social workers. All such claims shall be filed against the United States and are subject to the limitations and restrictions of the FTCA. Yes. For the purpose of Federal Tort Claims Act coverage, an Indian tribe or tribal organization and its employees performing medical-related functions under a self-determination contract are deemed a part of the Public Health Service if the employees are acting within the scope of their employment in carrying out the contract. (a) Permanent employees; (b) Temporary employees; (c) Persons providing services without compensation in carrying out a contract; (d) Persons required because of their employment by a self-determination contractor to serve non-IHS beneficiaries (even if the services are provided in facilities not owned by the contractor); and (e) Federal employees assigned to the contract. Yes. The coverage extends to individual personal services contractors providing health services in such a facility, including a facility owned by an Indian tribe or tribal organization but operated under a self-determination contract with IHS. Yes. Those services are covered, as long as the contractor's health care practitioners do not receive additional compensation from a third party for the performance of these services and they are acting within the scope of their employment under a self-determination contract. Reciprocal services include: (a) Cross-covering other medical personnel who temporarily cannot attend their patients; (b) Assisting other personnel with surgeries or other medical procedures; (c) Assisting with unstable patients or at deliveries; or (d) Assisting in any patient care situation where additional assistance by health care personnel is needed. No. Yes, if the services are provided in carrying out a self-determination contract. (An emergency motor vehicle is a vehicle, whether government, contractor, or employee-owned, used to transport passengers for medical services.) Yes, as long as the services out of which the claim arose were performed in carrying out the self-determination contract. Yes. Yes, health care practitioners with staff privileges in a facility operated by a contractor are covered when they perform services to IHS beneficiaries. Such personnel are not covered when providing services to non-IHS beneficiaries. Yes. Non-Indian individuals served under the contract whether or not on a fee-for-service basis, may assert claims under this subpart. Claims should be filed on Standard Form 95 (Claim for Damage, Injury or Death) or by submitting comparable written information (including a definite amount of monetary damage claimed) with the Chief, PHS Claims Branch, Room 18–20, Parklawn Building, 5600 Fishers Lane, Rockville, MD 20857, or at such other address as shall have been provided to the contractor in writing. They should immediately forward the claim to the PHS Claims Branch at the address indicated in §900.201 and notify the contractor's tort claims liaison. As part of the notification required by 28 U.S.C. 2679(c), the contractor should immediately inform the Chief, Litigation Branch, Business and Administrative Law Division, Office of General Counsel, Department of Health and Human Services, 330 Independence Avenue SW., Room 5362, Washington, DC 20201, and the contractor's tort claims liaison, and forward the following materials: (a) Four copies of the claimant's medical records of treatment, inpatient and outpatient, and any related correspondence, as well as reports of consultants; (b) A narrative summary of the care and treatment involved; (c) The names and addresses of all personnel who were involved in the care and treatment of the claimant; (d) Any comments or opinions that the employees who treated the claimant believe to be pertinent to the allegations contained in the claim; and (e) Other materials identified in §900.188(c). Yes. Except as explained in §900.183(b), no claim may be filed against a self-determination contractor or employee based upon performance of non-medical-related functions under a self-determination contract. Claims of this type must be filed against the United States under FTCA. It applies to: (a) All tort claims arising from the performance of self-determination contracts under the authority of the Act on or after October 1, 1989; and (b) Any tort claims first filed on or after October 24, 1989, regardless of when the incident which is the basis of the claim occurred. (a) Permanent employees; (b) Temporary employees; (c) Persons providing services without compensation in carrying out a contract; (d) Persons required because of their employment by a self-determination contractor to serve non-IHS beneficiaries (even if the services are provided in facilities not owned by the contractor); and (e) Federal employees assigned to the contract. Non-medical-related tort claims and lawsuits arising out of the performance of self-determination contracts with the Indian Health Service should be filed in the manner described in §900.201 (for both §900.207 and §900.208). Non-medical-related claims arising out of the performance of self-determination contracts with the Secretary of the Interior should be filed in the manner described in §900.201 with the Assistant Solicitor, Procurement and Patents, Office of the Solicitor, Department of the Interior, Room 6511, 1849 C Street NW., Washington, DC 20240. (a) If the contract is with DHHS, they should immediately forward the claim to the PHS Claims Branch at the address indicated in §900.201 and notify the contractor's tort claims liaison. (b) If the contract is with DOI, they should immediately notify the Assistant Solicitor, Procurement and Patents, Office of the Solicitor, Department of the Interior, Room 6511, 1849 C Street N.W., Washington, DC 20240. (a) If the contract is with the DHHS, they should immediately inform the Chief, Litigation Branch, Business and Administrative Law Division, Office of General Counsel, Department of Health and Human Services, 330 Independence Avenue S.W., Room 5362, Washington, DC 20201 and the contractor's tort claims liaison. (b) If the contract is with the Department of the Interior, they should immediately notify the Assistant Solicitor, Procurement and Patents, Office of the Solicitor, Department of the Interior, Room 6511, 1849 C Street N.W., Washington, DC 20240, and the contractor's tort claims liaison. (a) This subpart covers: (1) All HHS and DOI self-determination contracts, including construction contracts; and (2) All disputes regarding an awarding official's decision relating to a self-determination contract. (b) This subpart does not cover the decisions of an awarding official that are covered under subpart L. (a) The Contract Disputes Act of 1978 (CDA), Public Law 95–563 (41 U.S.C. 601 as amended); (b) If the matter is submitted to the Interior Board of Contract Appeals, 43 CFR 4.110–126; and (c) The Equal Access to Justice Act, 5 U.S.C. 504 and 28 U.S.C. 2412 and regulations at 43 CFR 4.601 through 4.619 (DOI) and 45 CFR 13 (DHHS). No. The Federal government attempts to resolve all contract disputes by agreement at the awarding official's level. These are alternatives to filing a claim under the CDA: (a) Before issuing a decision on a claim, the awarding official should consider using informal discussions between the parties, assisted by individuals who have not substantially participated in the matter, to aid in resolving differences. (b) In addition to filing a CDA claim, or instead of filing a CDA claim, the parties may choose to use an alternative dispute resolution mechanism, pursuant to the provisions of the Administrative Dispute Resolution Act, Public Law 101–552, as amended, 5 U.S.C. 581 et seq., or the options listed in section 108(1)(b)(12) of the Indian Self-Determination Act, as applicable. (a) A claim is a written demand by one of the contracting parties, asking for one or more of the following: (1) Payment of a specific sum of money under the contract; (2) Adjustment or interpretation of contract terms; or (3) Any other claim relating to the contract. (b) However, an undisputed voucher, invoice, or other routing request for payment is not a claim under the CDA. A voucher, invoice, or routing request for payment may be converted into a CDA claim if: (1) It is disputed as to liability or amount; or (2) It is not acted upon in a reasonable time and written notice of the claim is given to the awarding official by the senior official designated in the contract. (a) An Indian tribe or tribal organization shall submit its claim in writing to the awarding official. The awarding official shall document the contract file with evidence of the date the claim was received. (b) A Federal agency shall submit its claim in writing to the contractor's senior official, as designated in the contract. Yes. The Contract Disputes Act requires that an Indian tribe or tribal organization making a claim for more than $100,000 shall certify that: (a) The claim is made in good faith, (b) Supporting documents or data are accurate and complete to the best of the Indian tribe or tribal organization's knowledge and belief; (c) The amount claimed accurately reflects the amount believed to be owed by the Federal government; and (d) The person making the certification is authorized to do so on behalf of the Indian tribe or tribal organization. (a) If the parties do not agree on a settlement, the awarding official will issue a written decision on the claim. (b) The awarding official shall always give a copy of the decision to the Indian tribe or tribal organization by certified mail, return receipt requested, or by any other method which provides a receipt. A decision shall: (a) Describe the claim or dispute; (b) Refer to the relevant terms of the contract; (c) Set out the factual areas of agreement and disagreement; (d) Set out the actual decision, based on the facts, and outline the reasoning which supports the decision; and (e) Contain the following language:
This is a final decision. You may appeal this decision to the Interior Board of Contract Appeals (IBCA), U.S. Department of the Interior, 801 North Quincy Street, Arlington, VA 22203. If you decide to appeal, you shall, within 90 days from the date you receive this decision, mail or otherwise furnish written notice to the IBCA and provide a copy to the individual from whose decision the appeal is taken. The notice shall indicate that an appeal is intended, and refer to the decision and contract number. Instead of appealing to the IBCA, you may bring an action in the U.S. Court of Federal Claims or in the United States District Court within 12 months of the date you receive this notice. (a) If the claim is for more than $100,000, the awarding official shall issue the decision within 60 days of the day he or she receives the claim. If the awarding official cannot issue a decision that quickly, he or she shall tell you when the decision will be issued. (b) If the claim is for $100,000 or less, and you want a decision within 60 days, you shall advise the awarding official in writing that you want a decision within that period. If you advise the awarding official in writing that you do want a decision within 60 days, the awarding official shall issue the decision within 60 days of the day he or she receives your written notice. (c) If your claim is for $100,000 or less and you do not advise the awarding official that you want a decision within 60 days, or if your claim exceeds $100,000 and the awarding official has notified you of the time within which a decision will be issued, the awarding official shall issue a decision within a reasonable time. What is “reasonable” depends upon the size and complexity of your claim, and upon the adequacy of the information you have given to the awarding official in support of your claim. If the awarding official does not issue a decision within the time required under §900.223, the Indian tribe or tribal organization may treat the delay as though the awarding official has denied the claim, and proceed according to §900.222(e), Yes. Once the awarding official decides that money should be paid under the contract, the amount due, minus any portion already paid, should be paid as promptly as possible, without waiting for either party to file an appeal. Any payment which is made under this subsection will not affect any other rights either party might have. In addition, it will not create a binding legal precedent as to any future payments. In any appeal involving a disallowance of costs, the Board of Contract Appeals will give due consideration to the factual circumstances giving rise to the disallowed costs, and shall seek to determine a fair result without rigid adherence to strict accounting principles. The determination of allowability shall assure fair compensation for the work or service performed, using cost and accounting data as guides, but not rigid measures, for ascertaining fair compensation. (a) The decision of the awarding official is final and conclusive, and not subject to review by any forum, tribunal or government agency, unless an appeal or suit is timely commenced as authorized by the Contract Disputes Act. Once the decision has been made, the awarding official may not change it, except by agreement of the parties, or under the following limited circumstances: (1) If evidence is discovered which could not have been discovered through due diligence before the awarding official issued the decision; (2) If the awarding official learns that there has been fraud, misrepresentation, or other misconduct by a party; (3) If the decision is beyond the scope of the awarding official's authority; (4) If the claim has been satisfied, released or discharged; or (5) For any other reason justifying relief from the decision. (b) Nothing in this subpart shall be interpreted to discourage settlement discussions or prevent settlement of the dispute at any time. (c) If a decision is withdrawn and a new decision is issued that is not acceptable to the contractor, the contractor may proceed with the appeal based on the new decision. If no new decision is issued, the contractor may proceed under §900.224. (d) If an appeal or suit is filed, the awarding official may modify or withdraw his or her final decision. Yes. If an Indian tribe or tribal organization wins the claim, it will be entitled to interest on the amount of the award. The interest will be calculated from the date the awarding official receives the claim until the day it is paid. The interest rate will be the rate which the Secretary of the Treasury sets for the Renegotiation Board under the Renegotiation Act of 1951, Public Law 92–41, 26 U.S.C. 1212 and 26 U.S.C. 7447. (a) The awarding official shall provide any data, documentation, information or support required by the IBCA for use in deciding a pending appeal. (b) Within 30 days of receiving an appeal or learning that an appeal has been filed, the awarding official shall assemble a file which contains all the documents which are pertinent to the appeal, including: (1) The decision and findings of fact from which the appeal is taken; (2) The contract, including specifications and pertinent modifications, plans and drawings; (3) All correspondence between the parties which relates to the appeal, including the letter or letters of claims in response to which the decision was issued; (4) Transcripts of any testimony taken during the course of the proceedings, and affidavits or statements of any witnesses on the matter in dispute, which were made before the filing of the notice of appeal with the IBCA; and (5) Any additional information which may be relevant. (a) Indian tribes and tribal organizations shall continue performance of a contract during the appeal of any claims to the same extent they would had there been no dispute. (b) A pending dispute will not affect or bar the negotiation or award of any subsequent contract or negotiation between the parties. An organizational conflict of interest arises when there is a direct conflict between the financial interests of the contracting Indian tribe or tribal organization and: (a) The financial interests of beneficial owners of Indian trust resources; (b) The financial interests of the United States relating to trust resources, trust acquisitions, or lands conveyed or to be conveyed pursuant to the Alaska Native Claims Settlement Act 43 U.S.C. 1601 et seq.; or (c) An express statutory obligation of the United States to third parties. This section only applies if the conflict was not addressed when the contract was first negotiated. This section only applies where the financial interests of the Indian tribe or tribal organization are significant enough to impair the Indian tribe or tribal organization's objectivity in carrying out the contract, or a portion of the contract. This section only applies if the conflict was not addressed when the contract was first negotiated. When an Indian tribe or tribal organization becomes aware of an organizational conflict of interest, the Indian tribe or tribal organization must immediately disclose the conflict to the Secretary. An Indian tribe or tribal organization must maintain written standards of conduct to govern officers, employees, and agents (including subcontractors) engaged in functions related to the management of trust assets. The Indian tribe or tribal organization would need a tribally-approved mechanism to ensure that no officer, employee, or agent (including a subcontractor) of the Indian tribe or tribal organization reviews a trust transaction in which that person has a financial or employment interest that conflicts with that of the trust beneficiary, whether the tribe or an allottee. Interests arising from membership in, or employment by, an Indian tribe or rights to share in a tribal claim need not be regulated. The standards must prohibit an officer, employee, or agent (including a subcontractor) from participating in the review, analysis, or inspection of trust transactions involving an entity in which such persons have a direct financial interest or an employment relationship. It must also prohibit such officers, employees, or agents from accepting any gratuity, favor, or anything of more than nominal value, from a party (other than the Indian tribe) with an interest in the trust transactions under review. Such standards must also provide for sanctions or remedies for violation of the standards. Yes. An Indian tribe and the Secretary may agree to contract provisions, concerning either personal or organizational conflicts, that address the issues specific to the program and activities contracted in a manner that provides equivalent protection against conflicts of interest to these regulations. Agreed-upon contract provisions shall be followed, rather than the related provisions of this regulation. For example, the Indian tribe and the Secretary may agree that using the Indian tribe's own written code of ethics satisfies the objectives of the personal conflicts provisions of this regulation, in whole or in part. A retrocession means the return to the Secretary of a contracted program, in whole or in part, for any reason, before the expiration of the term of the contract. An Indian tribe or tribal organization authorized by an Indian tribe may retrocede a contract. The retrocession is effective on the date which is the earliest date among: (a) One year from the date of the Indian tribe or tribal organization's request; (b) The date the contract expires; or (c) A mutually agreed-upon date. An Indian tribe or tribal organization's retrocession shall not negatively affect: (a) Any other contract to which it is a party; (b) Any other contracts it may request; and (c) Any future request by the Indian tribe or tribal organization to contract for the same program. No. The Secretary shall provide not less than the same level of funding that would have been available if there had been no retrocession. On the effective date of any retrocession, the Indian tribe or tribal organization shall, at the request of the Secretary, deliver to the Secretary all requested property and equipment provided under the contract which have a per item current fair market value, less the cost of improvements borne by the Indian tribe or tribal organization, in excess of $5,000 at the time of the retrocession. Reassumption means rescission, in whole or in part, of a contract and assuming or resuming control or operation of the contracted program by the Secretary without consent of the Indian tribe or tribal organization. There are two types of reassumption: emergency and non-emergency. (a) A reassumption is considered an emergency reassumption if an Indian tribe or tribal organization fails to fulfill the requirements of the contract and this failure poses: (1) An immediate threat of imminent harm to the safety of any person; or (2) Imminent substantial and irreparable harm to trust funds, trust lands, or interest in such lands. (b) A reassumption is considered a non-emergency reassumption if there has been: (1) A violation of the rights or endangerment of the health, safety, or welfare of any person; or (2) Gross negligence or mismanagement in the handling or use of: (i) Contract funds; (ii) Trust funds; (iii) Trust lands; or (iv) Interests in trust lands under the contract. The Secretary must: (a) Notify the Indian tribes or tribal organizations served by the contract and the contractor in writing by certified mail of the details of the deficiencies in contract performance; (b) Request specified corrective action to be taken within a reasonable period of time, which in no case may be less than 45 days; and (c) Offer and provide, if requested, the necessary technical assistance and advice to assist the contractor to overcome the deficiencies in contract performance. The Secretary may also make a grant for the purpose of obtaining such technical assistance as provided in section 103 of the Act. The Secretary shall provide a second written notice by certified mail to the Indian tribes or tribal organizations served by the contract and the contractor that the contract will be rescinded, in whole or in part. The second written notice shall include: (a) The intended effective date of the reassumption; (b) The details and facts supporting the intended reassumption; and (c) Instructions that explain the Indian tribe or tribal organization's right to a formal hearing within 30 days of receipt of the notice. The contract will not be rescinded by the Secretary before the issuance of a final decision in any administrative hearing or appeal. (a) Immediately rescind, in whole or in part, the contract; (b) Assume control or operation of all or part of the program; and (c) Give written notice to the contractor and the Indian tribes or tribal organizations served. The written notice shall include the following: (a) A detailed statement of the findings which support the Secretary's determination; (b) A statement explaining the contractor's right to a hearing on the record under §900.160 and §900.161 within 10 days of the emergency reassumption or such later date as the contractor may approve; (c) An explanation that the contractor may be reimbursed for actual and reasonable “wind up costs” incurred after the effective date of the rescission; and (d) A request for the return of property, if any. Yes. On the effective date of any rescission, the Indian tribe or tribal organization shall, at the request of the Secretary, deliver to the Secretary all property and equipment provided under the contract which has a per item current fair market value, less the cost of improvements borne by the Indian tribe or tribal organization, in excess of $5,000 at the time of the retrocession. No. The Secretary shall provide at least the same level of funding that would have been provided if there had been no reassumption.
Title 25: Indians
PART 900—CONTRACTS UNDER THE INDIAN SELF-DETERMINATION AND EDUCATION ASSISTANCE ACT
Section Contents
§ 900.1 Authority.
§ 900.2 Purpose and scope.
§ 900.3 Policy statements.
§ 900.4 Effect on existing tribal rights.
§ 900.5 Effect of these regulations on Federal program guidelines, manual, or policy directives.
§ 900.6 Definitions.
§ 900.7 What technical assistance is available to assist in preparing an initial contract proposal?
§ 900.8 What must an initial contract proposal contain?
§ 900.9 May the Secretary require an Indian tribe or tribal organization to submit any other information beyond that identified in §900.8?
§ 900.10 How does an Indian tribe or tribal organization secure a list of all Federal property currently in use in carrying out the programs, functions, services, or activities that benefit the Indian tribe or tribal organization to assist in negotiating a contract?
§ 900.11 What should an Indian tribe or tribal organization that is proposing a contract do about specifying the Federal property that the Indian tribe or tribal organization may wish to use in carrying out the contract?
§ 900.12 Are the proposal contents requirements the same for renewal of a contract that is expiring and for securing an annual funding agreement after the first year of the funding agreement?
§ 900.13 Does the contract proposal become part of the final contract?
§ 900.14 What does this subpart cover?
§ 900.15 What shall the Secretary do upon receiving a proposal?
§ 900.16 How long does the Secretary have to review and approve the proposal and award the contract, or decline a proposal?
§ 900.17 Can the statutory 90-day period be extended?
§ 900.18 What happens if a proposal is not declined within 90 days after it is received by the Secretary?
§ 900.19 What happens when a proposal is approved?
§ 900.20 What does this subpart cover?
§ 900.21 When can a proposal be declined?
§ 900.22 For what reasons can the Secretary decline a proposal?
§ 900.23 Can the Secretary decline a proposal where the Secretary's objection can be overcome through the contract?
§ 900.24 Can a contract proposal for an Indian tribe or tribal organization's share of administrative programs, functions, services, and activities be declined for any reason other than the five reasons specified in §900.22?
§ 900.25 What if only a portion of a proposal raises one of the five declination criteria?
§ 900.26 What happens if the Secretary declines a part of a proposal on the ground that the proposal proposes in part to plan, conduct, or administer a program, function, service or activity that is beyond the scope of programs covered under section 102(a) of the Act, or proposes a level of funding that is in excess of the applicable level determined under section 106(a) of the Act?
§ 900.27 If an Indian tribe or tribal organization elects to contract for a severable portion of a proposal, does the Indian tribe or tribal organization lose its appeal rights to challenge the portion of the proposal that was declined?
§ 900.28 Is technical assistance available to an Indian tribe or tribal organization to avoid declination of a proposal?
§ 900.29 What is the Secretary required to do if the Secretary decides to decline all or a portion of a proposal?
§ 900.30 When the Secretary declines all or a portion of a proposal, is the Secretary required to provide an Indian tribe or tribal organization with technical assistance?
§ 900.31 When the Secretary declines all or a portion of a proposal, is an Indian tribe or tribal organization entitled to any appeal?
§ 900.32 Can the Secretary decline an Indian tribe or tribal organization's proposed successor annual funding agreement?
§ 900.33 Are all proposals to renew term contracts subject to the declination criteria?
General
§ 900.35 What is the purpose of this subpart?
§ 900.36 What requirements are imposed upon Indian tribes or tribal organizations by this subpart?
§ 900.37 What provisions of Office of Management and Budget (OMB) circulars or the “common rule” apply to self-determination contracts?
§ 900.38 Do these standards apply to the subcontractors of an Indian tribe or tribal organization carrying out a self-determination contract?
§ 900.39 What is the difference between a standard and a system?
§ 900.40 When are Indian tribe or tribal organization management standards and management systems evaluated?
§ 900.41 How long must an Indian tribe or tribal organization keep management system records?
Standards for Financial Management Systems
§ 900.42 What are the general financial management system standards that apply to an Indian tribe carrying out a self-determination contract?
§ 900.43 What are the general financial management system standards that apply to a tribal organization carrying out a self-determination contract?
§ 900.44 What minimum general standards apply to all Indian tribe or tribal organization financial management systems when carrying out a self-determination contract?
§ 900.45 What specific minimum requirements shall an Indian tribe or tribal organization's financial management system contain to meet these standards?
§ 900.46 What requirements are imposed upon the Secretary for financial management by these standards?
Procurement Management System Standards
§ 900.47 When procuring property or services with self-determination contract funds, can an Indian tribe or tribal organization follow the same procurement policies and procedures applicable to other Indian tribe or tribal organization funds?
§ 900.48 If the Indian tribe or tribal organization does not propose different standards, what basic standards shall the Indian tribe or tribal organization follow?
§ 900.49 What procurement standards apply to subcontracts?
§ 900.50 What Federal laws, regulations, and Executive Orders apply to subcontractors?
Property Management System Standards
§ 900.51 What is an Indian tribe or tribal organization's property management system expected to do?
§ 900.52 What type of property is the property management system required to track?
§ 900.53 What kind of records shall the property management system maintain?
§ 900.54 Should the property management system prescribe internal controls?
§ 900.55 What are the standards for inventories?
§ 900.56 What maintenance is required for property?
§ 900.57 What if the Indian tribe or tribal organization chooses not to take title to property furnished or acquired under the contract?
§ 900.58 Do the same accountability and control procedures described above apply to Federal property?
§ 900.59 How are the inventory requirements for Federal property different than for tribal property?
§ 900.60 How does an Indian tribe or tribal organization dispose of Federal personal property?
§ 900.65 What programmatic reports and data shall the Indian tribe or tribal organization provide?
§ 900.66 What happens if the Indian tribe or tribal organization and the Secretary cannot come to an agreement concerning the type and/or frequency of program narrative and/or program data report(s)?
§ 900.67 Will there be a uniform data set for all IHS programs?
§ 900.68 Will this uniform data set be required of all Indian tribe or tribal organizations contracting with the IHS under the Act?
§ 900.69 What is the purpose of this subpart?
§ 900.70 What elements are included in the compensation for a lease entered into between the Secretary and an Indian tribe or tribal organization for a building owned or leased by the Indian tribe or tribal organization that is used for administration or delivery of services under the Act?
§ 900.71 What type of reserve fund is anticipated for funds deposited into a reserve for replacement of facilities as specified in §900.70(c)?
§ 900.72 Who is the guardian of the fund and may the funds be invested?
§ 900.73 Is a lease with the Secretary the only method available to recover the types of cost described in §900.70?
§ 900.74 How may an Indian tribe or tribal organization propose a lease to be compensated for the use of facilities?
General
§ 900.85 What is the purpose of this subpart?
§ 900.86 How will the Secretary exercise discretion to acquire and donate BIA or IHS excess property and excess and surplus Federal property to an Indian tribe or tribal organization?
Government-Furnished Property
§ 900.87 How does an Indian tribe or tribal organization obtain title to property furnished by the Federal government for use in the performance of a contract or grant agreement pursuant to section 105(f)(2)(A) of the Act?
§ 900.88 What should the Indian tribe or tribal organization do if it wants to obtain title to government-furnished real property that includes land not already held in trust?
§ 900.89 When may the Secretary elect to reacquire government-furnished property whose title has been transferred to an Indian tribe or tribal organization?
§ 900.90 Does government-furnished real property to which an Indian tribe or tribal organization has taken title continue to be eligible for facilities operation and maintenance funding from the Secretary?
Contractor-Purchased Property
§ 900.91 Who takes title to property purchased with funds under a self-determination contract or grant agreement pursuant to section 105(f)(2)(A) of the Act?
§ 900.92 What should the Indian tribe or tribal organization do if it wants contractor-purchased real property to be taken into trust?
§ 900.93 When may the Secretary elect to acquire title to contractor-purchased property?
§ 900.94 Is contractor-purchased real property to which an Indian tribe or tribal organization holds title eligible for facilities operation and maintenance funding from the Secretary?
BIA and IHS Excess Property
§ 900.95 What is BIA or IHS excess property?
§ 900.96 How can Indian tribes or tribal organizations learn about BIA and IHS excess property?
§ 900.97 How can an Indian tribe or tribal organization acquire excess BIA or IHS property?
§ 900.98 Who takes title to excess BIA or IHS property donated to an Indian tribe or tribal organization?
§ 900.99 Who takes title to any land that is part of excess BIA or IHS real property donated to an Indian tribe or tribal organization?
§ 900.100 May the Secretary elect to reacquire excess BIA or IHS property whose title has been transferred to an Indian tribe or tribal organization?
§ 900.101 Is excess BIA or IHS real property to which an Indian tribe or tribal organization has taken title eligible for facilities operation and maintenance funding from the Secretary?
Excess or Surplus Government Property of Other Agencies
§ 900.102 What is excess or surplus government property of other agencies?
§ 900.103 How can Indian tribes or tribal organizations learn about property that has been designated as excess or surplus government property?
§ 900.104 How may an Indian tribe or tribal organization receive excess or surplus government property of other agencies?
§ 900.105 Who takes title to excess or surplus Federal property donated to an Indian tribe or tribal organization?
§ 900.106 If a contract or grant agreement or portion thereof is retroceded, reassumed, terminated, or expires, may the Secretary reacquire title to excess or surplus Federal property of other agencies that was donated to an Indian tribe or tribal organization?
Property Eligible for Replacement Funding
§ 900.107 What property to which an Indian tribe or tribal organization obtains title under this subpart is eligible for replacement funding?
§ 900.110 What does this subpart cover?
§ 900.111 What activities of construction programs are contractible?
§ 900.112 What are construction phases?
§ 900.113 Definitions.
§ 900.114 Why is there a separate subpart in these regulations for construction contracts and grants?
§ 900.115 How do self-determination construction contracts relate to ordinary Federal procurement contracts?
§ 900.116 Are negotiated fixed-price contracts treated the same as cost-reimbursable contracts?
§ 900.117 Do these “construction contract” regulations apply to planning services?
§ 900.118 Do these “construction contract” regulations apply to construction management services?
§ 900.119 To what extent shall the Secretary consult with affected Indian tribes before spending funds for any construction project?
§ 900.120 How does an Indian tribe or tribal organization find out about a construction project?
§ 900.121 What happens during the preplanning phase and can an Indian tribe or tribal organization perform any of the activities involved in this process?
§ 900.122 What does an Indian tribe or tribal organization do if it wants to secure a construction contract?
§ 900.123 What happens if the Indian tribe or tribal organization and the Secretary cannot develop a mutually agreeable contract proposal?
§ 900.124 May the Indian tribe or tribal organization elect to use a grant in lieu of a contract?
§ 900.125 What shall a construction contract proposal contain?
§ 900.126 Shall a construction contract proposal incorporate provisions of Federal construction guidelines and manuals?
§ 900.127 What can be included in the Indian tribe or tribal organization's contract budget?
§ 900.128 What funding shall the Secretary provide in a construction contract?
§ 900.129 How do the Secretary and Indian tribe or tribal organization arrive at an overall fair and reasonable price for the performance of a construction contract?
§ 900.130 What role does the Indian tribe or tribal organization play during the performance of a self-determination construction contract?
§ 900.131 What role does the Secretary play during the performance of a self-determination construction contract?
§ 900.132 Once a contract and/or grant is awarded, how will the Indian tribe or tribal organization receive payments?
§ 900.133 Does the declination process or the Contract Dispute Act apply to construction contract amendments proposed either by an Indian tribe or tribal organization or the Secretary?
§ 900.134 At the end of a self-determination construction contract, what happens to savings on a cost-reimbursement contract?
§ 900.135 May the time frames for action set out in this subpart be reduced?
§ 900.136 Do tribal employment rights ordinances apply to construction contracts and subcontracts?
§ 900.137 Do all provisions of the other subparts apply to contracts awarded under this subpart?
§ 900.140 Can any provision of the regulations under this part be waived?
§ 900.141 How does an Indian tribe or tribal organization get a waiver?
§ 900.142 Does an Indian tribe or tribal organization's waiver request have to be included in an initial contract proposal?
§ 900.143 How is a waiver request processed?
§ 900.144 What happens if the Secretary makes no decision within the 90-day period?
§ 900.145 On what basis may the Secretary deny a waiver request?
§ 900.146 Is technical assistance available for waiver requests?
§ 900.147 What appeal rights are available?
§ 900.148 How can an Indian tribe or tribal organization secure a determination that a law or regulation has been superseded by the Indian Self-Determination Act, as specified in section 107(b) of the Act?
Appeals Other Than Emergency Reassumption and Suspension, Withholding or Delay in Payment
§ 900.150 What decisions can an Indian tribe or tribal organization appeal under this subpart?
§ 900.151 Are there any appeals this subpart does not cover?
§ 900.152 How does an Indian tribe or tribal organization know where and when to file its appeal from decisions made by agencies of DOI or DHHS?
§ 900.153 Does an Indian tribe or tribal organization have any options besides an appeal?
§ 900.154 How does an Indian tribe or tribal organization request an informal conference?
§ 900.155 How is an informal conference held?
§ 900.156 What happens after the informal conference?
§ 900.157 Is the recommended decision always final?
§ 900.158 How does an Indian tribe or tribal organization appeal the initial decision, if it does not request an informal conference or if it does not agree with the recommended decision resulting from the informal conference?
§ 900.159 May an Indian tribe or tribal organization get an extension of time to file a notice of appeal?
§ 900.160 What happens after an Indian tribe or tribal organization files an appeal?
§ 900.161 How is a hearing arranged?
§ 900.162 What happens when a hearing is necessary?
§ 900.163 What is the Secretary's burden of proof for appeals from decisions under §900.150(a) through §900.150(g)?
§ 900.164 What rights do Indian tribes, tribal organizations, and the government have during the appeal process?
§ 900.165 What happens after the hearing?
§ 900.166 Is the recommended decision always final?
§ 900.167 If an Indian tribe or tribal organization objects to the recommended decision, what will the Secretary of Health and Human Services or the IBIA do?
§ 900.168 Will an appeal hurt the Indian tribe or tribal organization's position in other contract negotiations?
§ 900.169 Will the decisions on appeals be available for the public to review?
Appeals of Emergency Reassumption of Self-Determination Contracts or Suspensions, Withholding or Delay of Payments Under a Self-Determination Contract
§ 900.170 What happens in the case of emergency reassumption or suspension or withholding or delay of payments?
§ 900.171 Will there be a hearing?
§ 900.172 What happens after the hearing?
§ 900.173 Is the recommended decision always final?
§ 900.174 If an Indian tribe or tribal organization objects to the recommended decision, what will the Secretary of Health and Human Services or the IBIA do?
§ 900.175 Will an appeal hurt an Indian tribe or tribal organization's position in other contract negotiations?
§ 900.176 Will the decisions on appeals be available for the public to review?
Applicability of the Equal Access to Justice Act
§ 900.177 Does the Equal Access to Justice Act (EAJA) apply to appeals under this subpart?
§ 900.180 What does this subpart cover?
§ 900.181 What definitions apply to this subpart?
§ 900.182 What other statutes and regulations apply to FTCA coverage?
§ 900.183 Do Indian tribes and tribal organizations need to be aware of areas which FTCA does not cover?
§ 900.184 Is there a deadline for filing FTCA claims?
§ 900.185 How long does the Federal government have to process an FTCA claim after the claim is received by the Federal agency, before a lawsuit may be filed?
§ 900.186 Is it necessary for a self-determination contract to include any clauses about Federal Tort Claims Act coverage?
§ 900.187 Does FTCA apply to a self-determination contract if FTCA is not referenced in the contract?
§ 900.188 To what extent shall the contractor cooperate with the Federal government in connection with tort claims arising out of the contractor's performance?
§ 900.189 Does this coverage extend to subcontractors of self-determination contracts?
Medical-Related Claims
§ 900.190 Is FTCA the exclusive remedy for a tort claim for personal injury or death resulting from the performance of a self-determination contract?
§ 900.191 Are employees of self-determination contractors providing health services under the self-determination contract protected by FTCA?
§ 900.192 What employees are covered by FTCA for medical-related claims?
§ 900.193 Does FTCA coverage extend to individuals who provide health care services under a personal services contract providing services in a facility that is owned, operated, or constructed under the jurisdiction of the IHS?
§ 900.194 Does FTCA coverage extend to services provided under a staff privileges agreement with a non-IHS facility where the agreement requires a health care practitioner to provide reciprocal services to the general population?
§ 900.195 Does FTCA coverage extend to the contractor's health care practitioners providing services to private patients on a fee-for-services basis when such personnel (not the self-determination contractor) receive the fee?
§ 900.196 Do covered services include the conduct of clinical studies and investigations and the provision of emergency services, including the operation of emergency motor vehicles?
§ 900.197 Does FTCA cover employees of the contractor who are paid by the contractor from funds other than those provided through the self-determination contract?
§ 900.198 Are Federal employees assigned to a self-determination contractor under the Intergovernmental Personnel Act or detailed under section 214 of the Public Health Service Act covered to the same extent that they would be if working directly for a Federal agency?
§ 900.199 Does FTCA coverage extend to health care practitioners to whom staff privileges have been extended in contractor health care facilities operated under a self-determination contract on the condition that such practitioner provide health services to IHS beneficiaries covered by FTCA?
§ 900.200 May persons who are not Indians or Alaska Natives assert claims under FTCA?
Procedure for Filing Medical-Related Claims
§ 900.201 How should claims arising out of the performance of medical-related functions be filed?
§ 900.202 What should a self-determination contractor or a contractor's employee do on receiving such a claim?
§ 900.203 If the contractor or contractor's employee receives a summons and/or a complaint alleging a tort covered by FTCA, what should the contractor do?
Non-Medical Related Claims
§ 900.204 Is FTCA the exclusive remedy for a non-medical related tort claim arising out of the performance of a self-determination contract?
§ 900.205 To what non-medical-related claims against self-determination contractors does FTCA apply?
§ 900.206 What employees are covered by FTCA for non-medical-related claims?
§ 900.207 How are non-medical related tort claims and lawsuits filed for IHS?
§ 900.208 How are non-medical related tort claims and lawsuits filed for DOI?
§ 900.209 What should a self-determination contractor or contractor's employee do on receiving a non-medical related tort claim?
§ 900.210 If the contractor or contractor's employee receives a summons and/or complaint alleging a non-medical related tort covered by FTCA, what should an Indian tribe or tribal organization do?
§ 900.215 What does this subpart cover?
§ 900.216 What other statutes and regulations apply to contract disputes?
§ 900.217 Is filing a claim under the CDA our only option for resolving post-award contract disputes?
§ 900.218 What is a claim under the CDA?
§ 900.219 How does an Indian tribe, tribal organization, or Federal agency submit a claim?
§ 900.220 Does it make a difference whether the claim is large or small?
§ 900.221 What happens next?
§ 900.222 What goes into a decision?
§ 900.223 When does an Indian tribe or tribal organization get the decision?
§ 900.224 What happens if the decision does not come within that time?
§ 900.225 Does an Indian tribe or tribal organization get paid immediately if the awarding official decides in its favor?
§ 900.226 What rules govern appeals of cost disallowances?
§ 900.227 Can the awarding official change the decision after it has been made?
§ 900.228 Is an Indian tribe or tribal organization entitled to interest if it wins its claim?
§ 900.229 What role will the awarding official play during an appeal?
§ 900.230 What is the effect of a pending appeal?
§ 900.231 What is an organizational conflict of interest?
§ 900.232 What must an Indian tribe or tribal organization do if an organizational conflict of interest arises under a contract?
§ 900.233 When must an Indian tribe or tribal organization regulate its employees or subcontractors to avoid a personal conflict of interest?
§ 900.234 What types of personal conflicts of interest involving tribal officers, employees or subcontractors would have to be regulated by an Indian tribe?
§ 900.235 What personal conflicts of interest must the standards of conduct regulate?
§ 900.236 May an Indian tribe elect to negotiate contract provisions on conflict of interest to take the place of this regulation?
§ 900.240 What does retrocession mean?
§ 900.241 Who may retrocede a contract, in whole or in part?
§ 900.242 What is the effective date of retrocession?
§ 900.243 What effect will an Indian tribe or tribal organization's retrocession have on its rights to contract?
§ 900.244 Will an Indian tribe or tribal organization's retrocession adversely affect funding available for the retroceded program?
§ 900.245 What obligation does the Indian tribe or tribal organization have with respect to returning property that was used in the operation of the retroceded program?
§ 900.246 What does reassumption mean?
§ 900.247 Under what circumstances is a reassumption considered an emergency instead of non-emergency reassumption?
§ 900.248 In a non-emergency reassumption, what is the Secretary required to do?
§ 900.249 What happens if the contractor fails to take corrective action to remedy the contract deficiencies identified in the notice?
§ 900.250 What shall the second written notice include?
§ 900.251 What is the earliest date on which the contract will be rescinded in a non-emergency reassumption?
§ 900.252 In an emergency reassumption, what is the Secretary required to do?
§ 900.253 What shall the written notice include?
§ 900.254 May the contractor be reimbursed for actual and reasonable “wind up costs” incurred after the effective date of rescission?
§ 900.255 What obligation does the Indian tribe or tribal organization have with respect to returning property that was used in the operation of the rescinded contract?
§ 900.256 Will a reassumption adversely affect funding available for the reassumed program?
Subpart A—General Provisions
top
§ 900.1 Authority.
top
§ 900.2 Purpose and scope.
top
§ 900.3 Policy statements.
top
§ 900.4 Effect on existing tribal rights.
top
§ 900.5 Effect of these regulations on Federal program guidelines, manual, or policy directives.
top
Subpart B—Definitions
top
§ 900.6 Definitions.
top
Subpart C—Contract Proposal Contents
top
§ 900.7 What technical assistance is available to assist in preparing an initial contract proposal?
top
§ 900.8 What must an initial contract proposal contain?
top
§ 900.9 May the Secretary require an Indian tribe or tribal organization to submit any other information beyond that identified in §900.8?
top
§ 900.10 How does an Indian tribe or tribal organization secure a list of all Federal property currently in use in carrying out the programs, functions, services, or activities that benefit the Indian tribe or tribal organization to assist in negotiating a contract?
top
§ 900.11 What should an Indian tribe or tribal organization that is proposing a contract do about specifying the Federal property that the Indian tribe or tribal organization may wish to use in carrying out the contract?
top
§ 900.12 Are the proposal contents requirements the same for renewal of a contract that is expiring and for securing an annual funding agreement after the first year of the funding agreement?
top
§ 900.13 Does the contract proposal become part of the final contract?
top
Subpart D—Review and Approval of Contract Proposals
top
§ 900.14 What does this subpart cover?
top
§ 900.15 What shall the Secretary do upon receiving a proposal?
top
§ 900.16 How long does the Secretary have to review and approve the proposal and award the contract, or decline a proposal?
top
§ 900.17 Can the statutory 90-day period be extended?
top
§ 900.18 What happens if a proposal is not declined within 90 days after it is received by the Secretary?
top
§ 900.19 What happens when a proposal is approved?
top
Subpart E—Declination Procedures
top
§ 900.20 What does this subpart cover?
top
§ 900.21 When can a proposal be declined?
top
§ 900.22 For what reasons can the Secretary decline a proposal?
top
§ 900.23 Can the Secretary decline a proposal where the Secretary's objection can be overcome through the contract?
top
§ 900.24 Can a contract proposal for an Indian tribe or tribal organization's share of administrative programs, functions, services, and activities be declined for any reason other than the five reasons specified in §900.22?
top
§ 900.25 What if only a portion of a proposal raises one of the five declination criteria?
top
§ 900.26 What happens if the Secretary declines a part of a proposal on the ground that the proposal proposes in part to plan, conduct, or administer a program, function, service or activity that is beyond the scope of programs covered under section 102(a) of the Act, or proposes a level of funding that is in excess of the applicable level determined under section 106(a) of the Act?
top
§ 900.27 If an Indian tribe or tribal organization elects to contract for a severable portion of a proposal, does the Indian tribe or tribal organization lose its appeal rights to challenge the portion of the proposal that was declined?
top
§ 900.28 Is technical assistance available to an Indian tribe or tribal organization to avoid declination of a proposal?
top
§ 900.29 What is the Secretary required to do if the Secretary decides to decline all or a portion of a proposal?
top
§ 900.30 When the Secretary declines all or a portion of a proposal, is the Secretary required to provide an Indian tribe or tribal organization with technical assistance?
top
§ 900.31 When the Secretary declines all or a portion of a proposal, is an Indian tribe or tribal organization entitled to any appeal?
top
§ 900.32 Can the Secretary decline an Indian tribe or tribal organization's proposed successor annual funding agreement?
top
§ 900.33 Are all proposals to renew term contracts subject to the declination criteria?
top
Subpart F—Standards for Tribal or Tribal Organization Management Systems
top
General
top
§ 900.35 What is the purpose of this subpart?
top
§ 900.36 What requirements are imposed upon Indian tribes or tribal organizations by this subpart?
top
§ 900.37 What provisions of Office of Management and Budget (OMB) circulars or the “common rule” apply to self-determination contracts?
top
§ 900.38 Do these standards apply to the subcontractors of an Indian tribe or tribal organization carrying out a self-determination contract?
top
§ 900.39 What is the difference between a standard and a system?
top
§ 900.40 When are Indian tribe or tribal organization management standards and management systems evaluated?
top
§ 900.41 How long must an Indian tribe or tribal organization keep management system records?
top
Standards for Financial Management Systems
top
§ 900.42 What are the general financial management system standards that apply to an Indian tribe carrying out a self-determination contract?
top
§ 900.43 What are the general financial management system standards that apply to a tribal organization carrying out a self-determination contract?
top
§ 900.44 What minimum general standards apply to all Indian tribe or tribal organization financial management systems when carrying out a self-determination contract?
top
§ 900.45 What specific minimum requirements shall an Indian tribe or tribal organization's financial management system contain to meet these standards?
top
------------------------------------------------------------------------ Type of tribal organization Applicable OMB cost circular------------------------------------------------------------------------Tribal Government...................... A-87, ``Cost Principles for State, Local and Indian Tribal Governments.''Tribal private non-profit other than: A-122, ``Cost Principles for (1) an institution of higher Non-Profit Organizations.'' education, (2) a hospital, or (3) an organization named in OMB Circular A- 122 as not subject to that circular.Tribal educational institution......... A-21, ``Cost Principles for Educational Institutions.''------------------------------------------------------------------------
§ 900.46 What requirements are imposed upon the Secretary for financial management by these standards?
top
Procurement Management System Standards
top
§ 900.47 When procuring property or services with self-determination contract funds, can an Indian tribe or tribal organization follow the same procurement policies and procedures applicable to other Indian tribe or tribal organization funds?
top
§ 900.48 If the Indian tribe or tribal organization does not propose different standards, what basic standards shall the Indian tribe or tribal organization follow?
top
§ 900.49 What procurement standards apply to subcontracts?
top
§ 900.50 What Federal laws, regulations, and Executive Orders apply to subcontractors?
top
Property Management System Standards
top
§ 900.51 What is an Indian tribe or tribal organization's property management system expected to do?
top
§ 900.52 What type of property is the property management system required to track?
top
§ 900.53 What kind of records shall the property management system maintain?
top
§ 900.54 Should the property management system prescribe internal controls?
top
§ 900.55 What are the standards for inventories?
top
§ 900.56 What maintenance is required for property?
top
§ 900.57 What if the Indian tribe or tribal organization chooses not to take title to property furnished or acquired under the contract?
top
§ 900.58 Do the same accountability and control procedures described above apply to Federal property?
top
§ 900.59 How are the inventory requirements for Federal property different than for tribal property?
top
§ 900.60 How does an Indian tribe or tribal organization dispose of Federal personal property?
top
Subpart G—Programmatic Reports and Data Requirements
top
§ 900.65 What programmatic reports and data shall the Indian tribe or tribal organization provide?
top
§ 900.66 What happens if the Indian tribe or tribal organization and the Secretary cannot come to an agreement concerning the type and/or frequency of program narrative and/or program data report(s)?
top
§ 900.67 Will there be a uniform data set for all IHS programs?
top
§ 900.68 Will this uniform data set be required of all Indian tribe or tribal organizations contracting with the IHS under the Act?
top
Subpart H—Lease of Tribally-Owned Buildings by the Secretary
top
§ 900.69 What is the purpose of this subpart?
top
§ 900.70 What elements are included in the compensation for a lease entered into between the Secretary and an Indian tribe or tribal organization for a building owned or leased by the Indian tribe or tribal organization that is used for administration or delivery of services under the Act?
top
§ 900.71 What type of reserve fund is anticipated for funds deposited into a reserve for replacement of facilities as specified in §900.70(c)?
top
§ 900.72 Who is the guardian of the fund and may the funds be invested?
top
§ 900.73 Is a lease with the Secretary the only method available to recover the types of cost described in §900.70?
top
§ 900.74 How may an Indian tribe or tribal organization propose a lease to be compensated for the use of facilities?
top
Subpart I—Property Donation Procedures
top
General
top
§ 900.85 What is the purpose of this subpart?
top
§ 900.86 How will the Secretary exercise discretion to acquire and donate BIA or IHS excess property and excess and surplus Federal property to an Indian tribe or tribal organization?
top
Government-Furnished Property
top
§ 900.87 How does an Indian tribe or tribal organization obtain title to property furnished by the Federal government for use in the performance of a contract or grant agreement pursuant to section 105(f)(2)(A) of the Act?
top
§ 900.88 What should the Indian tribe or tribal organization do if it wants to obtain title to government-furnished real property that includes land not already held in trust?
top
§ 900.89 When may the Secretary elect to reacquire government-furnished property whose title has been transferred to an Indian tribe or tribal organization?
top
§ 900.90 Does government-furnished real property to which an Indian tribe or tribal organization has taken title continue to be eligible for facilities operation and maintenance funding from the Secretary?
top
Contractor-Purchased Property
top
§ 900.91 Who takes title to property purchased with funds under a self-determination contract or grant agreement pursuant to section 105(f)(2)(A) of the Act?
top
§ 900.92 What should the Indian tribe or tribal organization do if it wants contractor-purchased real property to be taken into trust?
top
§ 900.93 When may the Secretary elect to acquire title to contractor-purchased property?
top
§ 900.94 Is contractor-purchased real property to which an Indian tribe or tribal organization holds title eligible for facilities operation and maintenance funding from the Secretary?
top
BIA and IHS Excess Property
top
§ 900.95 What is BIA or IHS excess property?
top
§ 900.96 How can Indian tribes or tribal organizations learn about BIA and IHS excess property?
top
§ 900.97 How can an Indian tribe or tribal organization acquire excess BIA or IHS property?
top
§ 900.98 Who takes title to excess BIA or IHS property donated to an Indian tribe or tribal organization?
top
§ 900.99 Who takes title to any land that is part of excess BIA or IHS real property donated to an Indian tribe or tribal organization?
top
§ 900.100 May the Secretary elect to reacquire excess BIA or IHS property whose title has been transferred to an Indian tribe or tribal organization?
top
§ 900.101 Is excess BIA or IHS real property to which an Indian tribe or tribal organization has taken title eligible for facilities operation and maintenance funding from the Secretary?
top
Excess or Surplus Government Property of Other Agencies
top
§ 900.102 What is excess or surplus government property of other agencies?
top
§ 900.103 How can Indian tribes or tribal organizations learn about property that has been designated as excess or surplus government property?
top
§ 900.104 How may an Indian tribe or tribal organization receive excess or surplus government property of other agencies?
top
§ 900.105 Who takes title to excess or surplus Federal property donated to an Indian tribe or tribal organization?
top
§ 900.106 If a contract or grant agreement or portion thereof is retroceded, reassumed, terminated, or expires, may the Secretary reacquire title to excess or surplus Federal property of other agencies that was donated to an Indian tribe or tribal organization?
top
Property Eligible for Replacement Funding
top
§ 900.107 What property to which an Indian tribe or tribal organization obtains title under this subpart is eligible for replacement funding?
top
Subpart J—Construction
top
§ 900.110 What does this subpart cover?
top
§ 900.111 What activities of construction programs are contractible?
top
§ 900.112 What are construction phases?
top
§ 900.113 Definitions.
top
§ 900.114 Why is there a separate subpart in these regulations for construction contracts and grants?
top
§ 900.115 How do self-determination construction contracts relate to ordinary Federal procurement contracts?
top
§ 900.116 Are negotiated fixed-price contracts treated the same as cost-reimbursable contracts?
top
§ 900.117 Do these “construction contract” regulations apply to planning services?
top
§ 900.118 Do these “construction contract” regulations apply to construction management services?
top
§ 900.119 To what extent shall the Secretary consult with affected Indian tribes before spending funds for any construction project?
top
§ 900.120 How does an Indian tribe or tribal organization find out about a construction project?
top
§ 900.121 What happens during the preplanning phase and can an Indian tribe or tribal organization perform any of the activities involved in this process?
top
§ 900.122 What does an Indian tribe or tribal organization do if it wants to secure a construction contract?
top
§ 900.123 What happens if the Indian tribe or tribal organization and the Secretary cannot develop a mutually agreeable contract proposal?
top
§ 900.124 May the Indian tribe or tribal organization elect to use a grant in lieu of a contract?
top
§ 900.125 What shall a construction contract proposal contain?
top
§ 900.126 Shall a construction contract proposal incorporate provisions of Federal construction guidelines and manuals?
top
§ 900.127 What can be included in the Indian tribe or tribal organization's contract budget?
top
§ 900.128 What funding shall the Secretary provide in a construction contract?
top
§ 900.129 How do the Secretary and Indian tribe or tribal organization arrive at an overall fair and reasonable price for the performance of a construction contract?
top
§ 900.130 What role does the Indian tribe or tribal organization play during the performance of a self-determination construction contract?
top
§ 900.131 What role does the Secretary play during the performance of a self-determination construction contract?
top
§ 900.132 Once a contract and/or grant is awarded, how will the Indian tribe or tribal organization receive payments?
top
§ 900.133 Does the declination process or the Contract Dispute Act apply to construction contract amendments proposed either by an Indian tribe or tribal organization or the Secretary?
top
§ 900.134 At the end of a self-determination construction contract, what happens to savings on a cost-reimbursement contract?
top
§ 900.135 May the time frames for action set out in this subpart be reduced?
top
§ 900.136 Do tribal employment rights ordinances apply to construction contracts and subcontracts?
top
§ 900.137 Do all provisions of the other subparts apply to contracts awarded under this subpart?
top
Subpart K—Waiver Procedures
top
§ 900.140 Can any provision of the regulations under this part be waived?
top
§ 900.141 How does an Indian tribe or tribal organization get a waiver?
top
§ 900.142 Does an Indian tribe or tribal organization's waiver request have to be included in an initial contract proposal?
top
§ 900.143 How is a waiver request processed?
top
§ 900.144 What happens if the Secretary makes no decision within the 90-day period?
top
§ 900.145 On what basis may the Secretary deny a waiver request?
top
§ 900.146 Is technical assistance available for waiver requests?
top
§ 900.147 What appeal rights are available?
top
§ 900.148 How can an Indian tribe or tribal organization secure a determination that a law or regulation has been superseded by the Indian Self-Determination Act, as specified in section 107(b) of the Act?
top
Subpart L—Appeals
top
Appeals Other Than Emergency Reassumption and Suspension, Withholding or Delay in Payment
top
§ 900.150 What decisions can an Indian tribe or tribal organization appeal under this subpart?
top
§ 900.151 Are there any appeals this subpart does not cover?
top
§ 900.152 How does an Indian tribe or tribal organization know where and when to file its appeal from decisions made by agencies of DOI or DHHS?
top
§ 900.153 Does an Indian tribe or tribal organization have any options besides an appeal?
top
§ 900.154 How does an Indian tribe or tribal organization request an informal conference?
top
§ 900.155 How is an informal conference held?
top
§ 900.156 What happens after the informal conference?
top
§ 900.157 Is the recommended decision always final?
top
§ 900.158 How does an Indian tribe or tribal organization appeal the initial decision, if it does not request an informal conference or if it does not agree with the recommended decision resulting from the informal conference?
top
§ 900.159 May an Indian tribe or tribal organization get an extension of time to file a notice of appeal?
top
§ 900.160 What happens after an Indian tribe or tribal organization files an appeal?
top
§ 900.161 How is a hearing arranged?
top
§ 900.162 What happens when a hearing is necessary?
top
§ 900.163 What is the Secretary's burden of proof for appeals from decisions under §900.150(a) through §900.150(g)?
top
§ 900.164 What rights do Indian tribes, tribal organizations, and the government have during the appeal process?
top
§ 900.165 What happens after the hearing?
top
§ 900.166 Is the recommended decision always final?
top
§ 900.167 If an Indian tribe or tribal organization objects to the recommended decision, what will the Secretary of Health and Human Services or the IBIA do?
top
§ 900.168 Will an appeal hurt the Indian tribe or tribal organization's position in other contract negotiations?
top
§ 900.169 Will the decisions on appeals be available for the public to review?
top
Appeals of Emergency Reassumption of Self-Determination Contracts or Suspensions, Withholding or Delay of Payments Under a Self-Determination Contract
top
§ 900.170 What happens in the case of emergency reassumption or suspension or withholding or delay of payments?
top
§ 900.171 Will there be a hearing?
top
§ 900.172 What happens after the hearing?
top
§ 900.173 Is the recommended decision always final?
top
§ 900.174 If an Indian tribe or tribal organization objects to the recommended decision, what will the Secretary of Health and Human Services or the IBIA do?
top
§ 900.175 Will an appeal hurt an Indian tribe or tribal organization's position in other contract negotiations?
top
§ 900.176 Will the decisions on appeals be available for the public to review?
top
Applicability of the Equal Access to Justice Act
top
§ 900.177 Does the Equal Access to Justice Act (EAJA) apply to appeals under this subpart?
top
Subpart M—Federal Tort Claims Act Coverage General Provisions
top
§ 900.180 What does this subpart cover?
top
§ 900.181 What definitions apply to this subpart?
top
§ 900.182 What other statutes and regulations apply to FTCA coverage?
top
§ 900.183 Do Indian tribes and tribal organizations need to be aware of areas which FTCA does not cover?
top
§ 900.184 Is there a deadline for filing FTCA claims?
top
§ 900.185 How long does the Federal government have to process an FTCA claim after the claim is received by the Federal agency, before a lawsuit may be filed?
top
§ 900.186 Is it necessary for a self-determination contract to include any clauses about Federal Tort Claims Act coverage?
top
§ 900.187 Does FTCA apply to a self-determination contract if FTCA is not referenced in the contract?
top
§ 900.188 To what extent shall the contractor cooperate with the Federal government in connection with tort claims arising out of the contractor's performance?
top
§ 900.189 Does this coverage extend to subcontractors of self-determination contracts?
top
Medical-Related Claims
top
§ 900.190 Is FTCA the exclusive remedy for a tort claim for personal injury or death resulting from the performance of a self-determination contract?
top
§ 900.191 Are employees of self-determination contractors providing health services under the self-determination contract protected by FTCA?
top
§ 900.192 What employees are covered by FTCA for medical-related claims?
top
§ 900.193 Does FTCA coverage extend to individuals who provide health care services under a personal services contract providing services in a facility that is owned, operated, or constructed under the jurisdiction of the IHS?
top
§ 900.194 Does FTCA coverage extend to services provided under a staff privileges agreement with a non-IHS facility where the agreement requires a health care practitioner to provide reciprocal services to the general population?
top
§ 900.195 Does FTCA coverage extend to the contractor's health care practitioners providing services to private patients on a fee-for-services basis when such personnel (not the self-determination contractor) receive the fee?
top
§ 900.196 Do covered services include the conduct of clinical studies and investigations and the provision of emergency services, including the operation of emergency motor vehicles?
top
§ 900.197 Does FTCA cover employees of the contractor who are paid by the contractor from funds other than those provided through the self-determination contract?
top
§ 900.198 Are Federal employees assigned to a self-determination contractor under the Intergovernmental Personnel Act or detailed under section 214 of the Public Health Service Act covered to the same extent that they would be if working directly for a Federal agency?
top
§ 900.199 Does FTCA coverage extend to health care practitioners to whom staff privileges have been extended in contractor health care facilities operated under a self-determination contract on the condition that such practitioner provide health services to IHS beneficiaries covered by FTCA?
top
§ 900.200 May persons who are not Indians or Alaska Natives assert claims under FTCA?
top
Procedure for Filing Medical-Related Claims
top
§ 900.201 How should claims arising out of the performance of medical-related functions be filed?
top
§ 900.202 What should a self-determination contractor or a contractor's employee do on receiving such a claim?
top
§ 900.203 If the contractor or contractor's employee receives a summons and/or a complaint alleging a tort covered by FTCA, what should the contractor do?
top
Non-Medical Related Claims
top
§ 900.204 Is FTCA the exclusive remedy for a non-medical related tort claim arising out of the performance of a self-determination contract?
top
§ 900.205 To what non-medical-related claims against self-determination contractors does FTCA apply?
top
§ 900.206 What employees are covered by FTCA for non-medical-related claims?
top
§ 900.207 How are non-medical related tort claims and lawsuits filed for IHS?
top
§ 900.208 How are non-medical related tort claims and lawsuits filed for DOI?
top
§ 900.209 What should a self-determination contractor or contractor's employee do on receiving a non-medical related tort claim?
top
§ 900.210 If the contractor or contractor's employee receives a summons and/or complaint alleging a non-medical related tort covered by FTCA, what should an Indian tribe or tribal organization do?
top
Subpart N—Post-Award Contract Disputes
top
§ 900.215 What does this subpart cover?
top
§ 900.216 What other statutes and regulations apply to contract disputes?
top
§ 900.217 Is filing a claim under the CDA our only option for resolving post-award contract disputes?
top
§ 900.218 What is a claim under the CDA?
top
§ 900.219 How does an Indian tribe, tribal organization, or Federal agency submit a claim?
top
§ 900.220 Does it make a difference whether the claim is large or small?
top
§ 900.221 What happens next?
top
§ 900.222 What goes into a decision?
top
§ 900.223 When does an Indian tribe or tribal organization get the decision?
top
§ 900.224 What happens if the decision does not come within that time?
top
§ 900.225 Does an Indian tribe or tribal organization get paid immediately if the awarding official decides in its favor?
top
§ 900.226 What rules govern appeals of cost disallowances?
top
§ 900.227 Can the awarding official change the decision after it has been made?
top
§ 900.228 Is an Indian tribe or tribal organization entitled to interest if it wins its claim?
top
§ 900.229 What role will the awarding official play during an appeal?
top
§ 900.230 What is the effect of a pending appeal?
top
Subpart O—Conflicts of Interest
top
§ 900.231 What is an organizational conflict of interest?
top
§ 900.232 What must an Indian tribe or tribal organization do if an organizational conflict of interest arises under a contract?
top
§ 900.233 When must an Indian tribe or tribal organization regulate its employees or subcontractors to avoid a personal conflict of interest?
top
§ 900.234 What types of personal conflicts of interest involving tribal officers, employees or subcontractors would have to be regulated by an Indian tribe?
top
§ 900.235 What personal conflicts of interest must the standards of conduct regulate?
top
§ 900.236 May an Indian tribe elect to negotiate contract provisions on conflict of interest to take the place of this regulation?
top
Subpart P—Retrocession and Reassumption Procedures
top
§ 900.240 What does retrocession mean?
top
§ 900.241 Who may retrocede a contract, in whole or in part?
top
§ 900.242 What is the effective date of retrocession?
top
§ 900.243 What effect will an Indian tribe or tribal organization's retrocession have on its rights to contract?
top
§ 900.244 Will an Indian tribe or tribal organization's retrocession adversely affect funding available for the retroceded program?
top
§ 900.245 What obligation does the Indian tribe or tribal organization have with respect to returning property that was used in the operation of the retroceded program?
top
§ 900.246 What does reassumption mean?
top
§ 900.247 Under what circumstances is a reassumption considered an emergency instead of non-emergency reassumption?
top
§ 900.248 In a non-emergency reassumption, what is the Secretary required to do?
top
§ 900.249 What happens if the contractor fails to take corrective action to remedy the contract deficiencies identified in the notice?
top
§ 900.250 What shall the second written notice include?
top
§ 900.251 What is the earliest date on which the contract will be rescinded in a non-emergency reassumption?
top
§ 900.252 In an emergency reassumption, what is the Secretary required to do?
top
§ 900.253 What shall the written notice include?
top
§ 900.254 May the contractor be reimbursed for actual and reasonable “wind up costs” incurred after the effective date of rescission?
top
§ 900.255 What obligation does the Indian tribe or tribal organization have with respect to returning property that was used in the operation of the rescinded contract?
top
§ 900.256 Will a reassumption adversely affect funding available for the reassumed program?
top
