Philippine Supreme Court Jurisprudence


Philippine Supreme Court Jurisprudence > Year 2012 > February 2012 Decisions > [G.R. No. 184851 : February 15, 2012] VALIENTE C. VILLEGAS PETITIONER, VS. THE HONORABLE VICTOR C. FERNANDEZ, DEPUTY OMBUDSMAN FOR LUZON, CONRADO S. ANCIADO, JR., ROLLY P. DANILA, ANDREI S. ARABIT AND JAIME M. BARON, RESPONDENTS. :




SECOND DIVISION

[G.R. No. 184851 : February 15, 2012]

VALIENTE C. VILLEGAS PETITIONER, VS. THE HONORABLE VICTOR C. FERNANDEZ, DEPUTY OMBUDSMAN FOR LUZON, CONRADO S. ANCIADO, JR., ROLLY P. DANILA, ANDREI S. ARABIT AND JAIME M. BARON, RESPONDENTS.

R E S O L U T I O N


REYES, J.:

This is a petition for review on certiorari under Rule 45 of the Rules of Court filed by Valiente C. Villegas (petitioner) assailing the Decision[1] dated August 8, 2008 and Resolution[2] dated October 7, 2008 issued by the Court of Appeals (CA) in CA-G.R. SP No. 92771.cralaw

On May 6, 2003, the petitioner requested then Mandaluyong City Mayor Benjamin Abalos, Jr. to allow him to improve the sidewalk and driveway fronting his house at Dr. Fernandez Avenue.[3] The improvement consists of planting trees and excavation of a concrete driveway and sidewalk. Thereupon, a building permit[4] was issued by Engineer Conrado S. Anciado, Jr. (Anciado) � the Head of Mandaluyong City Engineering Department.

After the said improvement works had been completed, the city government, in March 2004, implemented a road widening project along Dr. Fernandez Avenue. The residents therein agreed to demolish portions of their respective houses which encroached on the sidewalk and canals. Nevertheless, some of the residents therein complained to the Mayor that a portion of the petitioner�s house likewise encroached on the sidewalk but the latter did not demolish the same.[5]

After conducting an inspection on Dr. Fernandez Avenue, Anciado notified the petitioner of the said encroachment.[6] However, the petitioner disputed Anciado�s finding and asserted that, based on a prior survey of his property conducted after he had finished the said improvement works, the perimeter fence of his house was still within his property line. Nevertheless, the road widening works along Dr. Fernandez Avenue continued.

In December 2004, Anciado told the petitioner that the road widening of Dr. Fernandez Avenue was already complete except for the drainage and concreting of the portion of the road fronting the latter�s house. Further, Anciado told the petitioner that he would assign a geodetic engineer to re-survey the site to determine whether the perimeter fence of the latter�s house encroached on the sidewalk.[7] The petitioner refused Anciado�s offer of re-survey and insisted on the immediate completion of the drainage and other works fronting his house.[8]

Nevertheless, Anciado proceeded with the re-survey of the site and found that the perimeter fence of the petitioner�s house had encroached on the sidewalk. Thereupon, Anciado filed a complaint with the Mandaluyong City Council against the petitioner for the encroachment of the sidewalk fronting the petitioner�s house.

In turn, the petitioner sought assistance from the Public Assistance Bureau of the Office of the Ombudsman (Ombudsman) in a letter[9] dated December 14, 2004. Consequently, a conference between the parties was held before the Ombudsman where it was agreed upon that Anciado would finish the drainage and other works fronting the house of the petitioner. The petitioner claimed that Anciado failed to do the works that were agreed upon during the said conference before the Ombudsman.

Meanwhile, on April 5, 2005, the Mandaluyong City Council sent the petitioner a letter[10] inviting him to a hearing scheduled on April 20, 2005 with respect to the said complaint filed by Anciado.

Thus, on April 18, 2005, the petitioner formally filed a complaint[11] for neglect of duty against Anciado together with Mandaluyong City Engineering Office employees Rolly P. Danila and Jaime M. Baron and Mandaluyong City Building Inspector Andrei S. Arabit.

On June 23, 2005, Anciado and the other respondents in the case before the Ombudsman filed their Joint Counter Affidavit asserting that they could not proceed with the concreting of the pavement fronting the house of the petitioner in view of the pendency of the complaint against the petitioner for encroachment of the sidewalk.

On July 6, 2005, the Ombudsman issued an Order[12] dismissing the said complaint filed by the petitioner. The Ombudsman stated that:

However, as the records of the case will show, the purported failure to complete the project in question was totally beyond the control of the respondents, as the complainant has refused to cooperate in the intended re-survey of his property to determine whether the improvements he made have encroached upon a portion of the sidewalk. With this, the respondents can not be expected to pursue the project to its conclusion as they are hampered by the issue of the encroachment. The administrative charge of Neglect of Duty therefore is apparently without basis in fact and in law.

x x x x

But be that as it may, it has also been shown that, even before the filing of the present case on April 18, 2005, the matter of the encroachment by the complainant became the subject of appropriate proceedings before the City Council of Mandaluyong City, Committee on Engineering, as of April 5, 2005. Thus, it is incumbent that the said proceedings be allowed to continue until its conclusion. This is necessary since the issue in the present case, that is, whether the respondents indeed committed neglect of duty, becomes part and parcel of the issues in the said proceedings before the City Council.[13] (citations omitted)

The petitioner sought for a reconsideration[14] of the July 6, 2005 Order but it was denied by the Ombudsman in its Order[15] dated October 5, 2005.

Subsequently, the petitioner filed a petition for certiorari and mandamus[16] with the CA alleging that the Ombudsman gravely abused his discretion in dismissing the complaint for neglect of duty against Anciado and the other employees of Mandaluyong City Engineering Office.

On August 8, 2008, the CA rendered the herein assailed Decision[17] dismissing the petition for certiorari and mandamus filed by the petitioner. In disposing of the said petition, the CA held that the Ombudsman did not act arbitrarily or without substantial evidence in administratively exonerating the respondents. In contrast, the CA pointed out that there is substantial evidence underlying the finding of the Ombudsman that the respondents are not administratively remiss in leaving uncompleted the works in front of the property of the petitioner.

With respect to the petitioner�s prayer for the issuance of a writ of mandamus, the CA held that:

We hold that mandamus is not proper in this � firstly, the petitioner has failed to prove a ministerial duty on the part of the respondents to pave and fix the drainage of the sidewalk up to the edge of his fence irrespective of whether it is on the property line or not, x x x, and secondly, even assuming that mandamus is available against the respondents, the action should not be directly filed with Us, but with the RTC which has jurisdiction over the area in which the dispute arises, under the principle of hierarchy of courts which serves as a general determinant of the forum for petitions for extraordinary writs. x x x[18]

The petitioner sought for a reconsideration of the said August 8, 2008 Decision, but it was denied by the CA in its Resolution[19] dated October 7, 2008.

Undaunted, the petitioner instituted the instant petition for review on certiorari before this Court alleging that the CA erred in dismissing his petition for certiorari and mandamus thereby affirming the July 6, 2005 and October 5, 2005 Orders of the Ombudsman.

The petition is denied.

A perusal of the allegations, issues and arguments set forth by the petitioner would readily show that the CA did not commit any reversible error as to warrant the exercise of the Court's appellate jurisdiction.

Verily, an analysis of the various arguments raised by the petitioner in his petition would reveal that the same are geared towards discrediting the factual findings of the Ombudsman.

It is a well-settled rule that in a petition for review under Rule 45, only questions of law may be raised by the parties and passed upon by this Court.[20] It is the burden of the party seeking review of a decision of the CA or other lower tribunals to distinctly set forth in his petition for review, not only the existence of questions of law fairly and logically arising therefrom, but also questions substantial enough to merit consideration, or show that there are special and important reasons warranting the review that he seeks.[21]

Elementary is the rule that the findings of fact of the Ombudsman are conclusive when supported by substantial evidence and are accorded due respect and weight, especially when they are affirmed by the CA. It is only when there is grave abuse of discretion by the Ombudsman that a review of factual findings may aptly be made. In reviewing administrative decisions, it is beyond the province of this Court to weigh the conflicting evidence, determine the credibility of witnesses, or otherwise substitute its judgment for that of the administrative agency with respect to the sufficiency of evidence. It is not the function of this Court to analyze and weigh the parties� evidence all over again except when there is serious ground to believe that a possible miscarriage of justice would thereby result.[22]

We find no reason to depart from the foregoing rule.

The main issue in the administrative complaint for neglect of duty before the Ombudsman is whether Anciado and the other respondents therein committed neglect of duty in completing the road widening project along Dr. Fernandez Avenue. In resolving this issue, the Ombudsman held that:

The crux of the complaint appertains to the alleged neglect by the respondents in completing the project along Dr. Fernandez [Avenue].

However, as the records of the case will show, the purported failure to complete the project in question was totally beyond the control of the respondents, as the complainant has refused to cooperate in the intended re-survey of his property to determine whether the improvements he made have encroached upon a portion of the sidewalk. With this, the respondents can not be expected to pursue the project to its conclusion as they are hampered by the issue of the encroachment. The administrative charge of Neglect of Duty therefore is apparently without basis in fact and in law.

x x x

Needless to state, the matter of refusal of the complainant to cooperate with the respondents has been shown by several pieces of evidence, and the complainant can not be allowed to pass the buck onto the respondents.

But be that as it may, it has also been shown that, even before the filing of the present case on April 18, 2005, the matter of the encroachment by the complainant became the subject of appropriate proceedings before the City Council of Mandaluyong City, Committee on Engineering, as of April 5, 2008. Thus, it is incumbent that the said proceedings be allowed to continue until its conclusion. This is necessary since the issue in the present case, that is, whether the respondents indeed committed neglect of duty, becomes part and parcel of the issues in the said proceedings before the City Council.[23] (citations omitted)

As aptly found by the Ombudsman, which finding was affirmed by the CA, the delay in the completion of the drainage and other works on Dr. Fernandez Avenue, specifically the portion fronting the petitioner�s house, was not attributable to Anciado and the other employees of the Mandaluyong City Engineering Department. Moreover, this matter was clearly and sufficiently addressed by the respondent-employees of Mandaluyong City Engineering Department in their Joint Counter Affidavit[24] before the Ombudsman. Thus:

3.4 However, we could not proceed with the concreting of the pavement in front of the complainant�s property since this will entail removing the temporary drainage pipe underneath that we installed to prevent flooding in the area. This temporary drainage pipe is connected to the newly installed big culvert pipe and the old lined canal is located inside the encroached area of the complainant x x x. Also, this temporary drainage pipe is to be replaced by a big culvert pipe after the issue on complainant�s encroachment shall have been resolved. Thus, if we proceeded with the concreting of said pavement, the City Government would have only incurred additional expenses because later on the same would be demolished to give way to the replacement of said temporary drainage pipe by a big culvert pipe.[25]

All told, we find that the petitioner failed to show any grave abuse of discretion or any reversible error on the part of the Ombudsman in issuing the July 6, 2005 and October 5, 2005 Orders, the same having been subsequently affirmed by the CA, which would impel this Court to rule otherwise.cralaw

WHEREFORE, in consideration of the foregoing disquisitions, the petition is DENIED. The assailed Decision dated August 8, 2008 and Resolution dated October 7, 2008 issued by the Court of Appeals in CA-G.R. SP No. 92771 are AFFIRMED.

SO ORDERED.

Carpio, (Chairperson), Villarama, Jr.,
* Perez, and Sereno, JJ., concur.

Endnotes:


* Additional Member in lieu of Associate Justice Arturo D. Brion per Special Order No. 1195 dated February 15, 2012.

[1] Penned by Associate Justice Mario L. Guari�a III, with Associate Justices Celia C. Librea-Leagogo and Mariflor P. Punzalan-Castillo, concurring; rollo, pp. 336-346.

[2] Id. at 374.

[3] Id. at 55.

[4] Id. at 57-58.

[5] Id. at 101-102.

[6] Id. at 62.

[7] Id. at 63.

[8] Id. at 64.

[9] Id. at 91.

[10] Id. at 115.

[11] Id. at 65-73.

[12] Id. at 151-162.

[13] Id. at 159-161.

[14] Id. at 163-172.

[15] Id. at 191-198.

[16] Id. at 204-232.

[17] Supra note 1.

[18] Rollo, pp. 344-345.

[19] Supra note 2.

[20] Republic of the Philippines v. De Guzman, G.R. No. 175021, June 15, 2011.

[21] Sps. Pengson v. Ocampo, Jr., 412 Phil. 860, 865-866 (2001).

[22] Tolentino v. Loyola, G.R. No. 153809, July 27, 2011.

[23] Rollo, pp. 159-161.

[24] Id. at 93-97.

[25] Id. at 94.



Back to Home | Back to Main




















chanrobles.com





ChanRobles On-Line Bar Review

ChanRobles Internet Bar Review : www.chanroblesbar.com

ChanRobles MCLE On-line

ChanRobles Lawnet Inc. - ChanRobles MCLE On-line : www.chanroblesmcleonline.com






February-2012 Jurisprudence                 

  • [G.R. No. 179579 : February 01, 2012] COMMISSIONER OF CUSTOMS AND THE DISTRICT COLLECTOR OF THE PORT OF SUBIC, PETITIONERS, VS. HYPERMIX FEEDS CORPORATION, RESPONDENT.

  • [G.R. No. 188722 : February 01, 2012] BANK OF LUBAO, INC., PETITIONER, VS. ROMMEL J. MANABAT AND THE NATIONAL LABOR RELATIONS COMMISSION, RESPONDENTS.

  • [G.R. No. 186226 : February 01, 2012] PEOPLE OF THE PHILIPPINES, APPELLEE, VS. YUSOP TADAH, APPELLANT.

  • [G.R. No. 185669 : February 01, 2012] JUAN GALOPE, PETITIONER, VS. CRESENCIA BUGARIN, REPRESENTED BY CELSO RABANG, RESPONDENT.

  • [G.R. No. 183093 : February 01, 2012] PEOPLE OF THE PHILIPPINES, PLAINTIFF-APPELLEE, VS. DIOSDADO TUBAT Y VERSOZA, ACCUSED-APPELLANT.

  • [G.R. No. 181974 : February 01, 2012] LYNVIL FISHING ENTERPRISES, INC. AND/OR ROSENDO S. DE BORJA, PETITIONERS, VS. ANDRES G. ARIOLA, JESSIE D. ALCOVENDAS, JIMMY B. CALINAO AND LEOPOLDO G. SEBULLEN, RESPONDENTS.

  • [G.R. No. 194320 : February 01, 2012] MALAYAN INSURANCE CO., INC., PETITIONER, VS. RODELIO ALBERTO AND ENRICO ALBERTO REYES, RESPONDENTS.

  • [G.R. No. 151258 : February 01, 2012] ARTEMIO VILLAREAL, PETITIONER, VS. PEOPLE OF THE PHILIPPINES, RESPONDENT. [G.R. NO. 154954] PEOPLE OF THE PHILIPPINES, PETITIONER, VS. THE HONORABLE COURT OF APPEALS, ANTONIO MARIANO ALMEDA, DALMACIO LIM, JR., JUNEL ANTHONY AMA, ERNESTO JOSE MONTECILLO, VINCENT TECSON, ANTONIO GENERAL, SANTIAGO RANADA III, NELSON VICTORINO, JAIME MARIA FLORES II, ZOSIMO MENDOZA, MICHAEL MUSNGI, VICENTE VERDADERO, ETIENNE GUERRERO, JUDE FERNANDEZ, AMANTE PURISIMA II, EULOGIO SABBAN, PERCIVAL BRIGOLA, PAUL ANGELO SANTOS, JONAS KARL B. PEREZ, RENATO BANTUG, JR., ADEL ABAS, JOSEPH LLEDO, AND RONAN DE GUZMAN, RESPONDENTS. [G.R. NO. 155101] FIDELITO DIZON, PETITIONER, VS. PEOPLE OF THE PHILIPPINES, RESPONDENT. [G.R. NOS. 178057 & 178080] GERARDA H. VILLA, PETITIONER, VS. MANUEL LORENZO ESCALONA II, MARCUS JOEL CAPELLAN RAMOS, CRISANTO CRUZ SARUCA, JR., AND ANSELMO ADRIANO, RESPONDENTS.

  • [G.R. No. 172455 : February 01, 2012] ANTONIO CHUA, PETITIONER, VS. TOTAL OFFICE PRODUCTS AND SERVICES (TOPROS), INC., RESPONDENT.

  • [G.R. No. 182769 : February 01, 2012] BANK OF THE PHILIPPINE ISLANDS, AS SUCCESSOR-IN-INTEREST OF FAR EAST BANK & TRUST COMPANY, PETITIONER, VS. CYNTHIA L. REYES, RESPONDENT.

  • [G.R. Nos. 174941 : February 01, 2012] ANTONIO P. SALENGA AND NATIONAL LABOR RELATIONS COMMISSION, PETITIONERS, VS. COURT OF APPEALS AND CLARK DEVELOPMENT CORPORATION, RESPONDENTS.

  • [G.R. No. 184109 : February 01, 2012] CELERINO E. MERCADO, PETITIONER, VS. BELEN* ESPINOCILLA** AND FERDINAND ESPINOCILLA, RESPONDENTS.

  • [G.R. No. 186541 : February 01, 2012] PEOPLE OF THE PHILIPPINES, PLAINTIFF-APPELLEE, VS. VICENTE VILBAR, ACCUSED-APPELLANT.

  • [G.R. No. 167952 : February 01, 2012] GONZALO PUYAT & SONS, INC., PETITIONER, VS. RUBEN ALCAIDE (DECEASED), SUBSTITUTED BY GLORIA ALCAIDE, REPRESENTATIVE OF THE FARMER-BENEFICIARIES, RESPONDENT.

  • [G.R. No. 189496 : February 01, 2012] D.M. FERRER & ASSOCIATES CORPORATION, PETITIONER, VS. UNIVERSITY OF SANTO TOMAS, RESPONDENT.

  • [G.R. Nos. 186659-710 : February 01, 2012] ZACARIA A. CANDAO, ABAS A. CANDAO AND ISRAEL B. HARON, PETITIONERS, VS. PEOPLE OF THE PHILIPPINES AND SANDIGANBAYAN, RESPONDENTS.

  • [A.M. No. P-11-2926 : February 01, 2012] JUDGE LUCINA ALPEZ DAYAON, PRESIDING JUDGE, REGIONAL TRIAL COURT OF MACABEBE, PAMPANGA, BRANCH 54, COMPLAINANT, VS. JESUSA V. DE LEON, COURT STENOGRAPHER III OF THE SAME COURT, RESPONDENT.

  • [G.R. No. 173531 : February 01, 2012] LEONCIO C. OLIVEROS, REPRESENTED BY HIS HEIRS,* MOISES DE LA CRUZ,** AND THE HEIRS OF LUCIO DELA CRUZ, REPRESENTED BY FELIX DELA CRUZ, PETITIONERS, VS. BERSAMIN, SAN MIGUEL CORPORATION, THE REGISTER OF DEEDS OF CALOOCAN CITY, AND THE REGISTER OF DEEDS OF VALENZUELA, METRO MANILA, RESPONDENTS.

  • [G.R. No. 171513 : February 06, 2012] ARNOLD JAMES M. YSIDORO, PETITIONER, VS. HON. TERESITA J. LEONARDO- DE CASTRO, HON. DIOSDADO M. PERALTA AND HON. EFREN N. DE LA CRUZ, IN THEIR OFFICIAL CAPACITIES AS PRESIDING JUSTICE AND ASSOCIATE JUSTICES, RESPECTIVELY, OF THE FIRST DIVISION OF THE SANDIGANBAYAN, AND NIERNA S. DOLLER, RESPONDENTS. [G.R. NO. 190963] PEOPLE OF THE PHILIPPINES, PETITIONER, VS. FIRST DIVISION OF THE SANDIGANBAYAN AND ARNOLD JAMES M. YSIDORO, RESPONDENTS.

  • [G.R. No. 189647 : February 06, 2012] NANCY T. LORZANO, PETITIONER, VS. JUAN TABAYAG, JR., RESPONDENT.

  • [G.R. No. 199150 : February 06, 2012] CARMINA G. BROKMANN, PETITIONER, VS. PEOPLE OF THE PHILIPPINES, RESPONDENT.

  • [G.R. No. 172223 : February 06, 2012] CANADIAN OPPORTUNITIES UNLIMITED, INC., PETITIONER, VS. BART Q. DALANGIN, JR., RESPONDENT.

  • [G.R. No. 193346 : February 06, 2012] PHILIPPINE NATIONAL BANK, PETITIONER, VS. SPOUSES ROGELIO AND EVELYN ROQUE, RESPONDENTS.

  • [G.R. No. 194306 : February 06, 2012] SEBASTIAN F. OASAY, JR. PETITIONER, VS. PALACIO DEL GOBERNADOR CONDOMINIUM CORPORATION AND/OR OMAR T. CRUZ, RESPONDENTS.

  • [G.R. No. 157838 : February 07, 2012] CANDELARIO L. VERZOSA, JR. (IN HIS FORMER CAPACITY AS EXECUTIVE DIRECTOR OF THE COOPERATIVE DEVELOPMENT AUTHORITY), PETITIONER, VS. GUILLERMO N. CARAGUE (IN HIS OFFICIAL CAPACITY AS CHAIRMAN OF THE COMMISSION ON AUDIT), RAUL C. FLORES, CELSO D. GANGAN, SOFRONIO B. URSAL AND COMMISSION ON AUDIT, RESPONDENTS.

  • [G.R. Nos. 153304-05 : February 07, 2012] PEOPLE OF THE PHILIPPINES, PETITIONER, VS. HON. SANDIGANBAYAN (FOURTH DIVISION), IMELDA R. MARCOS, JOSE CONRADO BENITEZ AND GILBERT C. DULAY,* RESPONDENTS.

  • [G. R. No. 180989 : February 07, 2012] GUALBERTO J. DELA LLANA, PETITIONER, VS. THE CHAIRPERSON, COMMISSION ON AUDIT, THE EXECUTIVE SECRETARY AND THE NATIONAL TREASURER, RESPONDENTS.

  • [G.R. No. 185572 : February 07, 2012] CHINA NATIONAL MACHINERY & EQUIPMENT CORP. (GROUP), PETITIONER, VS. HON. CESAR D. SANTAMARIA, IN HIS OFFICIAL CAPACITY AS PRESIDING JUDGE OF BRANCH 145, REGIONAL TRIAL COURT OF MAKATI CITY, HERMINIO HARRY L. ROQUE, JR., JOEL R. BUTUYAN, ROGER R. RAYEL, ROMEL R. BAGARES, CHRISTOPHER FRANCISCO C. BOLASTIG, LEAGUE OF URBAN POOR FOR ACTION (LUPA), KILUSAN NG MARALITA SA MEYCAUAYAN (KMM-LUPA CHAPTER), DANILO M. CALDERON, VICENTE C. ALBAN, MERLYN M. VAAL, LOLITA S. QUINONES, RICARDO D. LANOZO, JR., CONCHITA G. GOZO, MA. TERESA D. ZEPEDA, JOSEFINA A. LANOZO, AND SERGIO C. LEGASPI, JR., KALIPUNAN NG DAMAYANG MAHIHIRAP (KADAMAY), EDY CLERIGO, RAMMIL DINGAL, NELSON B. TERRADO, CARMEN DEUNIDA, AND EDUARDO LEGSON, RESPONDENTS.

  • [G.R. No. 173291 : February 08, 2012] ROMEO A. GALANG, PETITIONER, VS. CITYLAND SHAW TOWER, INC. AND VIRGILIO BALDEMOR, RESPONDENTS.

  • [G.R. No. 184015 : February 08, 2012] SPOUSES MARIANO P. MARASIGAN AND JOSEFINA LEAL, PETITIONERS, VS. CHEVRON PHILS., INC., ACCRA INVESTMENTS, CORP., AND ANGARA ABELLO CONCEPCION REGALA & CRUZ, RESPONDENTS.

  • [G.R. No. 176085 : February 08, 2012] FEDERICO S. ROBOSA, ROLANDO E. PANDY, NOEL D. ROXAS, ALEXANDER ANGELES, VERONICA GUTIERREZ, FERNANDO EMBAT, AND NANETTE H. PINTO, PETITIONERS, VS. NATIONAL LABOR RELATIONS COMMISSION (FIRST DIVISION), CHEMO-TECHNISCHE MANUFACTURING, INC. AND ITS RESPONSIBLE OFFICIALS LED BY FRANKLIN R. DE LUZURIAGA, AND PROCTER & GAMBLE PHILIPPINES, INC., RESPONDENTS.

  • [G.R. No. 160278, February 08, 2012] GARDEN OF MEMORIES PARK AND LIFE PLAN, INC. AND PAULINA T. REQUI�O, PETITIONERS, VS. NATIONAL LABOR RELATIONS COMMISSION, SECOND DIVISION, LABOR ARBITER FELIPE T. GARDUQUE II AND HILARIA CRUZ, RESPONDENTS.

  • [G.R. No. 158413 : February 08, 2012] CELSO M. MANUEL, EVANGELISTA A. MERU, FLORANTE A. MIANO, AND PEOPLE OF THE PHILIPPINES, PETITIONERS, VS. HON. SANDIGANBAYAN (FOURTH DIVISION), MELCHOR M. MALLARE AND ELIZABETH GOSUDAN, RESPONDENTS. [G.R. NO. 161133] MELCHOR M. MALLARE AND ELIZABETH GOSUDAN, PETITIONERS, VS. PEOPLE OF THE PHILIPPINES, RESPONDENT.

  • [G.R. No. 194653 : February 08, 2012] ANTONIO MENDOZA, PETITIONER, VS. FIL-HOMES REALTY DEVELOPMENT CORPORATION, RESPONDENT.

  • [A.M. No. MTJ-10-1761 : February 08, 2012] AIDA R. CAMPOS, ALISTAIR R. CAMPOS, AND CHARMAINE R. CAMPOS, COMPLAINANTS, VS. JUDGE ELISEO M. CAMPOS, MUNICIPAL TRIAL COURT, BAYUGAN, AGUSAN DEL SUR, RESPONDENT.

  • [G.R. No. 186720 : February 08, 2012] ELSA D. MEDADO, PETITIONER, VS. HEIRS OF THE LATE ANTONIO CONSING, AS REPRESENTED BY DR. SOLEDAD CONSING, RESPONDENTS.

  • [G. R. No. 183622 : February 08, 2012] MEROPE ENRIQUEZ VDA. DE CATALAN, PETITIONER, VS. LOUELLA A. CATALAN-LEE, RESPONDENT.

  • [G.R. No. 187733 : February 08, 2012] PEOPLE OF THE PHILIPPINES, APPELLEE, VS. TEOFILO �REY� BUYAGAN, APPELLANT.

  • [G.R. No. 192274 : February 08, 2012] NORBERTO LEE, PETITIONER, VS. PEOPLE OF THE PHILIPPINES AND ALLIED BANK, RESPONDENTS.

  • [G.R. No. 187490 : February 08, 2012] ANTONIA R. DELA PE�A AND ALVIN JOHN B. DELA PE�A, PETITIONERS, VS. GEMMA REMILYN C. AVILA AND FAR EAST BANK & TRUST CO., RESPONDENTS.

  • [A.M. No. RTJ-11-2291 : February 08, 2012] OFFICE OF THE COURT ADMINISTRATOR, COMPLAINANT, VS. JUDGE CELSO L. MANTUA, REGIONAL TRIAL COURT, BRANCH 17, PALOMPON, LEYTE, RESPONDENT.

  • [A.M. No. RTJ-10-2255 (Formerly OCA I.P.I. No. 10-3335-RTJ) : February 08, 2012] SPOUSES DEMOCRITO AND OLIVIA LAGO, COMPLAINANTS, VS. JUDGE GODOFREDO B. ABUL, JR., REGIONAL TRIAL COURT, BRANCH 43, GINGOOG CITY, RESPONDENT.

  • [G.R. No. 183132 : February 08, 2012] RICHARD CHUA, PETITIONER, VS. PEOPLE OF THE PHILIPPINES, RESPONDENT.

  • [A.M. No. P-06-2111 : February 08, 2012] ANNABELLE F. GARCIA, CLERK OF COURT, MUNICIPAL TRIAL COURT IN CITIES, BRANCH 2, OLONGAPO CITY, COMPLAINANT, VS. HERMINIO C. REYES AND ZOSIMA S. DE VERA, INTERPRETER AND STENOGRAPHER, RESPECTIVELY, MUNICIPAL TRIAL COURT IN CITIES, BRANCH 2, OLONGAPO CITY, RESPONDENTS.

  • [G.R. No. 187736 : February 08, 2012] PEOPLE OF THE PHILIPPINES, PLAINTIFF-APPELLEE, VS. FLORDELIZA ARRIOLA Y DE LARA, ACCUSED-APPELLANT.

  • [G.R. No. 190375 : February 08, 2012] TAN SHUY, PETITIONER, VS. SPOUSES GUILLERMO MAULAWIN AND PARING CARI�O-MAULAWIN, RESPONDENTS.

  • [G. R. No. 171701 : February 08, 2012] REPUBLIC OF THE PHILIPPINES PETITIONER, VS. MA. IMELDA "IMEE" R. MARCOS-MANOTOC, FERDINAND "BONGBONG" R. MARCOS, JR., GREGORIO MA. ARANETA III, IRENE R. MARCOS-ARANETA, YEUNG CHUN FAN, YEUNG CHUN HO, YEUNG CHUN KAM, AND PANTRANCO EMPLOYEES ASSOCIATION (PEA)-PTGWO, RESPONDENTS.

  • [G.R. No. 161796 : February 08, 2012] LAND BANK OF THE PHILIPPINES, PETITIONER, VS. ESTATE OF J. AMADO ARANETA, RESPONDENT. [G.R. NO. 161830] DEPARTMENT OF AGRARIAN REFORM,[1] PETITIONER, NORBERTO RESULTA, EDITHA ABAD, LEDELIA ASIDOY, GIL PAGARAGAN, ROSALITO PAGHUBASAN, EDWIN FAUSTINO, FELOMINO JUSOL, EDELBERTO POBLARES, EFREN APON, NELSON VILLAREAL, JIMMY ZONIO, SERLISTO ZONIO, WILFREDO MARCELINO, ROGELIO RODERO, SERGIO ZONIO, NORBERTO FRANCISCO, AURORA VILLACORTE, JOVITO NINONUEVO, ELIZABETH ZAUSA, RUBEN VILLANUEVA, VICENTA RACCA, ROGELIO RACCA, MERCEDES VILLANUEVA, EDUARDO BIUTE, APOLINARIO TORRAL, BENJAMIN TANJER, JR., MINDA SOLIMAN, CIPRIANO REQUIOLA, GLORIA ROMERO, SILVERIO ZONIO, NESTOR ZONIO, NILO ZAUSA, ROMUALDO ZAUSA, REYNALDO ZAUSA, LUMILYN ZAUSA, GILBERT BAUTISTA, GILDA PACETES, ALUDIA CALUB, LOURDES CAGNO, ABELARDO CAGNO, BENJAMIN MARINAS, CRISPINA ARNAIZ, MARIA CABUS, RESTITUTA PRETENCIO, MA. LUZ ABALOS, ABELARDO DEL ROSARIO, CANDELARIA CEPEDA, HAYDEE MARQUILENCIA, LEONCIA ZATA, LUCIA LOPEZ, MARGARITA MANLANGIT, CRISTINA PACIS, LEONELDA FIDELA, MA. BLESS MASAGNAY, AGUSTIN CADAO, DOLORES FELICIANO, MA. JESSICA FELICIANO, MA. LOURDES FELICIANO, MA. JULITA FELICIANO, FEDERICO ZONIO, NENITA SINGSON, LIBRADA ZASPA, THELMA ELISERIO, SALVADOR VILLORENTE, SATURNINA TESORERO, ROGELIO PARACUELES, ANITA MENDOZA, AMADEO MASAGNAY, ELVIRA CAMPOS, LAURIANO CAMPOS, BENITO VILLAGANAS, VIRGILIO FERRER, SALVADOR RESULTA, NORLITO RESULTA, DIANA SEPTIMO, SALVADOR SEPTIMO, DIOSDADO LAGMAN, CLAUDIA MIRALLES, RICARDO FRANCISCO, RODOLFO FRANCISCO, ALEXANDER YURONG, ALFREDO BUENAVENTURA, ISIDRO DELA CRUZ, REMEDIOS CABUNDOC, ARTEMIO MIRASOL, MINDA COPINO, ANDRES IBARBIA, WILFREDO BALLOS, ELSA BANGCA, ARTURO CANTURIA, PABLITO SAGUIBO, CARLITO VILLONES, JOSEFINA TABANGCURA, NEDA MASAGNAY, PETITIONERS-INTERVENORS, ESTELA MARIE MALOLOS, LORETO DELA CRUZ, JOSE PAJARILLO, IMELDA ZAUSA, FEDERICO ZAUSA REPRESENTED BY ROSALINDA ZAUSA, LUDEVICO ZAUSA, GLORIA VILLANUEVA, ZENAIDA MASAGNAY, ELSIO ESTO, RODOLFO VILLONES, ALVINO NARCI REPRESENTED BY LILIA VILLONES, RUFINO ZONIO, ALBERTO ROSI, ZENAIDA VILLENA, ANTONIO ZAUSA, SALDITO ZONIO, ZACARIAS CORTEZ, LARRY MASAGNAY REPRESENTED BY LEONEL MASAGNAY, ERLINDA MORISON, JUAN CORTEZ, PRIMITIBO NICASIO, CARMELO CESAR, ANDRES ZONIO REPRESENTED BY RUFINO ZONIO, JUANITO ZONIO, JERENCIO ZONIO, ALEX CORTEZ, PEPITO VILLAREAL, PETITIONERS-MOVANTS, VS. ESTATE OF J. AMADO ARANETA, RESPONDENT. [G.R. NO. 190456] ERNESTO B. DURAN, LOPE P. ABALOS (DECEASED) REPRESENTED BY LOPE ABALOS, JR., ARTEMIO T. GONZALES (DECEASED) REPRESENTED BY PAUL GONZALES, AUGUSTO LIM, IMELDA MARCELINO, ERNESTO NAVARTE (DECEASED) REPRESENTED BY SURVIVING SPOUSE NELIA NAVARTE, FLORANTE M. QUIMZON, MANUEL R. QUIMZON (DECEASED) REPRESENTED BY FLORANTE M. QUIMZON, NELIA ZAUSA, PETITIONERS-INTERVENORS, VS. ESTATE OF J. AMADO ARANETA, RESPONDENT.

  • [G.R. No. 165935 : February 08, 2012] BRIGHT MARITIME CORPORATION (BMC)/DESIREE P. TENORIO, PETITIONERS, VS. RICARDO B. FANTONIAL, RESPONDENT.

  • [G.R. No. 175558 : February 08, 2012] SKIPPERS UNITED PACIFIC, INC. AND SKIPPERS MARITIME SERVICES, INC., LTD., PETITIONERS, VS. NATHANIEL DOZA, NAPOLEON DE GRACIA, ISIDRO L. LATA, AND CHARLIE APROSTA, RESPONDENTS.

  • [G.R. No. 185665 : February 08, 2012] EASTERN TELECOMMUNICATIONS PHILIPPINES, INC., PETITIONER, VS. EASTERN TELECOMS EMPLOYEES UNION, RESPONDENT.

  • [G.R. No. 183444 : February 08, 2012] DEPARTMENT OF PUBLIC WORKS AND HIGHWAYS, PETITIONER, VS. RONALDO E. QUIWA, DOING BUSINESS UNDER THE NAME �R.E.Q. CONSTRUCTION,� EFREN N. RIGOR, DOING BUSINESS UNDER THE NAME �CHIARA CONSTRUCTION,� ROMEO R. DIMATULAC, DOING BUSINESS UNDER THE NAME �ARDY CONSTRUCTION,� AND FELICITAS C. SUMERA, DOING BUSINESS UNDER THE NAME �F.C.S. CONSTRUCTION,� REPRESENTED BY HER ATTORNEY-IN-FACT ROMEO M. DE LEON, RESPONDENTS.

  • [G.R. No. 197815 : February 08, 2012] THE PEOPLE OF THE PHILIPPINES, APPELLEE, VS. JULIETO SANCHEZ @ "OMPONG," APPELLANT.

  • [G.R. No. 180157 : February 08, 2012] EQUITABLE CARDNETWORK, INC., PETITIONER, VS. JOSEFA BORROMEO CAPISTRANO, RESPONDENT.

  • [A.M. No. 11-10-7-SC : February 14, 2012] RE: REQUEST OF JUSTICE JOSEFINA GUEVARA-SALONGA, COURT OF APPEALS, THAT HER SERVICES AS ASSISTANT PROVINCIAL FISCAL OF LAGUNA BE CREDITED AS PART OF HER SERVICES IN THE JUDICIARY FOR PURPOSES OF HER RETIREMENT.

  • [G.R. No. 194710 : February 14, 2012] MANILA INTERNATIONAL AIRPORT AUTHORITY, PETITIONER, VS. COMMISSION ON AUDIT, RESPONDENT.

  • [G.R. No. 180784 : February 15, 2012] INSURANCE COMPANY OF NORTH AMERICA, PETITIONER, VS. ASIAN TERMINALS, INC., RESPONDENT.

  • [G.R. No. 175932 : February 15, 2012] WUERTH PHILIPPINES, INC., PETITIONER, VS. RODANTE YNSON, RESPONDENT.

  • [A.C. No. 8254 (Formerly CBD Case No. 04-1310) : February 15, 2012] NESA ISENHARDT, COMPLAINANT, VS. ATTY. LEONARDO M. REAL, RESPONDENT.

  • [G.R. No. 178593 : February 15, 2012] REPUBLIC OF THE PHILIPPINES, REPRESENTED BY THE PRIVATIZATION AND MANAGEMENT OFFICE (PMO), PETITIONER, VS. PANTRANCO NORTH EXPRESS, INC. (PNEI), PANTRANCO EMPLOYEES ASSOCIATION (PEA-PTGWO), EUSEBIO RAMOSO, CIRIACO M. MAGSINO, A. CACHUELA, A. CAMUS, M. CALAHI, R. CANO, B.T. LANTANO, L. BERSAMINA, A. ALFARO AND 495 OTHERS, RESPONDENTS.

  • [G.R. No. 190022 : February 15, 2012] PHILIPPINE NATIONAL RAILWAYS CORPORATION, JAPHET ESTRANAS AND BEN SAGA, PETITIONERS, VS. PURIFICACION VIZCARA, MARIVIC VIZCARA, CRESENCIA A. NATIVIDAD, HECTOR VIZCARA, JOEL VIZCARA AND DOMINADOR ANTONIO, RESPONDENTS.

  • [A.M. No. P-11-2951 (Formerly A.M. No. 10-3544-P) : February 15, 2012] LEAVE DIVISION, OFFICE OF ADMINISTRATIVE SERVICES, OFFICE OF THE COURT ADMINISTRATOR, COMPLAINANT, VS. LEONCIO K. GUTIERREZ III, CLERK III, REGIONAL TRIAL COURT, BRANCH 116, PASAY CITY, RESPONDENT.

  • [G.R. No. 152262 : February 15, 2012] FELIMON MANGUIOB, PETITIONER, VS. JUDGE PAUL T. ARCANGEL, RTC, BRANCH 12, DAVAO CITY AND ALEJANDRA VELASCO, RESPONDENTS.

  • [G.R. No. 174445 : February 15, 2012] SPOUSES WILLIAM GUIDANGEN AND MARY GUIDANGEN, PETITIONERS, VS. DEVOTA B. WOODEN, RESPONDENT.

  • [G.R. No. 173882 : February 15, 2012] JULIE�S BAKESHOP AND/OR EDGAR REYES, PETITIONERS, VS. HENRY ARNAIZ EDGAR NAPAL,* AND JONATHAN TOLORES, RESPONDENTS.

  • [G.R. No. 185053 : February 15, 2012] EUSTAQUIO CANDARI, JR., RENE ESPULGAR, EDITHA DACIA, GONZALO PALMA, JR., ANDRES DE LEON, ARNOLD BAJAR, PETER BAYBAYAN, EUGENIO TABURNO, MATEO ALOJADO, ANSELMO LIGTAS, FLORITA BULANGIS, ADELAIDA PENIG, ATTY. LEVI SALIGUMBA, EDITHA JIMENA, CYNTHIA BELARMA AND ANTONIA BANTING, PETITIONERS, VS. ROLAND DONASCO, LIDIO VILLA, RENE GAID, PEPITO GUMBAN, OSCAR ANDRADA, ROMEO CASTONES, ROSEMARY CORDOVA, GLORIA MATULLANO, PONCIANO ABALOS, RESTITUTO BATIANCILLA, RESPONDENTS.

  • [G.R. No. 187926 : February 15, 2012] DR. EMMANUEL JARCIA, JR. AND DR. MARILOU BASTAN, PETITIONERS, VS. PEOPLE OF THE PHILIPPINES, RESPONDENT.

  • [G.R. No. 173128 : February 15, 2012] MARITIMEINDUSTRY AUTHORITY (MARINA) AND/OR ATTY. OSCAR M. SEVILLA, PETITIONERS, VS. MARC PROPERTIES CORPORATION, RESPONDENT.

  • [G.R. No. 185212 : February 15, 2012] PEOPLE OF THE PHILIPPINES, APPELLEE, VS. MARITESS ALOLOD, EFREN DEOCAMPO, ELMER DEOCAMPO AND EDWIN DEOCAMPO, ACCUSED, EFREN DEOCAMPO, APPELLANT.

  • [G.R. No. 187157 : February 15, 2012] PEOPLE OF THE PHILIPPINES, PLAINTIFF-APPELLEE, VS. ARNEL CLARITE Y SALAZAR, ACCUSED-APPELLANT.

  • [G.R. No. 187567 : February 15, 2012] THE REPUBLIC OF THE PHILIPPINES, PETITIONER, VS. NORA FE SAGUN, RESPONDENT.

  • [G.R. No. 175025 : February 15, 2012] ROGELIO J. JAKOSALEM AND GODOFREDO B. DULFO PETITIONERS, VS. ROBERTO S. BARANGAN, RESPONDENT.

  • [G.R. No. 175980 : February 15, 2012] PEOPLE OF THE PHILIPPINES,APPELLEE, VS. ADRIANO CABRILLAS, ACCUSED, BENNY CABTALAN, APPELLANT.

  • [G.R. No. 179469 : February 15, 2012] C.F. SHARP & CO. INC. AND JOHN J. ROCHA, PETITIONERS, VS. PIONEER INSURANCE & SURETY CORPORATION, WILFREDO C. AGUSTIN AND HERNANDO G. MINIMO, RESPONDENTS.

  • [G.R. No. 161771 : February 15, 2012] BANK OF THE PHILIPPINE ISLANDS, AS SUCCESSOR-IN-INTEREST OF FAR EAST BANK AND TRUST COMPANY, PETITIONER, VS. EDUARDO HONG, DOING BUSINESS UNDER THE NAME AND STYLE �SUPER LINE PRINTING PRESS� AND THE COURT OF APPEALS, RESPONDENTS.

  • [G.R. No. 186269 : February 15, 2012] SPOUSES ROMAN A. PASCUAL AND MERCEDITA R. PASCUAL, FRANCISCO A. PASCUAL, MARGARITA CORAZON D. MARIANO, EDWIN D. MARIANO AND DANNY R. MARIANO PETITIONERS, VS. SPOUSES ANTONIO BALLESTEROS AND LORENZA MELCHOR-BALLESTEROS, RESPONDENTS.

  • [G.R. No. 184851 : February 15, 2012] VALIENTE C. VILLEGAS PETITIONER, VS. THE HONORABLE VICTOR C. FERNANDEZ, DEPUTY OMBUDSMAN FOR LUZON, CONRADO S. ANCIADO, JR., ROLLY P. DANILA, ANDREI S. ARABIT AND JAIME M. BARON, RESPONDENTS.

  • [G.R. No. 192558 : February 15, 2012] BITOY JAVIER (DANILO P. JAVIER), PETITIONER, VS. FLY ACE CORPORATION/ FLORDELYN CASTILLO, RESPONDENTS.

  • [G.R. No. 157810 : February 15, 2012] ROLANDO SOFIO AND RUFIO SOFIO, PETITIONERS, VS. ALBERTO I. VALENZUELA, GLORIA I. VALENZUELA, REMEDIOS I. VALENZUELA, AND CESAR I. VALENZUELA, RESPONDENTS.

  • [G.R. No. 181485 : February 15, 2012] PHILIPPINE NATIONAL BANK, PETITIONER, VS. GATEWAY PROPERTY HOLDINGS, INC., RESPONDENT.

  • [A.C. No. 7430 : February 15, 2012] MARTIN LAHM III AND JAMES P. CONCEPCION, COMPLAINANTS, VS. LABOR ARBITER JOVENCIO LL. MAYOR, JR., RESPONDENT.

  • [G.R. No. 186961 : February 20, 2012] REPUBLIC OF THE PHILIPPINES, PETITIONER, VS. EAST SILVERLANE REALTY DEVELOPMENT CORPORATION, RESPONDENT.

  • [G.R. No. 185463 : February 22, 2012] TEEKAY SHIPPING PHILS., INC., AND/OR TEEKAY SHIPPING CANADA, PETITIONERS, VS. RAMIER C. CONCHA RESPONDENT.

  • [G.R. No. 190794 : February 22, 2012] JOSAN, JPS, SANTIAGO CARGO MOVERS, AND MARY GRACE S. PARUNGAO,* PETITIONERS, VS. EDUARDO RAMOS ADUNA, RESPONDENT.

  • [G.R. No. 186983 : February 22, 2012] MA. LOURDES S. FLORENDO, PETITIONER, VS. PHILAM PLANS, INC., PERLA ABCEDE AND MA. CELESTE ABCEDE, RESPONDENTS.

  • [G.R. Nos. 180631-33 : February 22, 2012] PHILIPPINE CHARTER INSURANCE CORPORATION, PETITIONER, VS. CENTRAL COLLEGES OF THE PHILIPPINES AND DYNAMIC PLANNERS AND CONSTRUCTION CORPORATION, RESPONDENTS.

  • [G.R. No. 177320 : February 22, 2012] PEOPLE OF THE PHILIPPINES, PLAINTIFF-APPELLEE, VS. CESAR BAUTISTA Y SANTOS, ACCUSED-APPELLANT.

  • [G.R. No. 172448 : February 22, 2012] THE BOARD OF REGENTS OF THE MINDANAO STATE UNIVERSITY REPRESENTED BY ITS CHAIRMAN, PETITIONER, VS. ABEDIN LIMPAO OSOP, RESPONDENT.

  • [G.R. No. 192085 : February 22, 2012] CARIDAD SEGARRA SAZON, PETITIONER, VS. LETECIA VASQUEZ-MENANCIO, REPRESENTED BY ATTORNEY-IN-FACT EDGAR S. SEGARRA, RESPONDENT.

  • [A.M. No. RTJ-11-2298 : February 22, 2012] ATTY. RENE O. MEDINA AND ATTY. CLARITO SERVILLAS, COMPLAINANTS, VS. JUDGE VICTOR A. CANOY, REGIONAL TRIAL COURT, BRANCH 29, SURIGAO CITY, RESPONDENT.

  • [G. R. No. 189021 : February 22, 2012] REPUBLIC OF THE PHILIPPINES, PETITIONER, VS. LUCIA M. GOMEZ, RESPONDENT.

  • [G.R. No. 165413 : February 22, 2012] PHILAM INSURANCE COMPANY, INC. AND AMERICAN HOME INSURANCE CO., PETITIONERS, VS. COURT OF APPEALS, AND D.M. CONSUNJI INC., RESPONDENTS.

  • [G.R. No. 169055 : February 22, 2012] SPOUSES JOSE AND MILAGROS VILLACERAN AND FAR EAST BANK & TRUST COMPANY, PETITIONERS, VS. JOSEPHINE DE GUZMAN, RESPONDENT.

  • [G.R. No. 191365 : February 22, 2012] PEOPLE OF THE PHILIPPINES, PLAINTIFF-APPELLEE, VS. EDUARDO NAVARETTE, JR. Y NATO, ACCUSED-APPELLANT.

  • [G.R. No. 181368 : February 22, 2012] GEORGE S. TOLENTINO, MONICA S. TOLENTINO, GUSTAVO S. TOLENTINO, JR., MA. MARJORIE S. TOLENTINO, MARILYN S. TOLENTINO, MICHAEL GLEN S. TOLENTINO, MYLENE S. TOLENTINO, MILAGROS M. GUEVARRA, MA. VICTORIA T. RAMIREZ, LORENZA T. ANDES, MICHAEL T. MEDRANO AND JACINTO T. MEDRANO, PETITIONERS, VS. PACIFICO S. LAUREL, HEIRS OF ILUMINADA LAUREL-ASCALON, CONSUELO T. LAUREL, BIENVENIDO LAUREL, HEIRS OF ARCHIMEDES LAUREL, TEODORO LAUREL, FE LAUREL-LIMJUCO AND CLARO LAUREL, RESPONDENTS.

  • [G.R. No. 173008 : February 22, 2012] NENITA GONZALES, SPOUSES GENEROSA GONZALES AND RODOLFO FERRER, SPOUSES FELIPE GONZALES AND CAROLINA SANTIAGO, SPOUSES LOLITA GONZALES AND GERMOGENES GARLITOS, SPOUSES DOLORES GONZALES AND FRANCISCO COSTIN, SPOUSES CONCHITA GONZALES AND JONATHAN CLAVE, AND SPOUSES BEATRIZ GONZALES AND ROMY CORTES, REPRESENTED BY THEIR ATTORNEY-IN-FACT AND CO-PETITIONER NENITA GONZALES, PETITIONERS, VS. MARIANO BUGAAY AND LUCY BUGAAY, SPOUSES ALICIA BUGAAY AND FELIPE BARCELONA, CONEY �CONIE� BUGAAY, JOEY GATAN, LYDIA BUGAAY, SPOUSES LUZVIMINDA BUGAAY AND REY PAGATPATAN AND BELEN BUGAAY, RESPONDENTS.

  • [G.R. No. 187122 : February 22, 2012] NEGROS SLASHERS, INC., RODOLFO C. ALVAREZ AND VICENTE TAN, PETITIONERS, VS. ALVIN L. TENG, RESPONDENT.

  • [G.R. No. 173476 : February 22, 2012] PEOPLE OF THE PHILIPPINES, PLAINTIFF-APPELLEE, VS. RODRIGO SALAFRANCA Y BELLO, ACCUSED-APPELLANT.

  • [G.R. No. 184556 : February 22, 2012] CHINA BANKING CORPORATION, PETITIONER, VS. QBRO FISHING ENTERPRISES, INC., RESPONDENT.

  • [G.R. No. 187229 : February 22, 2012] ARNEL SISON Y ESCUADRO, PETITIONER, VS. PEOPLE OF THE PHILIPPINES, RESPONDENT.

  • [G.R. No. 181497 : February 22, 2012] PEOPLE OF THE PHILIPPINES, PLAINTIFF-APPELLEE, VS. PATERNO SARMIENTO SAMANDRE, ACCUSED-APPELLANT.

  • [A.M. No. P-11-2999 [formerly OCA IPI No. 10-3517-P] : February 27, 2012] SHEILA G. DEL ROSARIO, COURT STENOGRAPHER III, REGIONAL TRIAL COURT, BRANCH 36, SANTIAGO CITY, ISABELA, COMPLAINANT, VS. MARY ANNE C. PASCUA, COURT STENOGRAPHER III, SAME COURT, RESPONDENT.

  • [G.R. No. 197540 : February 27, 2012] PEOPLE OF THE PHILIPPINES, APPELLEE, VS. DINNES OLASO AND ROLLY ANGELIO, ACCUSED. ROLLY ANGELIO, APPELLANT.

  • [G.R. No. 186132 : February 27, 2012] PEOPLE OF THE PHILIPPINES, APPELLEE, VS. NESTOR TUGUINAY, APPELLANT.

  • [G.R. No. 180168 : February 27, 2012] MANILA INTERNATIONAL AIRPORT AUTHORITY, PETITIONER, VS. AVIA FILIPINAS INTERNATIONAL, INC., RESPONDENT.

  • [G.R. No. 186123 : February 27, 2012] PEOPLE OF THE PHILIPPINES, APPELLEE, VS. MARITES VALERIO Y TRAJE, APPELLANT.

  • [G.R. No. 182650 : February 27, 2012] TOMAS K. CHUA, PETITIONER, VS. WESTMONT BANK, REGISTRAR OF DEEDS OF PARA�AQUE CITY, REGISTRAR OF DEEDS OF PASAY CITY, NOTARY PUBLIC MANUEL FONACIER, AND JOHN DOES, RESPONDENTS.

  • [G.R. No. 182197 : February 27, 2012] PEOPLE OF THE PHILIPPINES, APPELLEE, VS. TEOFILO HONRADO AND ROMULO HONRADO, APPELLANTS.

  • [G.R. No. 193065 : February 27, 2012] DEUTSCHE BANK AG, PETITIONER, VS. COURT OF APPEALS AND STEEL CORPORATION OF THE PHILIPPINES, RESPONDENTS.

  • [G.R. No. 162196 : February 27, 2012] SAN JOSE TIMBER CORPORATION AND CASILAYAN SOFTWOOD DEVELOPMENT CORPORATION, PETITIONERS, VS. SECURITIES AND EXCHANGE COMMISSION, TIERRA FACTOR CORPORATION AND OTHER CREDITORS OF SAN JOSE TIMBER CORPORATION AND CASILAYAN SOFTWOOD DEVELOPMENT CORPORATION, RESPONDENTS.

  • [G.R. No. 192565 : February 28, 2012] UNION BANK OF THE, PHILIPPINES AND DESI TOMAS, PETITIONERS, VS. PEOPLE OF THE PHILIPPINES, RESPONDENT.

  • [G.R. No. 196271 : February 28, 2012] DATU MICHAEL ABAS KIDA, IN HIS PERSONAL CAPACITY, AND IN REPRESENTATION OF MAGUINDANAO FEDERATION OF AUTONOMOUS IRRIGATORS ASSOCIATION, INC., HADJI MUHMINA J. USMAN, JOHN ANTHONY L. LIM, JAMILON T. ODIN, ASRIN TIMBOL JAIYARI, MUJIB M. KALANG, ALIH AL-SAIDI J. SAPI-E, KESSAR DAMSIE ABDIL, AND BASSAM ALUH SAUPI, PETITIONERS, VS. SENATE OF THE PHILIPPINES, REPRESENTED BY ITS PRESIDENT JUAN PONCE ENRILE, HOUSE OF REPRESENTATIVES, THRU SPEAKER FELICIANO BELMONTE, COMMISSION ON ELECTIONS, THRU ITS CHAIRMAN, SIXTO BRILLANTES, JR., PAQUITO OCHOA, JR., OFFICE OF THE PRESIDENT EXECUTIVE SECRETARY, FLORENCIO ABAD, JR., SECRETARY OF BUDGET, AND ROBERTO TAN, TREASURER OF THE PHILIPPINES, RESPONDENTS. [G.R. NO. 196305] BASARI D. MAPUPUNO, PETITIONER, VS. SIXTO BRILLANTES, IN HIS CAPACITY AS CHAIRMAN OF THE COMMISSION ON ELECTIONS, FLORENCIO ABAD, JR. IN HIS CAPACITY AS SECRETARY OF THE DEPARTMENT OF BUDGET AND MANAGEMENT, PAQUITO OCHOA, JR., IN HIS CAPACITY AS EXECUTIVE SECRETARY, JUAN PONCE ENRILE, IN HIS CAPACITY AS SENATE PRESIDENT, AND FELICIANO BELMONTE, IN HIS CAPACITY AS SPEAKER OF THE HOUSE OF REPRESENTATIVES, RESPONDENTS. [G.R. NO. 197221] REP. EDCEL C. LAGMAN, PETITIONER, VS. PAQUITO N. OCHOA, JR., IN HIS CAPACITY AS THE EXECUTIVE SECRETARY, AND THE COMMISSION ON ELECTIONS, RESPONDENTS. [G.R. NO. 197280] ALMARIM CENTI TILLAH, DATU CASAN CONDING CANA, AND PARTIDO DEMOKRATIKO PILIPINO LAKAS NG BAYAN (PDP-LABAN), PETITIONERS, VS. THE COMMISSION ON ELECTIONS, THROUGH ITS CHAIRMAN, SIXTO BRILLANTES, JR., HON. PAQUITO N. OCHOA, JR., IN HIS CAPACITY AS EXECUTIVE SECRETARY, HON. FLORENCIO B. ABAD, JR., IN HIS CAPACITY AS SECRETARY OF THE DEPARTMENT OF BUDGET AND MANAGEMENT, AND HON. ROBERTO B. TAN, IN HIS CAPACITY AS TREASURER OF THE PHILIPPINES, RESPONDENTS. [G.R. NO. 197282] ATTY. ROMULO B. MACALINTAL, PETITIONER, VS. COMMISSION ON ELECTIONS AND THE OFFICE OF THE PRESIDENT, THROUGH EXECUTIVE SECRETARY PAQUITO N. OCHOA, JR., RESPONDENTS. [G.R. NO. 197392] LOUIS �BAROK� C. BIRAOGO, PETITIONER, VS. THE COMMISSION ON ELECTIONS AND EXECUTIVE SECRETARY PAQUITO N. OCHOA, JR., RESPONDENTS. [G.R. NO. 197454] JACINTO V. PARAS, PETITIONER, VS. EXECUTIVE SECRETARY PAQUITO N. OCHOA, JR., AND THE COMMISSION ON ELECTIONS, RESPONDENTS. MINORITY RIGHTS FORUM, PHILIPPINES, INC., RESPONDENTS-INTERVENOR.

  • [G.R. No. 193978 : February 28, 2012] JELBERT B. GALICTO, PETITIONER, VS. H.E. PRESIDENT BENIGNO SIMEON C. AQUINO III, IN HIS CAPACITY AS PRESIDENT OF THE REPUBLIC OF THE PHILIPPINES; ATTY. PAQUITO N. OCHOA, JR., IN HIS CAPACITY AS EXECUTIVE SECRETARY; AND FLORENCIO B. ABAD, IN HIS CAPACITY AS SECRETARY OF THE DEPARTMENT OF BUDGET AND MANAGEMENT, RESPONDENTS.

  • [G.R. No. 192984 : February 28, 2012] ROLANDO D. LAYUG, PETITIONER, VS. COMMISSION ON ELECTIONS, MARIANO VELARDE (ALIAS �BROTHER MIKE�) AND BUHAY PARTY-LIST, RESPONDENTS.

  • [G.R. No. 169903 : February 29, 2012] LAND BANK OF THE PHILIPPINES, PETITIONER, VS. HONEYCOMB FARMS CORPORATION, RESPONDENT.

  • [G.R. No. 158379 : February 29, 2012] SPOUSES PONCIANO & PACITA DELA CRUZ, PETITIONERS, VS. HEIRS OF PABLO SUNIA, ETC.,[1] RESPONDENTS.

  • [G. R. No. 197788 : February 29, 2012] RODEL LUZ Y ONG, PETITIONER, VS. PEOPLE OF THE PHILIPPINES,[1] RESPONDENT.

  • [G.R. No. 189327 : February 29, 2012] PEOPLE OF THE PHILIPPINES, PLAINTIFF-APPELLEE, VS. EMILY MENDOZA Y SARTIN, ACCUSED-APPELLANT.

  • [G.R. No. 188132 : February 29, 2012] PEOPLE OF THE PHILIPPINES, PLAINTIFF-APPELLEE, VS. ROSEMARIE MAGUNDAYAO Y ALEJANDRO ALIAS �ROSE,� ACCUSED-APPELLANT.

  • [G.R. No. 196830 : February 29, 2012] CESAR V. GARCIA, CARLOS RAZON, ALBERTO DE GUZMAN, TOMAS RAZON, OMER E. PALO, RIZALDE VALENCIA, ALLAN BASA, JESSIE GARCIA, ORAG, ROMMEL PANGAN, RUEL SOLIMAN, AND CENEN CANLAPAN, REPRESENTED BY CESAR V. GARCIA, PETITIONERS, VS. KJ COMMERCIAL AND REYNALDO QUE, RESPONDENTS.

  • [G.R. No. 170098 : February 29, 2012] DANIEL O. PADUATA, PETITIONER,VS. MANILA ELECTRIC COMPANY (MERALCO), RESPONDENT.

  • [G.R. No. 193667 : February 29, 2012] PEOPLE OF THE PHILIPPINES, APPELLEE, VS. MARIAVIC ESPENILLA Y MERCADO, APPELLANT.

  • [G.R. No. 185582 : February 29, 2012] TUNA PROCESSING, INC., PETITIONER, VS. PHILIPPINE KINGFORD, INC., RESPONDENT.

  • [G.R. Nos. 191288 & 191304 : February 29, 2012] MANILA ELECTRIC COMPANY, PETITIONER, VS. JAN CARLO GALA, RESPONDENT.

  • [G.R. No. 189191 : February 29, 2012] MID-ISLANDS POWER GENERATION CORPORATION, PETITIONER, VS. COURT OF APPEALS, POWER ONE CORPORATION, ISLANDS GRID NETWORK PHILIPPINES, INC., DAVID TAN, AND MANUEL LAURON,* RESPONDENTS.

  • [G.R. No. 197043 : February 29, 2012] PEOPLE OF THE PHILIPPINES, APPELLEE, VS. ANTONIO BALDOMAR Y LISCANO, APPELLANT.